Commencement of Improvements Sample Clauses

Commencement of Improvements. Prior to or on the date FRANCHISEE signs a lease with respect to the Center Site or the date of commencement of the improvements or construction of the Center Site, whichever is earlier, FRANCHISEE shall pay to FRANCHISOR the sum of Twenty-Five Thousand Dollars ($25,000) (or Twelve Thousand Five Hundred Dollars ($12,500) in the case of additional franchises). After such payment by FRANCHISEE, such portion of the Initial Franchise Fee shall not be refundable.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Commencement of Improvements. The Developer shall commence construction of the Improvements no later than the date set forth in the Development Schedule.
Sample 1
Commencement of Improvements. The City shall issue a Notice to Proceed for each phase of the Subdivision upon satisfaction of the following conditions for each phase of the Subdivision: A. The City Engineer has reviewed and approved the Plans for the Improvements for such phase and Developer’s engineer has certified those Plans; B. The City has received the Financial Guaranty for the Improvements for such phase; C. The City has received evidence that the applicable Plat for such phase of the Subdivision has been recorded with Scott County; D. The City has received a certificate of insurance naming the City as an additional insured and satisfying the insurance requirements set forth below. E. Developer has conducted a preconstruction meeting and submitted an accurate construction schedule for such phase in form and at a level of detail acceptable to the City; F. Sewer Area Capital Charge, Water Area Capital Charge and Storm Water Management Area / Capital Charge for such phase have been paid; and G. Developer has completed (i) all required environmental review and documentation steps identified during the EAW process, including Phase 1 archeological study meeting OSA and SHPO standards, and (ii) a survey and work efforts to satisfy the DNR requirements for evaluating and avoiding habitat for the Henslow’s Sparrow. Developer’s subsequent operations must comply with the findings and associated agency requirements of said findings.
Sample 1Sample 2
Commencement of Improvements. The Owner and/or Builder shall not commence work on any construction project or improvement, including clearing or excavation, without first obtaining written approval from the VRPOA-ACC. A violation of this rule shall be an immediate default of the Rules for Construction and Owner and Builder shall be subject to applicable penalties, including but not limited to, fines, rescission of VRPOA-ACC approval, injunctive relief, suspension of Owner's rights, and enforcement of penalties as set forth herein, subject to the limitations of the Texas Property Code. In the event any Owner, Builder or third party commences construction of an improvement prior to obtaining written approval from the VRPOA-ACC, the party shall cease and desist from the continuation of making improvements upon receipt of notice from the VRPOA-ACC. The VRPOA-ACC shall have forty-five (45) business days (fifteen [15] days with respect to construction performed by an Approved Builder) from receipt of the last of any required documentation, submitted after commencement of construction, alteration or exterior changes to respond by approval, disapproval or modification requirements. The VRPOA, acting by and through the VRPOA-ACC or a designated agent of the VRPOA shall have the right to enter upon any lot to inspect all work in progress to ensure compliance with approved plans and specifications and to obtain restraining orders and/or temporary or permanent injunctions to terminate or halt construction, alterations or exterior changes which have not been reviewed and approved in writing by the VRPOA-ACC in accordance herewith. The VRPOA-ACC shall have full and complete authority to approve any construction of any improvement on any Lot and its judgment shall be final and conclusive.
Sample 1Sample 2
Commencement of Improvements. Except as set forth on Exhibit C, prior to the recordation of the Security Instrument, no work of any kind has been or will be commenced or performed upon the Property and no materials or equipment have been or will be delivered to or upon the Property. In the event that any work of any kind has been commenced or performed upon the Property, or in the event that any materials or equipment have been ordered or delivered to or upon the Property, then (i) prior to the execution of the Security Instrument, Borrower shall fully disclose in writing to the title insurance company issuing the mortgagee title insurance policy insuring the lien of the Security Instrument that work has been commenced or performed on the Property, or materials or equipment have been ordered or delivered to or upon the Property, (ii) prior to the execution of the Security Instrument, Borrower shall have obtained and delivered to Xxxxxxx Mac and the title company issuing the mortgagee title insurance policy insuring the lien of the Security Instrument lien waivers from all contractors, subcontractors, suppliers, or any other applicable party, pertaining to all work commenced or performed on the Property, or materials or equipment ordered or delivered to or upon the Property, and (iii) the final mortgagee’s title insurance policy insuring the lien of the Security Instrument shall take no exception from coverage for any mechanics or materialmen’s liens.
Sample 1
Commencement of Improvements. Within the Plat or Property to be platted, the Developer may not commence Improvements, other than any grading permitted under Section 4.3 of the City Code, until all the following conditions have been satisfied: A) The necessary Financial Guaranty has been received and accepted by the City. B) The City has received evidence that the Plat has been filed with Dakota County. C) The City has issued a Permit to Proceed.
Sample 1
Commencement of Improvements. The City shall issue the Notice to Proceed within fourteen (14) days of satisfaction of the following conditions: (a) The City Engineer has reviewed and approved the Plans and Developer’s engineer has certified those Plans; (b) The City has received the Financial Guaranty for the Improvements; (c) The City has received evidence that the applicable Plat has been recorded with Scott County; (d) The City has received a certificate of insurance naming the City as an additional insured and satisfying the insurance requirements set forth in Section III; (e) Developer has conducted a preconstruction meeting and submitted an accurate construction schedule (the “Construction Schedule”) of acceptable form and level of detail to the City, and submitted to the City the list required by Section 5.2; (f) SAC, WAC and storm sewer charges have been paid pursuant to Section 5.14; and (g) Any and all mortgagees have provided the City with release of the Pineview Park and Cedarview Park in a form satisfactory to the City. Developer may not commence the Improvements, other than any grading permitted under Chapter 150 of the City Code, until the Notice to Proceed has been issued by the City. Developer will furnish the City Engineer with an updated Construction Schedule if any significant changes occur to the schedule of proposed operations and construction. If grading by Xxxxxxxxx has been started prior to the issuance of the Notice to Proceed, Xxxxxxxxx agrees to make any corrections to the grading performed and Plans, at Developer’s expense, after the City Engineer has reviewed the Plans.
Sample 1
AutoNDA by SimpleDocs
Commencement of Improvements. No improvements of any kind shall be commenced on the real property until authorized by the title company, including, but not limited to, the placing of materials upon said real property.
Sample 1

