Non-Compensable Delays Sample Clauses

Non-Compensable Delays. The Contractor agrees to make no claim for, and is deemed to have included in its Bid prices for the various items of the Contract, the extra/additional costs attributable to any delays caused by or attributable to the items set forth below. For such items, the Contractor shall be compensated, if at all, solely by an extension of time to complete the performance of the Work, in accordance with the provisions of Article 46. Such extensions of time will be granted, if at all, pursuant to the grounds set forth in Article 46.3. 44.5.1. The acts or omissions of any third parties, including but not limited to Other Contractors, public/ governmental bodies (other than City Agencies), utilities or private enterprises, who are disclosed in the Contract Documents or are ordinarily encountered or generally recognized as related to the Work; 44.5.2. Any situation which was within the contemplation of the parties at the time of entering into the Contract, including any delay indicated or disclosed in the Contract Documents or generally recognized as related to the nature of the Work, and/or the existence of any facility or appurtenance owned, operated or maintained by any third party, as indicated or disclosed in the Contract Documents or ordinarily encountered or generally recognized as related to the nature of the Work; 44.5.3. Restraining orders, injunctions or judgments issued by a court which were caused by a Contractor’s submission, action or inaction or by a Contractor’s Means and Methods of Work, or by third parties, unless such order, injunction or judgment was the result of an action or omission by the City; 44.5.4. Any labor boycott, strike, picketing, lockout or similar situation; 44.5.5. Any shortages of supplies or materials, or unavailability of equipment, required by the Contract Work; 44.5.6. Climatic conditions, storms, floods, droughts, tidal waves, fires, hurricanes, earthquakes, landslides or other catastrophes or acts of God, or acts of war or of the public enemy or terrorist acts, including the City’s reasonable responses thereto; and 44.5.7. Extra Work which does not significantly affect the overall completion of the Contract, reasonable delays in the review or issuance of change orders or field orders and/or in shop drawing reviews or approvals.
Sample 1Sample 2Sample 3See All (37)
Non-Compensable Delays. The Parties acknowledge that the following types of delays and events are not within the responsibility or control of City, and are reasonably contemplated by the Parties to occur during the course of performance of a Work Order Package which may impact the schedule for performance: Force Majeure events as described in the General Conditions (“Non-Compensable Delays”). Notwithstanding anything to the contrary in the Contract Documents, an extension of the Work Order Package Deadline, to the extent permitted under Section 8.2 of the General Conditions, shall be the sole remedy of Design-Builder for the above referenced Non- Compensable Delays. In no event shall Design-Builder be entitled to any compensation or recovery of any damages in connection with the Non- Compensable Delays identified in this section including, without limitation, consequential damages, lost opportunity costs, impact damages or other similar remuneration.
Sample 1Sample 2
Non-Compensable Delays. The Parties acknowledge that the following types of delays and events are not within the responsibility or control of City, and are reasonably contemplated by the Parties to occur during the course of performance of the Work which may impact the schedule for performance: (a) construction by separate contractors on or adjacent to the Sites; and (b) Force Majeure events as described in the General Conditions (“Non-Compensable Delays”). Notwithstanding anything to the contrary in the Contract Documents, an extension of the Contract Time, to the extent permitted under Paragraph 8.2 of the General Conditions, shall be the sole remedy of Design-Builder for the above referenced Non-Compensable Delays. In no event shall Design-Builder be entitled to any compensation or recovery of any damages in connection with the Non-Compensable Delays identified in this paragraph including, without limitation, consequential damages, lost opportunity costs, impact damages or other similar remuneration.
Sample 1
Non-Compensable Delays. Consistent with Public Contract Code Section 7102, neither the District nor any person or entity acting on its behalf shall be required to pay any additional compensation to the Contractor or shall otherwise be liable for any costs attributable to a delay (each a “Non-Compensable Delay”) if: (i) the cause of the delay was beyond the control of and without the fault of the District; (ii) the delay was reasonable under the circumstances involved; or (iii) the delay was within the contemplation of the District and the Contractor. For purposes of the Contract, delays within the contemplation of the District and the Contractor shall be deemed and construed to include, without limitation, delays attributable to: (i) normal seasonal weather conditions; (ii) coordination of the Work with any Work by Others; (iii) work on the Project that must be completed prior to some or all of the Work being commenced or completed; (iv) discovery of hazardous materials (including, without limitation, asbestos) if the Work or the Project involves or relates to the presence, repair, modification, rehabilitation, reconstruction, demolition, removal or other accommodation of existing structures, utilities, or other improvements; (v) the location, time of year and other conditions in which the Work is to be performed; and (vi) other matters typically attendant to construction projects of the same general type and scope as the Project. The Contractor’s sole and exclusive remedy in the event of a Non- Compensable Delay shall be to seek an extension of time for performance of the Work.
Sample 1
Non-Compensable Delays. Neither the District nor any person or entity acting on its behalf shall be required to pay any additional compensation to the Contractor or shall otherwise be liable for any costs attributable to a delay (each a “Non-Compensable Delay”) if: (i) the cause of the delay was beyond the control of and without the fault of the District; (ii) the delay was reasonable under the circumstances involved; or (iii) the delay was within the contemplation of the District and the Contractor. For purposes of the Contract, delays within the contemplation of the District and the Contractor shall be deemed and construed to include, without limitation, delays attributable to: (i) normal seasonal weather conditions; (ii) coordination of the Work with any Work by Others; (iii) work on the Project that must be completed prior to some or all of the Work being commenced or completed;
Sample 1
Non-Compensable Delays. The Parties acknowledge that delays caused by Force Majeure events as defined in the General Conditions are not within the responsibility or control of the City and may impact the schedule for performance: construction. Notwithstanding anything to the contrary in the Contract Documents, an extension of the Contract Time, to the extent permitted under Section 8.2 of the General Conditions, shall be the sole remedy of Design-Builder for any such delay caused by a Force Majeure event. In no event shall Design-Builder be entitled to any compensation or recovery of any damages in connection with any such delay as identified in this paragraph including, without limitation, consequential damages, lost opportunity costs, impact damages or other similar remuneration
Sample 1
Non-Compensable Delays. The Contractor agrees to make no claim for, and is deemed to have included in its Bid prices for the various items of the Contract, the extra/additional costs attributable to any delays caused by or attributable to the items set forth below. For such items, the Contractor shall be compensated, if at all, solely by an extension of time to complete the performance of the Work, in accordance with the provisions of Article
Sample 1
Non-Compensable Delays. Contractor’s sole remedy for Non-Compensable Delays shall be an extension of the applicable Contract Time, provided that Contractor has complied with the requirements of Paragraph 4.05.
Sample 1

