Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Obligations of Contractor 5.01 CONTRACTOR agrees to perform all Services in accordance with the terms and conditions of this Agreement and the Proposal. In the event that the terms of the Proposal shall conflict with the terms of this Agreement or contain additional terms that purport to bind the CITY other than the Services to be rendered and the price for the Services, the terms of this Agreement shall govern and said additional or conflicting terms shall be of no force or effect.
5.02 Except as otherwise agreed by the parties, CONTRACTOR will supply all personnel, materials and equipment required to perform the Services. CONTRACTOR shall provide its own offices, telephones, vehicles and computers and set its own work hours. CONTRACTOR will determine the method, details, and means of performing the Services under this Agreement.
5.03 CONTRACTOR shall keep CITY informed as to the progress of the Services by means of regular and frequent consultations. Additionally, when requested by CITY, CONTRACTOR shall prepare written status reports.
5.04 CONTRACTOR is responsible for paying, when due, all income and other taxes, fees and withholding, including withholding state and federal taxes, social security, unemployment and worker’s compensation, incurred as a result of the compensation paid under this Agreement. XXXXXXXXXX agrees to indemnify, defend and hold harmless CITY for any claims, costs, losses, fees, penalties, interest, or damages suffered by CITY resulting from CONTRACTOR’s failure to comply with this provision.
5.05 In the event CONTRACTOR is required to prepare plans, drawings, specifications and/or estimates, the same shall be furnished in conformance with local, state and federal laws, rules and regulations.
5.06 CONTRACTOR represents that it possesses all required licenses necessary or applicable to the performance of Services under this Agreement and the Proposal and shall obtain and keep in full force and effect all permits and approvals required to perform the Services herein. In the event CITY is required to obtain an approval or permit from another governmental entity, CONTRACTOR shall provide all necessary supporting documents to be filed with such entity.
5.07 CONTRACTOR shall be solely responsible for obtaining Employment Eligibility Verification information from CONTRACTOR’s employees, in compliance with the Immigration Reform and Control Act of 1986, Pub. L. 99-603 (8 U.S.C. 1324a), and shall ensure that CONTRACTOR’s employees are eligible to work in the United States.
5.08 In the event that CONTRACTOR employs, contracts with, or otherwise utilizes any CalPERS retirees in completing any of the Services performed hereunder, such instances shall be disclosed in advance to the CITY and shall be subject to the CITY’s advance written approval.
5.09 Drug-free Workplace Certification. By signing this Agreement, the CONTRACTOR hereby certifies under penalty of perjury under the laws of the State of California that the CONTRACTOR will comply with the requirements of the Drug-Free Workplace Act of 1990 (Government Code, Section 8350 et seq.) and will provide a drug- free workplace.
5.10 CONTRACTOR shall comply with all applicable local, state and federal laws, rules, regulations, entitlements and/or permits applicable to, or governing the Services authorized hereunder.
Obligations of the Consultant Conduct of the Services
Obligations of the Customer 3.1 The Customer agrees to:
(a) The Customer shall give the Company not less than 14 days prior written notice of any proposed change of ownership of the Customer and or any change in the Customer’s details (including but not limited to, changes in the customer’s name, address, contact phone/fax numbers or business practice). The Customer shall be liable for any loss incurred by the Company as a result of the Customers failure to comply with this clause.
(b) Pay the Company the Price for carrying out the Works in accordance with this agreement;
(c) Provide the Company with all necessary plans, specifications, services and amenities, so as to allow the Company to carry out the Works, provide access to the Location and ensure to the Company’s reasonable satisfaction that the Location remains in a state and condition that is safe for the Company and its employees and agents;
(d) Ensure the Location complies with all necessary bylaws and restrictions is structurally sound (in accordance with all legislation governing safety in the workplace);
(e) Not to cause any disruption or obstruction to the carrying out of any Works and to follow any reasonable instructions provided by the Company about the Works;
(f) Where the Works requires co-ordination with other trades then the Customer will supply the Company with a schedule detailing all relevant information so as to allow the Company sufficient time to co-ordinate with the Customer’s other tradespersons;
(g) Permit the Company to attach such reasonable signage as the Company may wish to any Works so as to identify that the Company is carrying out the Works;
(h) In circumstances where it wishes to make a claim against the Company pursuant to the guarantee given in clause 13.2, exclusively permit the Company or its authorised representative to remedy or make good any defects in its Workmanship and not permit any other third party to do so.
3.2 Without prejudice to any other right or remedy of the Company, if the Customer fails to carry out or perform any of its obligations pursuant to this clause 3 (excepting clause 3.1(g)) then, in addition to any Additional Expenses Charge that may apply, the Company may charge the Customer a Services Delay Charge for each day (or part thereof) that the Company is, in its reasonable opinion, unable and/or not required to carry out or perform the Works as a result of such breach by the Customer.
3.3 Where the Customer requests any Related Work to be carried out, the Company will use its best endeavours to source suppliers and/or contractors to carry out the Related Work, but the Customer is responsible for the commissioning, controlling, and payment for such work.
3.4 The Customer acknowledges that unless otherwise agreed in writing between the Customer and the Company, the Customer shall be responsible for obtaining, paying for and maintaining in force all permits, approvals, authorisations, authorities, licences and consents of all regulatory authorities whatsoever which are or may be necessary or advisable in connection with the Works.
