Responsibility for Construction Costs Sample Clauses

Responsibility for Construction Costs. (1) District’s budget for the Project may include a contingency of ten percent (10 %) over and above any estimate of construction cost or evaluation prepared or agreed to by Architect (2) Evaluation of District’s budget for the Project, preliminary estimates of the probable construction cost and any updated estimates of the probable construction cost prepared by Architect represent Architect’s best judgment as a design professional familiar with the construction industry. The parties recognize, however, that neither Architect nor District has control over the cost of labor, materials or equipment, over the contractor’s methods of determining bid prices, or over competitive bidding, market or negotiating conditions. Accordingly, Architect cannot and does not warrant or represent that bids or negotiated prices will not vary from District’s budget for the Project or from any estimate of construction costs or evaluation prepared or agreed to by Architect. (3) In preparing estimates of construction cost, the Architect shall include reasonable contingencies for design, bidding and price escalation as agreed to by the District. (4) If bidding or negotiating has not commenced within sixty (60) days after Architect submits the construction documents to District, following review and approval by District’s legal counsel, any Project budget shall be adjusted to reflect changes, if any, in the general level of prices in the construction industry. (5) Should the lowest responsible bid received exceed Architect’s final estimate of probable construction costs as accepted by District by more than ten percent (10%), District may: (a) award the contract and proceed with the Project; (b) authorize rebidding of the Project within a reasonable time; (c) cancel the Project and terminate this Agreement in accordance with Paragraph 13; or (d) direct Architect to revise the Project scope and quality as required to reduce the construction cost. (6) If District chooses to proceed under item 5(d) above, Architect shall as part of Basic Services make any changes in plans and specifications necessary to bring new bids within ten percent (10%) of such estimated cost. The modification of the contract documents shall be the limit of Architect’s responsibility arising out of the estimate of probable construction cost. Architect shall be entitled to compensation in accordance with this Agreement for all services satisfactorily performed to date whether or not the Construction Phase is comme...
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Responsibility for Construction Costs. Subject to their respective Total Funding Commitments, Alpharetta shall contribute 50% and the County shall contribute 50% of the funding required for the local government share of the construction costs of Phase 1-A, which costs shall include environmental mitigation costs and utility relocation costs. Subject to their respective Total Funding Commitments, Xxxxx Creek shall contribute 50% and the County shall contribute 50%, of the funding required for the local government share of the construction costs of Phase 1-J, which costs shall include environmental mitigation costs and utility relocation costs. The construction funds shall be payable at times and in increments consistent with the payment schedule established with the prime construction contractor, mitigation bank, or utility company, as applicable.
Sample 1Sample 2
Responsibility for Construction Costs. Landlord will perform the Landlord Work, except that all costs attributable to Change Orders requested or approved by Tenant shall be payable by Tenant. Tenant agrees that Landlord may condition its consent to any Change Orders on Tenant's payment to Landlord of the increased cost of the Landlord Work, if any, as a result thereof prior to commencing such
Sample 1
Responsibility for Construction Costs. 5.2.1 Evaluations of the COUNTY’S Project budget, preliminary estimates of Construction Cost and detailed estimates of Construction Cost, if any, prepared by the ENGINEER, represent the ENGINEER’S best judgment as a design professional familiar with the construction industry. It is recognized, however, that neither the ENGINEER nor the COUNTY has control over the cost of labor, materials or equipment, over the Contractor’s methods of determining bid prices, or over competitive bidding, market or negotiating conditions. Accordingly, the ENGINEER cannot and does not warrant or represent that bids or negotiated prices will not vary from the COUNTY’S Project budget or from any estimate of Construction Cost or evaluation prepared or agreed to by the ENGINEER.
Sample 1
Responsibility for Construction Costs. Landlord and Tenant agree that Tenant shall be responsible for and shall pay for the full cost of the following construction items (collectively, "Tenant's Work") (subject to partial reimbursement by Landlord through Landlord's Contribution, as hereinafter defined) and shall cause the Tenant's Work to be completed in accordance with the approved plans in good and workmanlike condition and in compliance with all applicable laws: (a) All additional improvements necessary to complete the Premises, including, without limitation, interior improvements, demising partitions, exterior facade, all costs of bringing or increasing electrical service to the Premises, electrical distribution within the Premises, any roof top facilities (subject to Section 12.4 hereof) such as signage, antennae, dishes or masts, all other utility distribution such as phone, data, cable television service, natural gas, and sanitary and water (collectively, the "Tenant Improvements"); (b) All Base Building Construction for those areas of the Complex necessary to complete the Premises (whether located inside or outside the Premises), but expressly excluding therefrom the costs of constructing the New Tenant Space; (c) All Seismic Upgrades to the Complex, provided that Landlord shall reimburse tenant in an amount equal to 50% of the cost of the Seismic Upgrades to the First and Second Street retail/office elements of the Complex, subject to a maximum reimbursement of Five Hundred Thousand Dollars ($500,000); and (d) All foundation improvements required to accommodate Tenant's occupancy and use of the Premises, but excluding any foundation improvements required to accommodate the use and occupancy of the New Tenant Space (which shall be part of Landlord's Work). In connection with the construction of Tenant's Work, Tenant shall also be responsible for, and shall pay for the full cost of, all permits, City Approval costs, inspection fees and connection fees (except those directly associated with Landlord's Work), all life safety elements, including without limitation sprinklers, annunciation panels and fire alarm connections to Landlord's system, and all items required by applicable laws. Landlord shall be responsible for and shall pay for the full cost of constructing the New Tenant Space (collectively, "Landlord's Work") and shall cause the same to be completed in accordance with the approved plans in good and workmanlike condition and in compliance with all applicable laws. Landlord also a...
Sample 1
Responsibility for Construction Costs. 11 Section 6.4.
Sample 1
Responsibility for Construction Costs 
Sample 1
AutoNDA by SimpleDocs