Related to Commencement of Improvements

  • Initial Improvements Subtenant may, at its option and subject to the provisions of the Prime Lease, including, without limitation, Article 8 thereof, complete certain initial improvements to prepare the Demised Premises for Subtenant’s occupancy thereof as described in the Work Letter Agreement attached hereto and made a part hereof as Exhibit B (the “Initial Improvements”), at Subtenant’s sole cost and expense without any contribution or improvement allowance from Sublandlord described in the Work Letter Agreement attached hereto and made a part hereof as Exhibit B); provided, however, Subtenant shall not make or permit anyone to make any Initial Improvements without the prior written consent of Sublandlord, which shall not be unreasonably withheld or delayed, and of Prime Landlord in accordance with the Prime Lease. In connection with the foregoing, Subtenant shall submit to Sublandlord, for prior written approval by Sublandlord, which shall not be unreasonably withheld or delayed, and Prime Landlord, complete plans and specifications for any and all Initial Improvements; including, without limitation, schematic designs and work drawings. Any and all costs and expenses associated with the acquisition of cabling, equipment, furniture, security systems, or other personal property for Subtenant or the Demised Premises or the installation or placement of any of the foregoing within the Demised Premises or with the project management for the performance of the Initial Improvements (collectively, “Subtenant’s Personal Property and Services”), shall be paid for by and be the sole responsibility of Subtenant. Sublandlord acknowledges and agrees that Subtenant shall not be required to remove any Initial Improvements upon the expiration or earlier termination of this Sublease unless the removal is required by Prime Landlord or Sublandlord is otherwise obligated to pay Prime Landlord the costs of any removal of any Initial Improvements pursuant to Section 8(e) of the Prime Lease.

  • Tenant's Improvements If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.

  • Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.

  • Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements. (b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.

  • Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • Lessee Improvements Lessee shall prepare final plans and ------------------- specifications for construction of the Lessee Improvements desired by Lessee and shall deliver to Lessor by July 1, 1999, two (2) copies of such plans and specifications and the names of two proposed contractors to construct the Lessee Improvements for Lessor approval. Lessor will promptly either approve of the plans and specifications and the contractors, or communicate its objections, and if Lessor has objections, the Lessor will work diligently with Lessee to resolve any objections such that approval of the plans and specifications and names of contractors is given within fifteen (15) days of receipt. Lessor shall be deemed to have approved the plans and specifications and the contractors unless Lessor shall have provided written notice to Lessee of Lessor's objections thereto within fourteen (14) days following the delivery thereof by Lessee to Lessor. The Lessor approved final plans and specifications for the Lessee Improvements are herein called the "Lessee Improvements Final Plans and Specifications". All reasonable costs involved in approving, drafting and preparing the Lessee Improvements Final Plans and Specifications shall be charged against the Improvement Allowance described below. Lessor shall apply for building permits to construct the Lessee Improvements and will submit bid requests to the two contractors selected by Lessee and the contractor for the Shell Building Improvements no later than two (2) days following approval of the Lessee Improvements Final Plans and Specifications. Contractors will be required to submit their bids no later than thirty (30) days following receipt of the bid request. Lessee shall have fifteen (15) days from receipt of all bids to select the contractor for the Lessee Improvements. Except for immaterial field changes, modifications to the Lessee Improvements Final Plans and Specifications must be made and accepted only by written change order or agreement signed by Lessor and Lessee and will constitute an amendment to this Lease. Lessee shall be responsible for payment in advance of all work and construction resulting from changes in the Lessee Improvements Final Plans and Specifications requested by Lessee if the additional cost attributable to the changes exceed the Improvement Allowance by more than $3.00 as described in subparagraph (c) below. The Lessee Improvements Final Plans and Specifications (when approved by Lessor and Lessee) are incorporated in this Lease by reference. For the purpose of this Section, an "immaterial field change" shall mean such field changes which are required by any governmental authority or changes which (i) do not affect the size, configuration, structural integrity, quality, character, architectural appearance and standard of workmanship contemplated in the Lessee Improvements Final Plans and Specifications, (ii) will not result in any default in any obligation to any person or violation of any governmental requirements, and (iii) the cost of or reduction resulting from any single field change or extra does not exceed $5,000.00.

  • Completion of Improvements Within 90 days of completion of any construction herein permitted, Company will cause to be prepared and delivered to Authority record documents as required under the Tenant Work Permit process, including but not limited to as-builts, legal descriptions, boundary surveys, and certified final cost of construction. The submission of record document electronic media will be in accordance with Authority’s Standard Procedure for computer aided design and drafting and drawings, as may be revised from time to time.

  • Needs Improvement the Educator’s performance on a standard or overall is below the requirements of a standard or overall, but is not considered to be unsatisfactory at this time. Improvement is necessary and expected.

  • Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.

  • Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!