COVID-19 Safety Measures Sample Clauses

COVID-19 Safety Measures. During the term of the Contract, when any work is performed at the work site, the safety measures and protocols set forth in this Subsection must be followed for the protection of Contractor’s employees and/or subcontractors, City employees, and the public. In the event that Contractor is required to evacuate the building or stop or delay work due to a COVID-19 related event, Contractor shall not be entitled to any additional payment, remobilization costs, or delay damages. 14.27.1. Contractor must submit a construction schedule for approval by the City’s Project Manager. 14.27.2. The City’s Project Manager may change the approved schedule immediately in the event needed for assurance of health and safety. 14.27.3. Contractor must meet the City’s Project Manager outside of the building or project area (if outdoors) where work is to take place and be prepared to be escorted to the work site.
Sample 1Sample 2
AutoNDA by SimpleDocs
COVID-19 Safety Measures. Contractor must have a written policy in place to comply with all applicable local, state, and federal laws, regulations, and executive orders related to the COVID-19 coronavirus outbreak to ensure the protection of Contractor’s employees and/or subcontractors, City employees, and the public. Contractor must provide its written policy to the City Project Manager at the commencement of the Project. In the event that Contractor is required to stop or delay work due to a COVID-19 related event, Contractor shall not be entitled to any additional payment, remobilization costs, or delay damages.
Sample 1
COVID-19 Safety Measures. Consultant must have a written policy in place to comply with all applicable local, state, and federal laws, regulations, and executive orders related to the COVID-19 coronavirus outbreak to ensure the protection of Consultant’s employees and/or subconsultants, City employees, and the public. Consultant must provide its written policy to the City Project Manager at the commencement of the Project. In the event that Consultant is required to stop or delay work due to a COVID-19 related event, Consultant shall not be entitled to any additional payment, remobilization costs, or delay damages.
Sample 1Sample 2
COVID-19 Safety Measures. The Contractor may be required to comply with the implementation of safety measures based on current circumstance and safety needs as defined by CDC and/or the Virginia Dept. of Health (VDH) and any future updates. These measures may include safe interactions with minimal or contactless procedures including: 1. Required face coverings and gloves when social distancing guidelines cannot be followed. Required personal protective equipment (PPE) will be provided by the Contractor. 2. Minimal contact or contactless check-in procedures when Contractors reports to the Designated VDOT Location and signs in. 3. Minimal contact or contactless equipment verification procedures for preseason equipment acceptance. 4. Minimal contact or contactless invoice processing and approval for payments of winter operations invoices. 5. Additional measures as defined by CDC and or the Virginia Dept. of Health.
Sample 1Sample 2
COVID-19 Safety Measures a. Consultant shall comply with all applicable current and future federal, state, and local laws, regulations, statutes, ordinances, and orders. This includes, but is not limited to, applicable portions of the County of San Diego Health Officer’s order that became effective on July 30, 2020, and any future updates thereto. xxxxx://xxx.xxxxxxxxxxxxxx.xxx/content/dam/sdc/hhsa/programs/phs/Epidem iology/HealthOfficerOrderCOVID19.pdf. b. Consultant shall implement, and require its subconsultants to implement, measures to protect employees, visitors, and anyone else related to the Project from COVID-19 and other infectious diseases. These measures shall include, but not be limited to, the following: Post all required notices at the worksite; update its Injury and Illness Prevention Plan, generate a worksite-specific COVID-19 prevention plan, designate a person at each worksite to implement the plans, provide training on preventing the spread of diseases, increase availability of handwashing stations, routinely disinfect common areas, enforce physical distancing, require cloth face coverings or PPE when otherwise required, encourage workers who are sick to stay at home, provide alcohol based wipes to clean tools before and after use, avoid carpooling, implement health screening programs (temperature checks and symptom screening) to ensure that employees showing up to work are healthy, and immediately separate employees with symptoms of COVID-19 from others and direct them to go home or to medical care as needed. In its implementation of COVID-19-related safety measures, Consultant shall be aware of and take into account the following guidance: i. California Department of Public Health, COVID-19 Industry Guidance: Construction, xxxxx://xxxxx00.xx.xxx/pdf/guidance- construction.pdf ii. Cal/OSHA, Interim General Guidelines on Protecting Workers from COVID-19, xxxxx://xxx.xxx.xx.xxx/dosh/coronavirus/General- Industry.html iii. Cal/OSHA, COVID-19 Infection Prevention in Construction, xxxxx://xxx.xxx.xx.xxx/dosh/coronavirus/COVID-19-Infection- Prevention-in-Construction.pdf iv. OSHA, Guidance on Preparing Workplaces for COVID-19 (OSHA 3990-03), xxxxx://xxx.xxxx.xxx/Publications/OSHA3990.pdf v. OSHA, COVID-19 Guidance for the Construction Workforce (OSHA 4000-04), xxxxx://xxx.xxxx.xxx/Publications/OSHA4000.pdf vi. OSHA, COVID-19 - Control and Prevention / Construction Work, xxxxx://xxx.xxxx.xxx/SLTC/covid-19/construction.html vii. Interim Guidance for Businesses and Em...
Sample 1
COVID-19 Safety Measures. During the Pandemic we will continue to follow best practices as directed by Public Health, recognizing that the specific directives may change over the course of the pandemic. Current practices include physical distancing as possible, the use of a plexi glass barrier during the assessment when masks are not worn by the student or the assessor, the use of hand sanitizers at the beginning of the assessment, and the sanitization of common areas before and after each session with the student. Please contact the Psychologist if you have specific questions or concerns about the safety measures being followed.
Sample 1
COVID-19 Safety Measures. Auditor must have a written policy in place to comply with all applicable local, state, and federal laws, regulations, and executive orders related to the COVID-19 coronavirus outbreak to ensure the protection of Auditor’s employees, City employees, and the public. Auditor must provide its written policy to the City Project Manager at the commencement of the Project. In the event that Auditor is required to stop or delay work due to a COVID-19 related event, Auditor shall not be entitled to any additional payment, remobilization costs, or delay damages.
Sample 1
AutoNDA by SimpleDocs