Related to Responsibility for Construction Costs

  • Responsibility for Costs The Servicer is responsible for collection from such Borrower of any recording or similar costs or expenses incidental to the granting of relief with respect to a delinquent Mortgage Loan.

  • Responsibility for Charges 4.1 CBB shall be responsible for and pay to Verizon all charges for any Telecommunications Services provided by Verizon or provided by persons other than Verizon and billed for by Verizon, that are ordered, activated or used by CBB, CBB Customers or any other persons, through, by means of, or in association with, Telecommunications Services provided by Verizon to CBB pursuant to this Resale Attachment. 4.2 Upon request by CBB, Verizon will provide for use on resold Verizon retail Telecommunications Service dial tone lines purchased by CBB such Verizon retail Telecommunications Service call blocking and call screening services as Verizon provides to its own end user retail Customers, where and to the extent Verizon provides such Verizon retail Telecommunications Service call blocking services to Verizon’s own end user retail Customers. CBB understands and agrees that certain of Verizon’s call blocking and call screening services are not guaranteed to block or screen all calls and that notwithstanding CBB’s purchase of such blocking or screening services, CBB’s end user Customers or other persons ordering, activating or using Telecommunications Services on the resold dial tone lines may complete or accept calls which CBB intended to block. Notwithstanding the foregoing, CBB shall be responsible for and shall pay Verizon all charges for Telecommunications Services provided by Verizon or provided by persons other than Verizon and billed for by Verizon in accordance with the terms of Section 4.1 above.

  • Responsibility for Content Vendor is solely responsible for administration, content, intellectual property rights, and all materials at Vendor’s website. DIR reserves the right to require a change of listed content if, in the opinion of DIR, it does not adequately represent the Contract.

  • Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.

  • Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.

  • General Conditions Costs Contractor is entitled to receive payment for the actual cost of the allowable General Conditions items incurred after receipt of a Notice to Proceed with Construction from Owner through Substantial Completion of the Project, plus 30 calendar days. Contractor is not entitled to reimbursement for General Conditions Costs incurred before receipt of the Notice to Proceed. General Conditions Costs incurred after Substantial Completion, plus 30 calendar days, must be approved in advance by Owner. Allowable General Conditions items are identified below and in Exhibit “D” attached to this Agreement. These items shall be included in the General Conditions Cost amount shown as a line item in the Guaranteed Maximum Price Proposal and as detailed on the Schedule of Values. Items not specifically included below or in Exhibit “D” will not be allowed as General Condition Costs.

  • Responsibility for Damages Contractor is responsible for all damage that occurs as a result of Contractor’s fault or negligence or that of its’ employees, agents, or representatives in connection with the performance of this Contract. Contractor shall immediately report any such damage to people and/or property to the Contract Administrator.

  • Responsibility For Use (a) The Company alone will be responsible for furnishing, or arranging for a third party to furnish, all data and information required by the Documentation and the specifications therein for the Licensed System to function and perform in accordance with the Documentation, other than the data and information residing in the Licensed System in connection with BNYM’s performance of the Core Services. BNYM shall have no liability or responsibility for any Loss caused in whole or in part by the Company’s or a Permitted User’s exercise of the Licensed Rights or use of the Licensed System or by data or information of any nature inputted into the Licensed System by or under the direction or authorization of Company or a Permitted User; provided, however, this Section 2.5 shall not relieve BNYM of its obligation to act in accordance with its obligations under the Main Agreement. Company shall be responsible and solely liable for the cost or expense of regenerating any output or other remedial action if the Company, a Permitted User or an agent of either shall have failed to transmit properly and in the correct format any data or information, shall have transmitted erroneous or incorrect information or data, or shall have failed to timely verify or reconcile any such data or information when it is generated by the Licensed System (“Data Faults”).

  • Responsibility for Damage Resident is solely responsible for any damage, defacement or loss arising within the assigned bedroom space. All assigned residents of an apartment are jointly and severally responsible for any damage, defacement or loss to common areas, other parts of the Property, fixtures or appliances, except for the portion of damages over $100,000 where it is finally established that Resident or one or more other residents of the apartment were solely at fault for the entire loss, in which case such person(s) will be solely responsible. Resident is fully responsible for the conduct of Resident’s guests, visitors, licensees and invitees (“Guests”), including without limitation harm to individuals or damage or defacement of any part of the Property or its fixtures or property of third parties (including other residents) by such Guests.

  • ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!