Work Change Directives. 12.4.1 A Work Change Directive is a written order prepared and signed by Design-Builder directing a change in the Work prior to agreement on an adjustment in the Contract Price and/or the times for completion of the Work.
12.4.2 Design-Builder and Design-Build Subcontractor shall negotiate in good faith and as expeditiously as possible the appropriate adjustments for the Work Change Directive. Upon reaching an agreement, the parties shall prepare and execute an appropriate Change Order reflecting the terms of the agreement.
Work Change Directives. 7.2.1 A Work Change Directive cannot change GMP or Contract Time, but is evidence that the Parties agree that a change, ordered by directive, will be incorporated in a subsequently issued Change Order as to its effect, if any, on a CGMP, the GMP, or Contract Time.
7.2.2 Failure by XXXX to commence work identified in a Work Change Directive within the time specified by Director, or to complete the work in a reasonable period of time, may be determined by Director to be a material breach of this Contract.
7.2.3 A Work Change Directive is used in the absence of total agreement of the terms of a Change Order. Interim payments are made in accordance with Article 9. XXXX may include a request for payment for undisputed Work under a Work Change Directive with Applications for Payment submitted in accordance with the Contract Documents.
7.2.4 If XXXX signs a Work Change Directive, then XXXX agrees to its terms including adjustment in a CGMP or the GMP (as applicable) and Contract Time or method for determining them. Contract by the Parties to adjustments in a CGMP or the GMP (as applicable) and Contract Time shall be recorded as a Change Order.
7.2.5 Director, by Work Change Directive, may direct XXXX to take measures as necessary to expedite construction to achieve Date of Substantial Completion on or before expiration of Contract Time. When the Work is expedited solely for convenience of the City and not due to XXXX’x failure to prosecute timely completion of the Work, then XXXX is entitled to an adjustment in the GMP equal to actual costs determined in accordance with Article 7.
Work Change Directives. Issue Work Change Directives (WCD), as required, to authorize change or extra Work to proceed on a time and material basis when Change Proposal Request finalization is not expedient or possible. Observe Time and Material (T&M) work and reconcile T&M costs with Contractor on a daily basis. Finalize WCD's when associated work is completed in an appropriate Change Order.
Work Change Directives. Due to the fast track nature of this project, the City authorizes H&S to issue work change directives after review with the City. A work change directive will be a written directive to the contractor issued after contract execution, signed by the City and recommended by H&S ordering an addition, deletion or revision in the work. A work change directive will not change the Contract price or time, but is evident that the parties expect that the change directed or documented by a work change directive will be incorporated into a subsequently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price or Contract Time. Issue work change directives only when necessary to avoid potential project delivery delays associated with the time needed to negotiate and process change orders.
5.5 Shop Drawings
5.6 Pay Requests
Work Change Directives. 6.2.1 Owner has the right to order changes in the Work at any time within the general scope of the Contract. A Work Change Directive is a written order prepared and signed by Owner, directing a change in the Work prior to agreement on an adjustment in the Contract Price and/or the Contract Time(s).
6.2.2 Owner and Xxxxxx Mechanical shall negotiate in good faith and as expeditiously as possible the appropriate adjustments for the Work Change Directive. Upon reaching an agreement, the parties shall prepare and execute an appropriate Change Order reflecting the terms of the agreement.
6.2.3 If the change, in Xxxxxx Mechanical’s judgment, would have a detrimental impact on performance of the Plant, or if the amount of the cost of the change order in dispute exceeds 1% of the Contract Sum, then Xxxxxx Mechanical shall have no obligation to proceed with any change until such agreement is reached. Furthermore, Xxxxxx Mechanical shall in no case be required to agree to any change requiring the handling of PCBs, asbestos or any other hazardous material.
Work Change Directives. 14.3.1 Owner may issue a written Work Change Directive directing a change in the Work prior to reaching agreement with the Contractor on the adjustment, if any, in the estimated Cost of the Work, the Project schedule, and if appropriate, the compensation for design phase services.
14.3.2 Owner and Contractor shall negotiate expeditiously and in good faith for appropriate adjustments, as applicable, to the Cost of the Work, the Project schedule, and if appropriate the compensation for design phase services, arising out of Work Change Directives.
14.3.3 If Owner and Contractor agree upon the adjustments in the estimated Cost of the Work, the Project schedule, and if appropriate the compensation for design phase services, for a change in the Work directed by a Work Change Directive, such agreement shall be the subject of an appropriate Change Order. The Change Order shall include all outstanding Change Directives issued since the last Change Order.
Work Change Directives. 3.5.1 A Work Change Directive cannot change Contract Price or Contract Time, but is evidence that the Parties agree that a change, ordered by directive, will be incorporated in a subsequently issued amended Work Order as to its effect, if any, on Contract Price or Contract Time.
3.5.2 Failure by Contractor to commence work identified in a Work Change Directive within the time specified by Director, or to complete the work in a reasonable period of time, may be determined by Director to be amaterial breach of the Agreement.
3.5.3 A Work Change Directive is used in the absence of total agreement of the terms of an amended Work Order.
3.5.4 If Contractor signs a Work Change Directive, then Contractor agrees to its terms including adjustment in Contract Price and Contract Time or method for determining them. Agreement by the Parties to adjustments in Contract Price and Contract Time are immediately recorded as an amended Work Order.
