Monitoring of Progress Sample Clauses

Monitoring of Progress. (a) Landlord will update Tenant on an on-going basis in connection with the Project and the schedule, and Tenant will have the right to monitor and inspect the Project as it progresses (including, without limitation, as to the inspection and uncovering of unsatisfactory work). Landlord shall update the Tenant in writing at least monthly as to the projected date(s) for each of the pertinent components of the Project. Landlord shall keep and maintain at all times and make available to Tenant for Tenant’s review all Space Plans and Construction Documents (including current as-built drawings, as and when prepared, but in any event Landlord shall deliver to Tenant three (3) complete copies of same within sixty (60) days following Substantial Completion, and in electronic format if available), specifications, field orders, change orders, shop drawings, catalog cuts and the like, in good order and reasonably marked to record all changes made during construction, as well as any invoices and bills. Tenant, at its sole cost and expense, shall have the right to retain construction consultants to assist Tenant throughout the construction process (including, without limitation, reviewing the Space Plans and Construction Documents and the Construction Budget, and in monitoring and inspecting the Project as it progresses), but any delays actually caused by such consultants shall be deemed to be a Tenant’s Delay, unless the delay is caused by the negligence of the Landlord or its agents, the Architect or the Contractor. The parties acknowledge that Tenant’s Representative is the consultant that will assist Tenant with the foregoing. (b) Tenant may inspect and conduct tests to determine whether construction is being performed consistent with the Base Building Shell Plans (as hereinafter defined) and/or the Construction Documents, regardless of whether such inspections or tests are required by the Base Building Shell Plans and/or Construction Documents. Should Tenant’s inspections or tests reveal that the work is not installed substantially in accordance with the Base Building Shell Plans and/or Construction Documents, the cost of uncovering and replacement shall be at Landlord’s expense. If Tenant’s inspections or tests require work to be uncovered and such inspections or tests reveal that the work has been installed substantially in accordance with the Base Building Shell Plans and/or Construction Documents, the costs of uncovering and replacement shall be at Tenant’s exp...
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Monitoring of Progress. 11 10. QUALITY ASSURANCE 11
Sample 1Sample 2Sample 3
Monitoring of Progress. (1) The Contractor shall submit to the Engineer three copies of a Monthly Progress Report (MPR), as described in Authority's Requirements Appendix 3 of Part A of this Schedule, describing the progress and current status of the Works. The MPR shall address the matters set out in the Works Programme. (2) The MPR shall be submitted by the end of each calendar month. It shall account for all works actually performed from twenty sixth day of the last month and up to twenty fifth day of the current month. (3) The MPR shall be divided into two sections. The first section shall cover progress and current status relating to design and the second section shall cover progress and current status relating to construction. (4) A monthly meeting to monitor & review the progress of the project shall be convened by the Engineer. Contractor’s site Representative & Designer Representative of Contractor and site agent of all interfacing parties as applicable shall also attend the meeting. The Authority may also be present in the meeting. (5) The Engineer or Authority may also conduct progress review meetings on weekly /bi-weekly intervals depending upon the requirements or urgency of works. In these review meetings Engineer may call Contractor’s Supplier/ Sub- Contractor/ Designer etc. as per the requirements.
Sample 1Sample 2Sample 3
Monitoring of Progress. Developer shall continuously monitor the status and progress of Development in order to ensure that any possible failures in meeting the dates set forth for any Milestone are identified well in advance. If the Developer cannot deliver to Nokia any Deliverable(s) or perform any of its other obligations hereunder in accordance with the Milestones, then the Developer shall as soon as Developer is or should reasonably have been aware of delay, inform Nokia thereof in writing specifying the reason for the delay and propose a new date for the delivery of such Deliverables or performance of obligations. Upon receipt of such notice, Nokia will determine whether a new date for the delayed Milestone is warranted given the circumstances causing the delay.
Sample 1Sample 2
