Suspension or Termination for Convenience. The County may, at any time, without cause, order Respondent in writing to suspend, delay or interrupt the work in whole or in part for such period of time as the County may determine, or to terminate all or a portion of the Contract for the County’s convenience. Upon such termination, the Contract Price earned to the date of termination shall be paid to Respondent, but Respondent waives any claim for damages, including loss of profits arising out of or related to the early termination. Those Contract provisions which by their nature survive final acceptance shall remain in full force and effect. If the County orders a suspension, the Contract price and Contract time may be adjusted for increases in the cost and time caused by suspension, delay or interruption. No adjustment shall be made to the extent that performance is, was or would have been so suspended, delayed or interrupted by reason for which Respondent is responsible; or that an equitable adjustment is made or denied under another provision of this Contract.
Suspension or Termination for Convenience. The County may, at any time, without cause, order Respondent in writing to suspend, delay or interrupt the work in whole or in part for such period of time as the County may determine, or to terminate all or a portion of the Contract for the County’s convenience. Upon such termination, the Contract Price earned to the date of termination shall be paid to Respondent, but Respondent waives any claim for damages, including loss of profits arising out of or related to the early termination. Those Contract provisions which by their nature survive final acceptance shall remain in full force and effect. If the County orders a suspension, the Contract price and Contract time may be adjusted for increases in the cost and time caused by suspension, delay, or interruption. No adjustment shall be made to the extent that performance is, was or would have been so suspended, delayed or interrupted by reason for which Respondent is responsible; or that an equitable adjustment is made or denied under another provision of this Contract.
Suspension or Termination for Convenience. The Town reserves the right to suspend or terminate this Agreement. Notification of such suspension or termination will be made by the Town to the Contractor in writing and may include the whole or any specified part of the Agreement. If this Agreement, or a specified part hereof, is suspended or terminated by the Town, the Contractor will be paid a pro rata portion of the Contract Price, as determined by the Town based upon the part of the Agreement terminated and the percent of the work completed.
Suspension or Termination for Convenience. NSF reserves the right to suspend or to terminate the performance of work under this cooperative agreement, in whole or in part, whenever, for any reason, the NSF Grants and Agreements Officer shall determine that such suspension or termination is in the best interest of the Government. Such suspension or termination shall be subject to the conditions specified in paragraphs d. and e. of Article 25 of the Grant General Conditions (GC-1).
Suspension or Termination for Convenience. ADOT reserves the right to terminate the Agreement, in whole or in part at any time, when in the best interests of ADOT without penalty or recourse. Upon receipt of the written notice, the MPO shall stop all work, as directed in the notice, notify all sub-recipients of the effective date of the termination and minimize all further costs to ADOT. In the event of termination under this paragraph, all documents, data and reports prepared by the MPO under this Agreement shall become the property of and be delivered to ADOT upon request. The MPO shall be entitled to receive just and equitable compensation for work in progress, work completed, and materials accepted before the effective date of the termination. The MPO shall continue to perform, in accordance with the requirements of the Agreement, up to the date of termination, as directed in the termination notice. ADOT shall reimburse the MPO for those eligible expenses incurred during the Agreement period which are directly attributable to the completed portion of the work covered by this Agreement, provided that the work has been completed in a manner satisfactory and acceptable to ADOT. The MPO shall not incur new obligations for the terminated portion after the effective date of termination. ADOT may seek any remedy available at law for recovery of any funds paid to MPO for any and all amounts for which ADOT has made payment to the MPO if such amounts are not directly attributable to the completed portion of the work covered by this Agreement or have been paid to the MPO for work completed after the effective date of the termination. ??? WP Agreement JPA 13-000 Work Program Agreement FY2016SFY2018 Page 40 of 64 In addition to the rights reserved in the Agreement, ADOT may terminate the Agreement in whole or in part due to the failure of the MPO to comply with any term or condition of the Agreement, to acquire and maintain all required insurance policies, bonds, licenses and permits, or to make satisfactory progress in performing the Agreement. This Agreement may be terminated by either party provided that a termination shall not be effective until 30 days after a Party has served written notice up on the other Party. This Agreement may be terminated by mutual consent of both Parties or unilaterally by either Party without cause.
Suspension or Termination for Convenience. 29.1 Owner reserves the right to suspend or terminate this Contract, or any part thereof, upon notice, at any time and for any reason it deems fit, including for its convenience (i.e., without cause). Such suspension or termination will be made in writing and may include the whole or any specified part of this Contract.
29.2 If during the Term Owner elects to terminate the Agreement for convenience, Owner will provide Contractor with 30 days' prior notice. The purpose of the specified thirty-day notice is to allow the Parties sufficient time for the Contractor to efficiently demobilize. For purposes of clarity, this Section 29.2 shall not prevent or restrict Owner from terminating the Agreement under Article 28 DELAYS AND FORCE MAJEURE.
29.3 As full compensation for suspension or termination for convenience, Contractor will be reimbursed for the following costs, reasonably incurred, in addition to compensation for Work executed, without duplication of any item, to the extent that such costs result from such suspension of the Work:
(a) A standby charge to be paid to Contractor during the period of suspension which standby charge will be sufficient to compensate Contractor for keeping, to the extent required in Owner's notice of suspensions, its organization, labor, supervision and equipment committed to the Project in a standby status. Standby charges are limited to onsite costs only. CONTRACT MINING AGREEMENT 21
(b) All reasonable costs associated with the Demobilization as per schedule and reasonable costs associated with remobilization of Contractor's plant, forces and equipment to the extent required in the notice.
(c) An equitable amount to reimburse Contractor for the cost of maintaining and protecting that portion of the Project upon which Work has been suspended.
29.4 Upon receipt of notice to resume suspended Work, Contractor will resume the suspended Work within a reasonable time to the extent of the resumption of Work required in the notice. If, as a result of any such suspension of the Work, the cost to Contractor of subsequently performing the Work is substantially increased or decreased, Owner will make an equitable adjustment in its payment for any remaining portion of the Work. Further, the time of performance of this Contract will be subject to extension as necessitated by the suspension, plus a reasonable additional period for remobilization. The Contract will, accordingly, be amended by a Change Order, provided, however, that any claim by...
Suspension or Termination for Convenience. Either party has the right to suspend or terminate for convenience further performance under this Agreement upon twenty-four (24) hours’ nfootriecgeo.inNgotPwairtthisctia under Articles 2, 4 and 9 shall survive any such suspension or termination.
Suspension or Termination for Convenience. Tourismo Jobs can terminate your access to the Services and/or this Agreement for convenience via email notification to you and, in the event of such termination for convenience, you will receive a pro-rata refund of any pre-paid fees pertaining to Services that will not be provided as a result of the termination.
Suspension or Termination for Convenience. TRC will have the right at any time, by written notice to Subcontractor, to terminate or suspend this Subcontract without cause for any reason whatsoever. Termination or suspension for convenience may be exercised at the sole discretion of TRC without prejudice to any other rights of TRC, the exercise of which need not be reasonable, and regardless of whether Subcontractor is or is not in default. A termination or suspension for the convenience of TRC will be effective immediately upon Subcontractor’s receipt of a written notice from TRC unless otherwise stated in the notice.
Suspension or Termination for Convenience. Cruitbay can terminate YOUR access to the Services and/or this Agreement at its convenience and its sole discretion, via email notification to YOU and, in the event of such termination for convenience, YOU will receive a pro-rata refund of any pre-paid fees pertaining to Services that will not be provided as a result of the termination.