Related to COVID-19 Safety Measures

  • Safety Measures Awarded vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Awarded vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage.

  • Emergency Measures Additional measures and/or other special requirements necessary during periods of critical fire-weather conditions shall be included in the fire prevention and presuppression plan.

  • Interim Measures Notwithstanding any requirements for alternative dispute resolution procedures as set forth in Articles 18(B), any party to the Dispute may apply to a court for interim measures (i) prior to the constitution of the arbitral tribunal (and thereafter as necessary to enforce the arbitral tribunal’s rulings); or (ii) in the absence of the jurisdiction of the arbitral tribunal to rule on interim measures in a given jurisdiction. The Parties agree that seeking and obtaining such interim measures shall not waive the right to arbitration. The arbitrators (or in an emergency the presiding arbitrator acting alone in the event one or more of the other arbitrators is unable to be involved in a timely fashion) may grant interim measures including injunctions, attachments and conservation orders in appropriate circumstances, which measures may be immediately enforced by court order. Hearings on requests for interim measures may be held in person, by telephone, by video conference or by other means that permit the parties to the Dispute to present evidence and arguments.

  • Remedial Measures Upon becoming aware of an alleged security breach, Contractor’s Contract Manager must set up a conference call with the Department’s and the Customer’s Contract Manager. The conference call invitation must contain a brief description of the nature of the event. When possible, a thirty (30)- minute notice will be given to allow Department personnel to be available for the call. If the designated time is not practical for the Customer, an alternate time for the call will be scheduled. Contractor must share all available information on the call. The Contractor must answer all questions based on the information known at that time and answer additional questions as additional information becomes known. The Contractor must provide the Department and Customer with final documentation of the incident including all actions that took place. If the Contractor becomes aware of a security breach or security incident outside of normal business hours, the Contractor must notify the Department’s and the Customer’s Contract Manager and in all events, within one business day.

  • Corrective Measures If the Participating Generator fails to meet or maintain the requirements set forth in this Agreement and/or the CAISO Tariff, the CAISO shall be permitted to take any of the measures, contained or referenced in the CAISO Tariff, which the CAISO deems to be necessary to correct the situation.