3.5.5 Director, by Work Change Directive, may direct Contractor to take measures as necessary to expedite construction to achieve Date of Substantial Completion on or before expiration of Contract Time. When the Work is expedited solely for convenience of the City and not due to Contractor’s failure to prosecute timely completion of the Work, then Contractor is entitled to an adjustment in Contract Price equal to actual costs determined in accordance with Section 3.6 of Exhibit “A”.
3.5.6 Whenever Contractor receives a Work Change Directive or amended Work Order, Contractor shall furnish all material, equipment, and personnel necessary to perform the work described by the Work Change Director or amended Work Order, as applicable. Contractor shall complete the Work within the time prescribed. If no time is prescribed, Contractor shall complete the Work within a reasonable time. If the Workdescribed by any amended Work Order causes an unavoidable delay in any other Work Contractor is required to perform under this Agreement, Contractor may require a time extension for the completion of the Work. The Director’s decision regarding time is final.
3.5.7 A product or service provided under a Work Change Directive or amended Work Order is subject to inspection, acceptance, or rejection the same manner as the Work described in the Agreement and is subject to the terms of the Agreement as if it had been originally included in the Agreement.
3.5.8 A Work Change Directive and amended Work Order is subject to Section
Work Change Directives. 7.2.1 A Work Change Directive cannot change the Guaranteed Maximum Price or Contract Time, but is evidence that the Parties agree that a change, ordered by directive, will be incorporated in a subsequently issued Change Order as to its effect, if any, on the Guaranteed Maximum Price or the Contract Time.
7.2.2 Failure by Design Build Contractor to commence work identified in a Work Change Directive within the time specified by City Engineer, or to complete the work in a reasonable period of time, may be determined by City Engineer to be a material breach of the Contract.
7.2.3 A Work Change Directive is used in the absence of total agreement of the terms of a Change Order. Interim payments are made in accordance with Article 9. Design Build Contractor may include a request for payment for undisputed Work under a Work Change Directive with Applications for Payment submitted in accordance with the Contract Documents.
7.2.4 If Design Build Contractor signs a Work Change Directive, then Design Build Contractor agrees to its terms including adjustment in the Guaranteed Maximum Price and Contract Time or method for determining them. Agreement by the Parties to adjustments in the Guaranteed Maximum Price or Contract Time shall immediately be recorded as a Change Order.
7.3.1.1 mutual acceptance of pricing, properly itemized and supported by sufficient data to permit evaluation in which to determine an adjustment to the GMP;
7.3.1.2 unit prices stated in the Contract or subsequently agreed upon;
7.3.1.3 cost to be determined in a manner agreed upon by the Parties and mutually acceptable fixed or percentage fee; or
7.3.1.4 as provided in Paragraph 7.3.2.
Work Change Directives. 7.2.1 A Work Change Directive cannot change the Guaranteed Maximum Price or Contract Time, but is evidence that the Parties agree that a change, ordered by directive, will be incorporated in a subsequently issued Change Order as to its effect, if any, on the Guaranteed Maximum Price or the Contract Time.
7.2.2 Failure by Design Build Contractor to commence work identified in a Work Change Directive within the time specified by Director, or to complete the work in a reasonable period of time, may be determined by Director to be a material breach of the Contract.
7.2.3 A Work Change Directive is used in the absence of total agreement of the terms of a Change Order. Interim payments are made in accordance with Article 9. Design Build Contractor may include a request for payment for undisputed Work under a Work Change Directive with Applications for Payment submitted in accordance with the Contract Documents.
7.2.4 If Design Build Contractor signs a Work Change Directive, then Design Build Contractor agrees to its terms including adjustment in the GMP and Contract Time or method for determining them. Agreement by the Parties to adjustments in the GMP and Contract Time shall be recorded as a Change Order.
7.2.5 Director, by Work Change Directive, may direct Design Build Contractor to take measures as necessary to expedite construction to achieve Date of Substantial Completion on or before expiration of Contract Time. When the Work is expedited solely for convenience of the City and not due to Design Build Contractor’s failure to prosecute timely completion of the Work, then Design Build Contractor is entitled to an adjustment in the GMP equal to actual costs determined in accordance with Article 7.
Work Change Directives. 8.2.1 The Owner may issue a written Work Change Directive directing a change in the Work prior to reaching agreement with the Design-Builder on the adjustment, if any, in the Contract Price and/or the Date of Substantial Completion and/or the Date of Final Completion, and if appropriate, the compensation for Design Services.
8.2.2 The Owner and the Design-Builder shall negotiate expeditiously and in good faith for appropriate adjustments, as applicable, to the Contract Price and/or the Date of Substantial Completion and/or the Date of Final Completion. and if appropriate the compensation for Design Services, arising out of Work Change Directives. As the changed work is completed, the Design Builder shall submit its costs for such work with its Application for Payment beginning with the next Application for Payment within thirty (30) days of the issuance of the Work Change Directive. Pending final determination of cost to the Owner, amounts not in dispute may be included in Applications for Payment and shall be paid by Owner.
8.2.3 If the Owner and the Design-Builder agree upon the adjustments in the Contract Price and/or the Date of Substantial Completion and/or the Date of Final Completion, and if appropriate the compensation for Design Services, for a change in the Work directed by a Work Change Directive, such agreement shall be the subject of an appropriate Change Order. The Change Order shall include all outstanding Change Directives issued since the last Change Order.