Monitoring of Progress. 5.1 Outreach and widening participation activities will continue to be monitored by the College’s Recruitment Committee and Equality and Diversity Committee and reported to Academic Board. 5.2 Similarly, the Access Agreement Enhancement Plan will continue to be monitored by Recruitment Committee and Equality and Diversity Committee and reported to Academic Board. 5.3 The Strategic Management Group will continue to monitor recruitment patterns through management information provided by Registry Services, and to report to Academic Board and Governors. 5.4 The impact of progression agreements will be monitored by Recruitment Committee via analysis of student data in order to assess their effectiveness at promoting vocational and non traditional progression routes as outlined in the OFFA Access Agreement.
Sample 1
Monitoring of Progress. 5.1 Outreach and widening participation activities will continue to be monitored by the College‟s Learning and Teaching Committee, Quality and Standards Committee and the Equality and Diversity Committee and reported to Academic Board. 5.2 The revised Access Agreement Enhancement Plan will continue to be monitored by Learning and Teaching Committee, the Equality and Diversity Committee and reported to the Academic Board. 5.3 The Strategic Management Group will continue to monitor recruitment patterns through management information provided by Registry Services, and to report to Academic Board and Governors. 5.4 The impact of progression agreements will be monitored by Learning and Teaching Committee and Academic Registry through analysis of student data in order to assess their effectiveness at promoting vocational and non- traditional progression as outlined in the OFFA Access Agreement.
Sample 1
Monitoring of Progress. 1. The Commission shall monitor the progress of the Union against the general objectives and digital targets. To this end, the Commission shall rely upon DESI and shall set out in an implementing act the key performance indicators (‘KPIs’) for each digital target. That implementing act shall be adopted in accordance with the examination procedure referred to in Article 25(2). 2. Member States shall provide to the Commission in a timely manner the necessary statistics and data required for the effective monitoring of the digital transformation and of the degree of achievement of the digital targets with data disaggregated, where possible, to the regional level and by gender, taking into consideration Union and national law. Where the relevant statistics from Member States are not yet available, the Commission may use an alternative data collection methodology, such as studies or direct collection of data from the Member States, in consultation with the Member States, including in order to ensure that the regional level is properly documented. The use of that alternative data collection methodology shall not affect the tasks of Eurostat as laid down in Commission Decision 2012/504/EU19. 3. The Commission, in close cooperation with Member States, shall define Union-level projected trajectories for the attainment of each of the digital targets, which would serve as basis for the monitoring and the national Digital Decade strategic roadmaps. Where necessary, in light of technical, economic or societal developments, the Commission, in close cooperation with Member States, shall update one or more of these projected trajectories. The Commission shall report to the European Parliament and the Council about the Union-level trajectories and their updates in due time.
Sample 1
AutoNDA by SimpleDocs
Monitoring of Progress. (1) The Contractor shall submit to the Engineer six copies of a Monthly Progress Report (MPR), as described in Appendix 5 of these Employer's Requirements, describing the progress and current status of the Works. The MPR shall address the matters set out inthe Works Programme. (2) The MPR shall be submitted by the last day of each calendar month. It shall account for all works actually performed from the twenty sixth day of the previous month and up to the twenty fifth day of the current month. The processing of the Interim Payment Certificate (IPC) will only commence after the receipt of the MPR on the due date. Late receipt of MPR will delay the processing of the IPC. (3) The MPR shall be divided into two sections. The first section shall cover progress made and current status relating to design, and the second section shall cover progress made and current status relating to construction. (4) The MPR shall be signed by the following Key Staff; Project Manager, QA Manager, Safety Manager, and the Engineering Manager (Design), who by signing the MPR shall certify that all information contained in the MPR, as relating to their section of the Works, has been accepted and verified by each signatory as being accurate, honest, true and meets the requirements of the Contract. (5) A monthly meeting to monitor the progress of the project shall be convened by the Engineer or his representatives. The Employer may also be present in the meeting. Refer to Clause A18 of this Employer’s Requirements Volume 3. (6) The Employer / the Engineer shall arrange Quarterly Review Meetings for the Project which the Contractor shall attend and participate in as required. Refer to Clause A18 of thisEmployer’s Requirements Volume 3.
Sample 1

