Field Change Order definition

Field Change Order is a written change order requested by the AE, accepted by the CM, and approved by the Project Coordinator for minor changes in the Work, not involving the adjustments in the Guaranteed Maximum Price or an extension of Time, and not inconsistent with the overall intent of the Contract Documents.
Sample 1Sample 2Sample 3
Field Change Order means a written instrument issued by Company to Contractor after the execution of this Contract ordering (1) a change in the Work, (2) an adjustment in the Contract Sum, or (3) an adjustment in the Contract Time.
Sample 1Sample 2
Field Change Order is a document which outlines the scope of a requested change in the Work as defined by the Shell and Core Plans and Tenant Plans and bears the signature of Tenant and Landlord representatives approving such change in scope. All such plans, specifications, and Field Change Orders shall be approved by Landlord and Tenant prior to being executed or acted upon by the Landlord's or Tenant's Contractors. Landlord and Tenant shall be given 24 hours to respond without causing a Landlord or Tenant Delay unless otherwise specified in said Field Change Order. In the event the Field Change Order increases the cost of the Shell and Core or Tenant Work beyond the maximum Tenant Work Allowance, Tenant shall pay for the work per the terms of this Exhibit and the Lease. As for Tenant Work, Tenant shall pay its Contractor per the terms of the construction contract between the Tenant and its Contractor. EXHIBIT D TO OFFICE LEASE AGREEMENT 000 XXXXXXX XXXXXX WEST BUILDING OFFICE TENANT BUILDING SHELL AND CORE OUTLINE SPECIFICATIONS The Building Outline Specifications which follow are intended to establish the scope and quality of finishes, materials and systems to be furnished by Landlord for the construction of the basic Building Shell and Core, as well as the parking structure and landscaped surface parking areas (together referred therein as the "Shell and Core"). The Building Outline Specifications are intended to govern the development of the building drawings through the completion of the final building working drawings and specifications ("The Contract Documents"). Capitalized terms used and not defined shall have the meanings given them in the Lease. Landlord is committed to developing a long-term investment quality product, which has lasting quality and landmark stature and will be considered in all respects a first class office building development. This Outline Specification may be amended, through mutual consent of the parties, during the completion of the design development and construction document phases of the design of the buildings. The cost of all maintenance following initial installation shall be as provided under the Lease. FOUNDATION SYSTEM 1. The foundation system shall be designed based upon good engineering practice, soils bearing analysis from a geotechnical engineer and structural load calculations. For Typical floor load capacities for all office floors, see Superstructure System below, including all exceptions.
Sample 1

Examples of Field Change Order in a sentence

  • If the amount of the adjustment of the Contract price and time for completion can be determined at the time of issuance of the Emergency Field Change Order, those adjustments shall be reflected on the face of the Emergency Field Change Order.

  • Such changes in the Work may be directed through issuance of an Emergency Field Change Order signed by the Contractor, the Principal Representative (or by a designee specifically appointed to do so in writing), and approved by the Director of State Buildings Program or his or her delegate.

  • The change shall be directed using an Emergency Field Change Order form (SC-6.31E).

  • The final adjustment of the Emergency Field Change Order amount and the adjustment to the Project time for completion shall be prepared on a normal Change Order from (SC-6.31) in accordance with the procedures described in Article 35A, The Value of Changed Work, and B, Detailed Breakdown, above.

  • If the CONTRACTOR believes that a Field Change Order justifies an increase in the Contract Price or an extension of the Contract Time and the parties are unable to agree as to the amount or extent thereof, the CONTRACTOR may make a claim.

  • These may be accomplished by a Field Change Order and the CONTRACTOR shall perform the Work involved promptly.

  • Otherwise, the Emergency Field Change Order shall reflect a not to exceed (NTE) amount for any schedule adjustment (increasing or decreasing the time for completion) and an NTE amount for any adjustment to Contract sum, which NTE amount shall represent the maximum amount of adjustment to which the Contractor will be entitled, including direct and indirect costs of changed Work, as well as any direct or indirect costs attributable to delays, inefficiencies or other impacts arising out of the change.

  • The term “Emergency Field Change Order” shall mean a written change order for extra Work or a change in the Work necessitated by an emergency as defined in Article 35D executed on State form SC 6.31 and identified as an Emergency Field Change Order.

