LEED and Project Close-Out Procedures Sample Clauses

LEED and Project Close-Out Procedures. (1) Evaluate and recommend use of LEED principles and guidelines, provide (to an order of magnitude that Owner approves as reasonably appropriate) cost-benefit analysis of various LEED credits, and establish and maintain procedures to ensure the Project achieves no less than a “Silver” certification by the USGBC and GBCI under LEED 2009 New Construction and Major Renovations, or such other level of certification as Owner may establish in accordance with Section II.1(A). (2) Oversee and coordinate the development and modification of all LEED Certification documentation, and ensure all such documentation necessary for LEED Certification is submitted to and approved by the USGBC. (3) Conduct Substantial Completion inspections and prepare a “punch-list” of items needed for Final Completion for each Project. Advise and recommend to the Owner as to when Substantial Completion of a Project, or completion of significant Project components has been achieved in relation to the schedule milestones established therefore, and obtain all warranties, as-built drawings, and other deliverables necessary to the final completion and close-out of all Projects. (4) Monitor completion of “punch list items,” conduct a Final Completion inspection, and submit a report to Owner confirming Final Completion of the Project. (5) Require special inspections or tests of the Work of Service Providers for the Projects, and receive, review and comment on all certificates of inspections, tests and approvals required by Applicable Laws or the applicable contracts for such Project, but only for conformance with the requirements of, and compatibility with the design objectives and criteria approved by Owner for the Project as a functioning whole, as indicated in the PIP and applicable contract documents. (6) Oversee commissioning and taking possession of completed Projects, or completed portions thereof. Coordinate all commissioning activities, including submission of all commissioning reports, plans and other verification documents and establish and coordinate post-construction commissioning prior to expiration of warranties and guarantees. (7) Coordinate transfer of property operation to Owner, including coordination of all warranties and guarantees, equipment and product/project manuals. (8) Establish and manage a warranty protocol throughout the warranty period to identify, enforce and resolve all warranty claims in consultation with the Owner. (9) Coordinate and ensure access to all electr...
Sample 1Sample 2

Related to LEED and Project Close-Out Procedures

  • Project Closeout a. Participate in final inspection to prepare punch lists for project contractor to correct and/or to complete listed items. Verify that items on punch lists have been completed successfully assist COUNTY Project Manager or designee to determine completion date and coordinate project close out. a. Coordinate the preparation, acceptance and distribution of project closeout documents in accordance with COUNTY Project Manager or designee procedures to clients.

  • Move-Out Procedure Prior to either (i) the expiry of the Term, or (ii) the date on which the Resident is to vacate the Residence (detailed in Table 1 & 3), the Manager, or designate, can be requested in advance by the Resident to complete a visual inspection of the Suite to view the state of cleanliness and repair. If no request to inspect the suite is made by the Resident, the inspection will take place once the Resident has vacated the suite. In the event the Resident chooses to have the inspection completed prior to vacating the suite, the Manager, or designate, will inspect the suite and inform the Resident of potential damage and/or cleaning charges and outline what steps the student may take to mitigate charges. On vacating, all garbage and belongings of the Resident must be removed, and the suite must be cleaned to the point of restoring the suite to its original condition. Once the Resident has vacated, the Manager, or designate, will complete a documented visual inspection of the Suite. In the event deficiencies are found, the cost of cleaning the suite and restoring it to its original state may be deducted from the Resident’s original Deposit. There is a minimum cleaning charge of

  • Project Close-out Termination of a research project that used controlled-access data from an NIHdesignated data repository (e.g., dbGaP) and confirmation of data destruction when the research is completed and/or discontinued. The project close-out process is completed in the dbGaP Authorized Access System.

  • Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.

  • Proposed Policies and Procedures Regarding New Online Content and Functionality By October 31, 2017, the School will submit to OCR for its review and approval proposed policies and procedures (“the Plan for New Content”) to ensure that all new, newly-added, or modified online content and functionality will be accessible to people with disabilities as measured by conformance to the Benchmarks for Measuring Accessibility set forth above, except where doing so would impose a fundamental alteration or undue burden. a) When fundamental alteration or undue burden defenses apply, the Plan for New Content will require the School to provide equally effective alternative access. The Plan for New Content will require the School, in providing equally effective alternate access, to take any actions that do not result in a fundamental alteration or undue financial and administrative burdens, but nevertheless ensure that, to the maximum extent possible, individuals with disabilities receive the same benefits or services as their nondisabled peers. To provide equally effective alternate access, alternates are not required to produce the identical result or level of achievement for persons with and without disabilities, but must afford persons with disabilities equal opportunity to obtain the same result, to gain the same benefit, or to reach the same level of achievement, in the most integrated setting appropriate to the person’s needs. b) The Plan for New Content must include sufficient quality assurance procedures, backed by adequate personnel and financial resources, for full implementation. This provision also applies to the School’s online content and functionality developed by, maintained by, or offered through a third-party vendor or by using open sources. c) Within thirty (30) days of receiving OCR’s approval of the Plan for New Content, the School will officially adopt, and fully implement the amended policies and procedures.

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

  • Contract Closeout The Provider Agency shall comply with all requirements of Policy Circular P7.01, Contract Closeout, including the timely submittal of the Final Report of Expenditures and any other financial or programmatic reports required by the Department. All required documentation is due within 120 Days of Contract Expiration, Non-renewal or Termination.

  • Violence Policies and Procedures The Employer agrees to have in place explicit policies and procedures to deal with violence. The policy will address the prevention of violence, the management of violent situations, provision of legal counsel and support to employees who have faced violence. The policies and procedures shall be part of the employee's health and safety policy and written copies shall be provided to each employee. Prior to implementing any changes to these policies, the employer agrees to consult with the Association.

  • Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.