Changes and Adjustments. XXXXX may at any time, by written order (and without notice to sureties), make changes within the general scope of any purchase order in any one or more of the following: (i) drawings, designs, specifications or other technical documents; (ii) quantity, (iii) time and place of delivery; and (iv) delivery schedules. Without limiting the foregoing, XXXXX may at any time and from time to time modify its Shipping Packing, and Marking Instructions or the Invoicing Instructions contained above by delivery of a revised version thereof to Supplier. Supplier will implement any such changes; provided, that if any such change causes an increase or decrease in the cost of or time required for performance of any work under a purchase order, an appropriate adjustment in the price and/or delivery schedule will be agreed to by XXXXX and Supplier. Notwithstanding the foregoing, no adjustment to the benefit of Supplier will be made: (a) for any change to delivery schedule when delivery is rescheduled within twelve (12) months of the originally scheduled delivery date; or (b) for any change made necessary by reason of defects or nonconformities for which Supplier would be liable under the terms of the order and these Terms and Conditions or otherwise; or (c) for any change to delivery schedule if the amended delivery schedule is commensurate with any delivery schedule changes received by XXXXX from its customer. Any claim by Supplier for adjustment will be made in writing within twenty (20) days from the date the change was ordered by XXXXX, and will set forth the amount claimed and the reasons therefore. Upon prior written request and subject to XXXXX maintaining the confidentiality thereof, Supplier will make available its books and records for XXXXX'x examination to allow XXXXX, its authorized representatives and its customers (including the government if this is a government contract) to verify any claim for adjustment by Supplier. If XXXXX and Supplier are unable to agree upon an adjustment in the event of any change directed by XXXXX, the matter will be resolved in accordance with the dispute resolution procedures set forth in the Paragraph of these Terms and Conditions entitled “Dispute Resolution.” Pending resolution of any such adjustment, Supplier will diligently pursue the performance of the order as changed. Notwithstanding the above, if XXXXX enters into an agreement with a customer, which provides for no cost increase as a result of changes to delivery or work ...
Changes and Adjustments. 9.1. Change Information 9.2. Reductions 9.3. Increases 9.4. Reinstatements 9.5. Conversions 9.6. Underwriting Reassessment 9.7. Terminations 9.8. Policy Replacement 9.9. Cash Values
Changes and Adjustments. Canadian ISD reserves the ability to make changes to the instructional transportation schedule and the school activity transportation schedule and pick up and drop off locations as needed to accommodate students, activities, construction and weather.
Changes and Adjustments. As to the Court and Community School Route, FCSS reserves the right to change school hours; adjust school start and ending times; change any aspect of or delete any established route(s); add new routes; change, increase, or decrease the number and type of vehicles required; change any school site to which transportation services will be provided; and/or change the number of or particular students assigned to a vehicle or route.
Changes and Adjustments. The Licensee is entitled to make such changes and adjustments to the Licensee’s copies as are supported by the Software and as are necessary in order for the Software to be used for its intended purpose. However, the Licensee should take notice that any changes/adjustments to the Software not performed by DATALOGISK will possibly waive DATALOGISK’s liability in full or in part, and any changes/adjustments may cause problems, e.g. in the form of lost functionality, particu- larly in relation to future updates, etc. from DATALOGISK.
Changes and Adjustments. 4.3.1 Except to the extent otherwise expressly provided herein or agreed in writing, the Architect agrees that the City may assume that all services are Basic Services unless the City expressly requests Additional Services in a writing expressly acknowledging that the requested services are Additional Services or the Architect notifies the City in writing and in advance that an Additional Service is required by the Architect or an Architect’s Consultant, or has been requested by the City, and the City then agrees in writing and expressly authorizes the performance of the Additional Service.
Changes and Adjustments. As a result of meetings and discussions between the parties, including, without limitation, meetings conducted by the parties pursuant to Section 2.3, the parties may desire to make changes to existing Project Agreements including, without limitation, changes to the number of Transmeta Personnel, the scope or specification of Services then being performed under such Project Agreements. Changes to the scope or specification of such Services may also require changes to the schedule for the performance of Services or adjustments to the fees payable for such Services or may require Transmeta to hire or engage additional Transmeta Personnel, all as may be appropriately determined between the parties. Any proposed changes to a Project Agreement will be effective only if such changes are confirmed in writing and signed by the Executive Relationship Manager and relevant Project Manager(s) of each party. Notwithstanding the foregoing provisions, if SONY provides Transmeta with * * * prior written notice and discusses with Transmeta new projection of the headcount of Transmeta Personnel, SONY may reduce headcount of the Transmeta Personnel set forth in any Project Agreement on its discretion.
Changes and Adjustments. 4.10.1 No deductions shall be made from amounts payable to the Architect on account of penalty, liquidated damages, or other sums withheld from payments to Contractors, or on account of the cost of changes in the Work other than those for which the Architect is proven to be legally responsible or has agreed to pay.
Changes and Adjustments