Related to Monitoring of Progress

  • Monitoring of Servicers (a) The Master Servicer shall be responsible for reporting to the Trustee, the Trust Administrator and the Depositor the compliance by each Servicer with its duties under the related Servicing Agreement. In the review of each Servicer's activities, the Master Servicer may rely upon an officer's certificate of the Servicer with regard to such Servicer's compliance with the terms of its Servicing Agreement. In the event that the Master Servicer, in its judgment, determines that a Servicer should be terminated in accordance with its Servicing Agreement, or that a notice should be sent pursuant to such Servicing Agreement with respect to the occurrence of an event that, unless cured, would constitute grounds for such termination, the Master Servicer shall notify the Depositor, the Trust Administrator and the Trustee thereof and the Master Servicer shall issue such notice or take such other action as it deems appropriate. (b) The Master Servicer, for the benefit of the Trustee, the Trust Administrator and the Certificateholders, shall enforce the obligations of each Servicer under the related Servicing Agreement, and shall, in the event that a Servicer fails to perform its obligations in accordance with the related Servicing Agreement, subject to the preceding paragraph, terminate the rights and obligations of such Servicer thereunder and act as successor Servicer of the related Mortgage Loans or cause the Trustee to enter into a new Servicing Agreement with a successor Servicer selected by the Master Servicer; provided, however, it is understood and acknowledged by the parties hereto that there will be a period of transition (not to exceed 90 days) before the actual servicing functions can be fully transferred to such successor Servicer. Such enforcement, including, without limitation, the legal prosecution of claims, termination of Servicing Agreements and the pursuit of other appropriate remedies, shall be in such form and carried out to such an extent and at such time as the Master Servicer, in its good faith business judgment, would require were it the owner of the related Mortgage Loans. The Master Servicer shall pay the costs of such enforcement at its own expense, provided that the Master Servicer shall not be required to prosecute or defend any legal action except to the extent that the Master Servicer shall have received reasonable indemnity for its costs and expenses in pursuing such action. (c) To the extent that the costs and expenses of the Master Servicer related to any termination of a Servicer, appointment of a successor Servicer or the transfer and assumption of servicing by the Master Servicer with respect to any Servicing Agreement (including, without limitation, (i) all legal costs and expenses and all due diligence costs and expenses associated with an evaluation of the potential termination of the Servicer as a result of an event of default by such Servicer and (ii) all costs and expenses associated with the complete transfer of servicing, including all servicing files and all servicing data and the completion, correction or manipulation of such servicing data as may be required by the successor servicer to correct any errors or insufficiencies in the servicing data or otherwise to enable the successor servicer to service the Mortgage Loans in accordance with the related Servicing Agreement) are not fully and timely reimbursed by the terminated Servicer, the Master Servicer shall be entitled to reimbursement of such costs and expenses from the Collection Account. (d) The Master Servicer shall require each Servicer to comply with the remittance requirements and other obligations set forth in the related Servicing Agreement. (e) If the Master Servicer acts as Servicer, it will not assume liability for the representations and warranties of the Servicer, if any, that it replaces. (f) If a Servicer fails to make its required payment of Compensating Interest on any Distribution Date, the Master Servicer will be required to make such payment of Compensating Interest to the same extent that such Servicer was required to make such payment of Compensating Interest. (g) To the extent a Servicer requests the consent of the Trust or the Master Servicer with respect to any servicing-related matter for which the applicable Servicer is required to seek consent under the applicable Servicing Agreement or Assignment Agreement, the Master Servicer shall promptly or within the time frame specified in such Servicing Agreement, if any, evaluate such request for consent in the best interest of the Trust and the Certificateholders, and grant or withhold such consent accordingly.

  • Coordination, Oversight and Monitoring of Service Providers As set forth in the Administrative Services Agreement between the Fund and CRMC, CRMC shall coordinate, monitor and oversee the activities performed by the Service Providers with which AFS contracts. AFS shall monitor Service Providers’ provision of services including the delivery of Customer account statements and all Fund-related material, including summary prospectuses and/or prospectuses, shareholder reports, and proxies.

  • Monitoring of Servicer The Master Servicer shall be responsible for reporting to the Trustee, the Trust Administrator and the Depositor the non-compliance by the Servicer with its duties under this Agreement. In the review of the Servicer’s activities, the Master Servicer may rely upon an Officers’ Certificate of the Servicer (or similar document signed by a Servicing Officer of the Servicer) with regard to the Servicer’s compliance with the terms of this Agreement. In the event that the Master Servicer, in its good faith judgment, determines that the Servicer should be terminated in accordance with the terms hereof, or that a notice should be sent pursuant to the terms hereof with respect to the occurrence of an event that, unless cured, would constitute grounds for such termination, the Master Servicer shall notify the Depositor, the Trust Administrator and the Trustee thereof and the Master Servicer shall issue such notice or take such other action as it deems appropriate. The Master Servicer (or if the Master Servicer is the Servicer, the Trustee), for the benefit of the Certificateholders, shall enforce the obligations of the Servicer under this Agreement, and shall, in the event that it receives notice and confirms that the Servicer has failed to perform its obligations in accordance with this Agreement, subject to the preceding paragraph, terminate the rights and obligations of the Servicer hereunder and in accordance with the provisions of Article VII of this Agreement and act as Servicer of the Mortgage Loans or appoint a successor servicer; provided, however, it is understood and acknowledged by the parties hereto that there will be a period of transition (not to exceed 90 days) before the actual servicing functions can be fully transferred to such successor servicer. Such enforcement, including, without limitation, the legal prosecution of claims and the pursuit of other appropriate remedies, shall be in such form and carried out to such an extent and at such time as the Master Servicer or Trustee, as applicable, in its good faith business judgment, would require were it the owner of the Mortgage Loans. The Master Servicer or the Trustee, as applicable, shall pay the costs of such enforcement at its own expense, provided that the Master Servicer or the Trustee, as applicable, shall not be required to prosecute or defend any legal action except to the extent that the Master Servicer or the Trustee, as applicable, shall have received reasonable indemnity for its costs and expenses in pursuing such action. To the extent that the costs and expenses of the Master Servicer or Trustee, as applicable, related to any termination of the Servicer, appointment of a successor servicer or the transfer and assumption of servicing by the Master Servicer or the Trustee, as applicable, with respect to this Agreement (including, without limitation, (i) all legal costs and expenses and all due diligence costs and expenses associated with an evaluation of the potential termination of the Servicer as a result of a Servicer Event of Default and (ii) all costs and expenses associated with the complete transfer of servicing, including all servicing files and all servicing data and the completion, correction or manipulation of such servicing data as may be required by the successor servicer to correct any errors or insufficiencies in the servicing data or otherwise to enable the successor servicer to service the Mortgage Loans in accordance with this Agreement) are not fully and timely reimbursed by the terminated Servicer, the Master Servicer or the Trustee, as applicable, shall be entitled to reimbursement of such costs and expenses from the Distribution Account. The Master Servicer (or if the Master Servicer is the Servicer, the Trustee) shall, upon receipt from the Servicer, the Master Servicer or the Trust Administrator, of notice of any failure of the Servicer to comply with the remittance requirements and other obligations set forth in this Agreement, enforce such obligations. If the Master Servicer or the Trustee, as applicable, acts as Servicer, it will not assume liability for the representations and warranties of the Servicer that it replaces.