OBLIGATIONS OF THE SUPPLIER In addition to the Article 4.2 of the GPC, it is specified that:
Obligations of DOE a. In express reliance on the covenants and representations in this Compromise Agreement and to avoid further expenditure of public resources, XXX agrees to accept Respondent’s payment pursuant to section III.2.a in full satisfaction of the penalty authorized by the Act.
x. XXX agrees to issue promptly an Adopting Order adopting this Agreement.
x. XXX agrees to terminate this enforcement action with prejudice upon Respondent’s completion of its Obligations in accordance with section III.2, above. If Respondent fails to complete its Obligations in accordance with section III.2, above, DOE may notify Respondent that the Agreement is null and void and may seek the maximum penalty in accordance with 10 C.F.R. § 429.120.
OBLIGATIONS OF THE LESSEE The Lessee shall keep the premises in a clean, sanitary, neat and presentable condition. The Lessee shall be responsible for the repairs, outside of ordinary wear and tear, of any part of the Premises that do not affect the structural parts of the building or structure in which it is located or those that are generally considered as minor repair (“Minor Repairs”) including but not limited to replacing light bulbs, cleaning or repairs of windows, doors, toilets and similar appurtenances. The Lessee shall, at its sole expense restore, repair and/or rectify any damage, outside of ordinary wear and tear, to the Premises caused by the Lessee or others that the lessee permits into the Premises that are not covered or compensable by any insurance.
Obligations of the Client 4.1. The client undertakes to inform the company in advance (meaning no later than 2 calendar days) about the dispatch of the goods, by entering the shipment into the Xxxxx.xxx software.
4.1.1. In case of non-compliance with subparagraph 3.2.1 of this agreement, the company has the right to refuse the client in accepting and placing his goods at the warehouse.
4.2. To send goods from the warehouse or to carry out other operations, the client is obliged to provide his client number (client ID) and data of the goods.
Obligations of the Company Whenever required under this Section 2 to effect the registration of any Registrable Securities, the Company shall, as expeditiously as reasonably possible:
(a) prepare and file with the SEC a registration statement with respect to such Registrable Securities and use its commercially reasonable efforts to cause such registration statement to become effective and, upon the request of the Holders of a majority of the Registrable Securities registered thereunder, keep such registration statement effective for a period of up to one hundred twenty (120) days or, if earlier, until the distribution contemplated in the registration statement has been completed; provided, however, that (i) such one hundred twenty (120) day period shall be extended for a period of time equal to the period the Holder refrains, at the request of an underwriter of Common Stock (or other securities) of the Company, from selling any securities included in such registration, and (ii) in the case of any registration of Registrable Securities on Form S-3 that are intended to be offered on a continuous or delayed basis, subject to compliance with applicable SEC rules, such one hundred twenty (120) day period shall be extended for up to sixty (60) days, if necessary, to keep the registration statement effective until all such Registrable Securities are sold;
(b) prepare and file with the SEC such amendments and supplements to such registration statement, and the prospectus used in connection with such registration statement, as may be necessary to comply with the Securities Act in order to enable the disposition of all securities covered by such registration statement;
(c) furnish to the selling Holders such numbers of copies of a prospectus, including a preliminary prospectus, as required by the Securities Act, and such other documents as the Holders may reasonably request in order to facilitate their disposition of their Registrable Securities;
(d) use its commercially reasonable efforts to register and qualify the securities covered by such registration statement under such other securities or blue-sky laws of such jurisdictions as shall be reasonably requested by the selling Holders; provided that the Company shall not be required to qualify to do business or to file a general consent to service of process in any such states or jurisdictions, unless the Company is already subject to service in such jurisdiction and except as may be required by the Securities Act;
(e) in the event of any underwritten public offering, enter into and perform its obligations under an underwriting agreement, in usual and customary form, with the underwriter(s) of such offering;
(f) use its commercially reasonable efforts to cause all such Registrable Securities covered by such registration statement to be listed on a national securities exchange or trading system and each securities exchange and trading system (if any) on which similar securities issued by the Company are then listed;
(g) provide a transfer agent and registrar for all Registrable Securities registered pursuant to this Agreement and provide a CUSIP number for all such Registrable Securities, in each case not later than the effective date of such registration;
(h) promptly make available for inspection by the selling Holders, any managing underwriter(s) participating in any disposition pursuant to such registration statement, and any attorney or accountant or other agent retained by any such underwriter or selected by the selling Holders, all financial and other records, pertinent corporate documents, and properties of the Company, and cause the Company’s officers, directors, employees, and independent accountants to supply all information reasonably requested by any such seller, underwriter, attorney, accountant, or agent, in each case, as necessary or advisable to verify the accuracy of the information in such registration statement and to conduct appropriate due diligence in connection therewith;
(i) notify each selling Holder, promptly after the Company receives notice thereof, of the time when such registration statement has been declared effective or a supplement to any prospectus forming a part of such registration statement has been filed; and
(j) after such registration statement becomes effective, notify each selling Holder of any request by the SEC that the Company amend or supplement such registration statement or prospectus. In addition, the Company shall ensure that, at all times after any registration statement covering a public offering of securities of the Company under the Securities Act shall have become effective, its xxxxxxx xxxxxxx policy shall provide that the Company’s directors may implement a trading program under Rule 10b5-1 of the Exchange Act.
Obligations of the Parties Clause 8