  • The term “Emergency Field Change Order” shall mean a written change order for extra work or a change in the work necessitated by an emergency as defined in Article 35C executed on State form SC 6.31 and identified as an Emergency Field Change Order.

  • Otherwise, the Emergency Field Change Order shall reflect a not to exceed (NTE) amount for any schedule adjustment (increasing or decreasing the time for completion) and an NTE amount for any adjustment to Contract sum, which NTE amount shall represent the maximum amount of adjustment to which the Contractor will be entitled, including direct and indirect costs of changed work, as well as any direct or indirect costs attributable to delays, inefficiencies or other impacts arising out of the change.


More Definitions of Field Change Order

Field Change Order. ("FCO"), Problem Reporting ("PO") and Service Information ("SI") Program OEM shall maintain a field change order, problem reporting and service information program in accordance with good industry practice. The following procedures are intended as minimum requirements for the program which OEM has in place and for interfacing this program with PMSN's procedures. Changes which affect Form, Fit, Function, or Certification of the Product, or Spare Parts stock may only be implemented after consultation between OEM and PMSN and mutual agreement. 5.1 Form of FCO Field modifications, if any, will be made available to PMSN in the form of modification kits. These kits will contain: - Implementation instructions, including a list of applicable Products and serial numbers - Material and Spare Parts - Special tools (if any) - Service Documentation updates -------- -------- Initials Initials Merge PMSN 5.2 Categories and Implementation of FCO's Three (3) categories will be distinguished:
Sample 1
Field Change Order. (FCO) means technical changes to the hardware, excluding the firmware, aimed at maintaining or enhancing the correct operation of the hardware.
Sample 1
Field Change Order is a document which outlines the scope of a requested change in the Work as defined by the Shell and Core Plans and Tenant Plans and bears the signature of Tenant and Landlord representatives approving such change in scope. All such plans, specifications, and Field Change Orders shall be approved by Landlord and Tenant prior to being executed or acted upon by the Landlord's or Tenant's Contractors. Landlord and Tenant shall be given 24 hours to respond without causing a Landlord or Tenant Delay unless otherwise specified in said Field Change Order. In the event the Field Change Order increases the cost of the Shell and Core or Tenant Work beyond the maximum Tenant Work Allowance, Tenant shall pay for the work per the terms of this Exhibit and the Lease. As for Tenant Work, Tenant shall pay its Contractor per the terms of the construction contract between the Tenant and its Contractor. EXHIBIT G OPTION SPACE PERFORMANCE CRITERION Per Section 33 of the Lease, Tenant has the Option to Expand its Premises into the Building Three Option Space as defined in said Section 33. This Exhibit establishes criterion under which Tenant's Building Three Option Space shall be reduced from a maximum of two full floors to one full floor. Tenant's Building Three Option Space shall be reduced to one (1) full floor (either the first or second floor of Building Three at Landlord's sole discretion) if either one of the following two conditions exist:
Sample 1

Related to Field Change Order

  • Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.

  • Work Order means an individually negotiated document that is executed by both Parties and which authorizes a Project, if any, in an indefinite quantity Contract.

  • Scope of Work means the description of Services and Deliverables specified in the Contract and as may be amended.

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • The Work Order means the order placed by the Purchaser on the Supplier signed by the Purchaser including all attachments and appendices thereto and all documents incorporated by reference therein. The Work order shall be deemed as "Contract" appearing in the document.

  • Statement of Work means the description of activities performed in completing the Project, as specified in the Contract and as may be amended.

  • Change of Scope Order shall have the meaning set forth in Clause 13.2 (iv); “Completion Certificate” shall have the meaning set forth in Clause 12.2; “Construction” shall have the meaning set forth in Clause 1.2 (f);

  • Project Plan means the document to be developed by the Contractor and approved by WTL, based on the requirements of the Contract and the Preliminary Project Plan included in the Contractor’s bid. For the sake of clarity, the Agreed and Finalized Project Plan” refers to the version of the Project Plan submitted by the contractor after receiving the letter of Award and the same approved by WTL. The project plan may be changed/ modified during the course of the project. Should the Project Plan conflict with the provisions of the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Product Specification means the document referred to in:

  • Construction Change Directive means a written order prepared by Owner Parties and signed by Owner directing Contractor to perform a change in the Work prior to agreeing to a change, if any, to the Contract Time, schedule of performance of the Work, Contract Sum, or Contractor’s compensation.