  • Monitoring Compliance Upon the request of the Lender, but without incurring any liability beyond the Guaranteed Obligations, from time to time, Guarantor shall promptly provide to the Lender such documents, certificates and other information as may be deemed reasonably necessary to enable the Lender to perform its functions under the Servicing Agreement as the same relates to the Guarantor.

  • Monitoring of Contract Performance The Contractor shall comply with the monitoring arrangements set out in the Monitoring Requirements Schedule including, but not limited to, providing such data and information as the Contractor may be required to produce under the Contract.

  • Audit, Inspection and Visitation The Adviser shall make available to the Trust during regular business hours all records and other data created and maintained pursuant to the foregoing provisions of this Agreement for reasonable audit and inspection by the Trust or any regulatory agency having authority over the Trust.

  • Monitoring of Performance Vendor shall continuously monitor and record its performance to ensure that all of Vendor's responsibilities and obligations hereunder are being met and fulfilled. Citizens may conduct programmatic and other administrative contract monitoring during the term of this Agreement. The purpose of this monitoring is to ensure that all of Vendor's responsibilities and obligations are being met and fulfilled. Such monitoring may include on-site visits, report reviews, invoice reviews, compliance reviews, and a review of any other areas reasonably necessary. Vendor acknowledges and agrees that Citizens may also monitor and record Vendor Staff communications to the extent they occur within or are connected to any Citizens’ resource, such as electronic or telecommunications systems.

  • Monitoring System In each case in which the Custodian has exercised delegated authority to place Assets with a Foreign Custodian, the Custodian shall establish a system, to re-assess or re-evaluate selected Foreign Custodians, at least annually in accordance with Rule 17f-5(c)(3).

  • Response/Compliance with Audit or Inspection Findings A. Grantee must act to ensure its and its Subcontractors’ compliance with all corrections necessary to address any finding of noncompliance with any law, regulation, audit requirement, or generally accepted accounting principle, or any other deficiency identified in any audit, review, inspection or investigation of the Grant Agreement and the services and Deliverables provided. Any such correction will be at Grantee’s or its Subcontractor's sole expense. Whether Xxxxxxx's action corrects the noncompliance shall be solely the decision of the System Agency. B. As part of the services, Grantee must provide to HHS upon request a copy of those portions of Grantee's and its Subcontractors' internal audit reports relating to the services and Deliverables provided to the State under the Grant Agreement. C. Grantee shall include the requirement to provide to System Agency (and any of its duly authorized federal, state, or local authorities) internal audit reports related to this Grant Agreement in any Subcontract it awards. Upon request by System Agency, Grantee shall enforce this requirement against its Subcontractor. Further, Grantee shall include in any Subcontract it awards a requirement that all Subcontractor Subcontracts must also include these provisions.

  • Monitoring Services IDT staff shall, using methods that include face-to-face and other contacts with the member, monitor the services a member receives. This monitoring shall ensure that: a. The member receives the services and supports authorized, arranged for and coordinated by the IDT staff; b. The services and supports identified in the MCP as being provided by natural and community supports are being provided; and c. The quality of the services and supports received is adequate and still necessary to continue to meet the needs and preferences of the member and support the member’s outcomes identified in the MCP.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!