Related to Non-Compensable Delays

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

  • Prevention or Delay of Performance by the Company or the Depositary Neither the Depositary nor the Company nor any of their respective directors, employees, agents or affiliates shall incur any liability to any Owner or Holder: (i) if by reason of (A) any provision of any present or future law or regulation or other act of the government of the United States, any State of the United States or any other state or jurisdiction, or of any governmental or regulatory authority or stock exchange; (B) (in the case of the Depositary only) any provision, present or future, of the articles of association or similar document of the Company, or any provision of any securities issued or distributed by the Company, or any offering or distribution thereof; or (C) any event or circumstance, whether natural or caused by a person or persons, that is beyond the ability of the Depositary or the Company, as the case may be, to prevent or counteract by reasonable care or effort (including, but not limited to, earthquakes, floods, severe storms, fires, explosions, war, terrorism, civil unrest, labor disputes, criminal acts or outbreaks of infectious disease; interruptions or malfunctions of utility services, Internet or other communications lines or systems; unauthorized access to or attacks on computer systems or websites; or other failures or malfunctions of computer hardware or software or other systems or equipment), the Depositary or the Company is, directly or indirectly, prevented from, forbidden to or delayed in, or could be subject to any civil or criminal penalty on account of doing or performing and therefore does not do or perform, any act or thing that, by the terms of this Deposit Agreement or the Deposited Securities, it is provided shall be done or performed; (ii) for any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement (including any determination by the Depositary to take, or not take, any action that this Deposit Agreement provides the Depositary may take); (iii) for the inability of any Owner or Holder to benefit from any distribution, offering, right or other benefit that is made available to holders of Deposited Securities but is not, under the terms of this Deposit Agreement, made available to Owners or Holders; or (iv) for any special, consequential or punitive damages for any breach of the terms of this Deposit Agreement. Where, by the terms of a distribution to which Section 4.1, 4.2 or 4.3 applies, or an offering to which Section 4.4 applies, or for any other reason, that distribution or offering may not be made available to Owners, and the Depositary may not dispose of that distribution or offering on behalf of Owners and make the net proceeds available to Owners, then the Depositary shall not make that distribution or offering available to Owners, and shall allow any rights, if applicable, to lapse.

  • Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.

  • Extended Illness Leave When an employee is absent from his/her duties on account of illness or accident for a period of five school months or less, whether or not the illness or accident arises out of or in the course of employment, the amount deducted from the salary due the employee for any of the five-school-month periods in which absence occurs shall not exceed the sum which is actually paid a substitute employee employed to fill the employee’s position during his/her absence, or if no substitute employee was employed, the amount that would have been paid to the substitute had a substitute been employed. The sick leave, including accumulated sick leave, and the five-month period shall run consecutively. In other words, the five-month period stipulated above begins immediately after use of the employee’s current annual ten days plus any accumulated sick leave. When the employee remains absent after use of the five-month differential pay leave, the employee shall be in unpaid status. When the employee has exhausted all available sick leave, including accumulated sick leave, and continues to be absent on account of illness or accident for a period beyond the five-month period, and the employee is not medically able to resume the duties of his/her position, the employee shall, if not placed in another position, be placed on a reemployment list for a period of 24 months if the employee is on probationary status or for a period of 39 months if the employee is on permanent status. When the employee is medically able, during the 24- or 39-month period, the employee shall be returned to employment in a position for which he/she is credentialed and is qualified. The 24-or 39-month period shall commence at the expiration of the five-month period described above. This five-month period shall be implemented as set forth in the mandatory provisions of Education Code Section 44977 (as amended by SB 1019, Chapter 30 of the Statutes of 1998) and the mandatory provisions of Education Code Section 44978.1 (as newly enacted by the same Chapter 30 of the Statutes of 1998.)

  • Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.

  • TERMINATION BY MPS - BREACH BY CONTRACTOR If Contractor fails to fulfill its obligations under this Contract in a timely or proper manner, or violates any of its provisions, MPS shall thereupon have the right to terminate it by giving five (5) days written notice before the effective date of termination of the Contract, specifying the alleged violations, and effective date of termination. The Contract shall not be terminated if, upon receipt of the notice, Contractor promptly cures the alleged violation with five (5) days. In the event of termination, MPS will only be liable for services rendered through the date of termination and not for the uncompleted portion, or for any materials or services purchased or paid for by Contractor for use in completing the Contract.