  • Bilateral Safeguard Measures 1. Where, as a result of the reduction or elimination of a customs duty under this Agreement, any product originating in a Party is being imported into the territory of another Party in such increased quantities, in absolute terms or relative to domestic production, and under such conditions as to constitute a substantial cause of serious injury or threat thereof to the domestic industry of like or directly competitive products in the territory of the importing Party, the importing Party may take bilateral safeguard measures to the minimum extent necessary to remedy or prevent the injury, subject to the provisions of paragraphs 2 to 10. 2. Bilateral safeguard measures shall only be taken upon clear evidence that increased imports have caused or are threatening to cause serious injury pursuant to an investigation in accordance with the procedures laid down in the WTO Agreement on Safeguards. 3. The Party intending to take a bilateral safeguard measure under this Article shall immediately, and in any case before taking a measure, make notification to the other Parties and the Joint Committee. The notification shall contain all pertinent information, which shall include evidence of serious injury or threat thereof caused by increased imports, a precise description of the product involved and the proposed measure, as well as the proposed date of introduction, expected duration and timetable for the progressive removal of the measure. A Party that may be affected by the measure shall be offered compensation in the form of substantially equivalent trade liberalisation in relation to the imports from any such Party. 4. If the conditions set out in paragraph 1 are met, the importing Party may take measures consisting in increasing the rate of customs duty for the product to a level not to exceed the lesser of: (a) the MFN rate of duty applied at the time the action is taken; or (b) the MFN rate of duty applied on the day immediately preceding the date of the entry into force of this Agreement. 5. Bilateral safeguard measures shall be taken for a period not exceeding one year. In very exceptional circumstances, after review by the Joint Committee, measures may be taken up to a total maximum period of three years. No measure shall be applied to the import of a product which has previously been subject to such a measure. 6. The Joint Committee shall within 30 days from the date of notification examine the information provided under paragraph 3 in order to facilitate a mutually acceptable resolution of the matter. In the absence of such resolution, the importing Party may adopt a measure pursuant to paragraph 4 to remedy the problem, and, in the absence of mutually agreed compensation, the Party against whose product the measure is taken may take compensatory action. The bilateral safeguard measure and the compensatory action shall be immediately notified to the other Parties and the Joint Committee. In the selection of the bilateral safeguard measure and the compensatory action, priority must be given to the measure which least disturbs the functioning of this Agreement. The compensatory action shall normally consist of suspension of concessions having substantially equivalent trade effects or concessions substantially equivalent to the value of the additional duties expected to result from the bilateral safeguard measure. The Party taking compensatory action shall apply the action only for the minimum period necessary to achieve the substantially equivalent trade effects and in any event, only while the measure under paragraph 4 is being applied. 7. Upon the termination of the measure, the rate of customs duty shall be the rate which would have been in effect but for the measure. 8. In critical circumstances, where delay would cause damage which would be difficult to repair, a Party may take a provisional emergency measure pursuant to a preliminary determination that there is clear evidence that increased imports constitute a substantial cause of serious injury, or threat thereof, to the domestic industry. The Party intending to take such a measure shall immediately notify the other Parties and the Joint Committee thereof. Within 30 days of the date of the notification, the procedures set out in paragraphs 2 to 6, including for compensatory action, shall be initiated. Any compensation shall be based on the total period of application of the provisional emergency measure and of the emergency measure. 9. Any provisional measure shall be terminated within 200 days at the latest. The period of application of any such provisional measure shall be counted as part of the duration of the measure set out in paragraph 5 and any extension thereof. Any tariff increases shall be promptly refunded if the investigation described in paragraph 2 does not result in a finding that the conditions of paragraph 1 are met. 10. Five years after the date of entry into force of this Agreement, the Parties shall review in the Joint Committee whether there is need to maintain the possibility to take safeguard measures between them. If the Parties decide, after the first review, to maintain such possibility, they shall thereafter conduct biennial reviews of this matter in the Joint Committee.

  • Health and Safety Plan Consultant shall prepare and submit a Health and Safety Plan (“HASP”) for the portion of Consultant’s work that will involve field work, assessments, or investigations of certain Project elements. The HASP shall describe how Consultant plans to complete field work, assessments, and/or investigations at the RWF. Consultant’s HASP must comply with the CIP HASP and shall be updated as new conditions are encountered.

  • Safeguard Measures The Parties note the multilateral negotiations pursuant to Article X of GATS on the question of emergency safeguard measures based on the principle of non-discrimination. Upon the conclusion of such multilateral negotiations, the Parties shall conduct a review for the purpose of discussing appropriate amendments to this Agreement so as to incorporate the results of such multilateral negotiations.

  • Protective Measures We have implemented and will maintain appropriate technical and organisational measures in relation to the Services taking into account the state of the art, the costs of implementation, and the nature, scope, context and purposes of Processing, as well as the likelihood and severity of risk to the rights and freedoms of data subjects. This includes measures relating to the physical security of Our facilities used to deliver them, measures to control access rights to Our assets and relevant networks, and processes for testing these measures. In accordance with Our obligations under applicable law, We may undertake digital forensic investigations in relation to the use of the Services and Subscriptions. You are responsible for using, and ensuring that your Users use, the controls and advice provided by the Services correctly and consistently.

  • Accident Prevention Health and Safety Committee (a) The Employer and the Union agree that they mutually desire to maintain standards of safety and health in the workplace in order to prevent accidents, injury and illness. (b) Recognizing its responsibilities under the applicable legislation, the Employer agrees to accept as a member of its Accident Prevention – Health & Safety Committee at least three (3) representatives, one from each base, selected or appointed by the Union from amongst bargaining unit employees. At any time where a vote is required, an equal number of representatives from each side shall be entitled to vote. (c) Such Committee shall identify potential dangers and hazards, institute means of improving health and safety programs and recommend actions to be taken to improve conditions related to safety and health. (d) The Employee agrees to co-operate reasonably in providing necessary information to enable the Committee to fulfill its functions. (e) Meetings shall be held quarterly or more frequently at the call of the Chair if required. The Committee shall maintain minutes of all meetings and make the same available for review. (f) Any representative appointed or select in accordance with (b) hereof shall serve a term of one (1) calendar year from the date of appointment which may be renewed for further periods of one (1) year. The Union will encourage its representative(s) to serve at least one (1) year. Time off for such representative(s) to attend meetings of the Accident Prevention – Health & Safety Committee in accordance with the foregoing shall be granted and time so spent attending such meetings shall be deemed to be work time for which the representative(s) shall be paid by the Employer at his regular or premium rate as may be applicable. (g) The Union agrees to endeavour to obtain the full co-operation of its membership in the observation of all safety rules and practices. (h) Pregnant employees may request to be transferred from their current duties if, in the professional opinion of the employee’s physician, the pregnancy may be at risk. If such a transfer is not feasible, the pregnant employee, if she so requests, will be granted an unpaid leave of absence before commencement of the maternity leave referred to in Article 16.04

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!