Construction by the Lessee Sample Clauses

Construction by the Lessee. Use this paragraph if the Lessee is not permitted to do construction work: During the Term of this Lease, and any renewal, extension or holdover thereof, if the Lessee desires any additional work to be performed in the Demised Premises, it shall make a request for the same by submitting a Tenant Alteration Request form (hereinafter referred to as a “TAR”) to the Lessor, in accordance with the directions on the TAR. The TAR and instructions on how to complete it can be found on the OGS website at xxxxx://xxx.xx.xxx/tenant-alteration- request-tar-101-form. If the State determines that the requested work will be done, it will cause the same to be performed in a timely manner, at the Lessee’s sole cost and expense. The Lessee will be solely responsible to pay the State, as additional rent, the cost of all work performed under this section within thirty (30) days of receipt of an invoice of the same. In the event any construction, improvement, alteration, modification, addition, repair or replacement is made without the State’s consent, then the State shall remove or change such work to the reasonable satisfaction of the State, and the Lessee shall pay the cost thereof to the State, as additional rent, on demand. Use a-b below if the Lessee is permitted to do construction work:
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Construction by the Lessee. (a) Except as provided in paragraphs (i) and (j) of this Section, the Lessee shall not erect any structures, make any modifications, alterations, additions, improvements, repairs or replacements or do any construction work on or to the premises, or install any fixtures in or on the premises (other than trade fixtures, removable without substantial injury to the premises) without the prior consent of the Port Authority, which shall not be arbitrarily and capriciously withheld, and the Port Authority shall not withhold such Consent except for reasons of safety, health, operational utility, impact on or compatibility of the proposed work on building systems, or other parts of the World Trade Center, or unless the proposed work, in the opinion of the Port Authority's Chief Engineer, acting in a non-arbitrary and non-capricious manner, shall fail to comply with (i) all governmental laws, ordinances, enactments, resolutions, rules and orders, including, without limitation, the enactments, ordinances, resolutions, and regulations of the City of New York and its various Departments, Boards and Bureaus that are applicable, or which would be applicable if the Port Authority were a private corporation, or (ii) all applicable requirements of the Port Authority's Tenant Construction Review Manual (hereinafter called the "Tenant Design Guide") issued by the Port Authority Engineering Department dated March, 1984, revised March, 1990, together with Amendment No. 1 dated October 1990 (as the same may be further amended in a non-arbitrary and non-capricious manner prior to the date the Lessee submits its plans and specifications) (the foregoing requirements in clauses (i) and (ii) hereinafter in this Agreement called the "Standards"). Except as provided below in this paragraph (a), any construction, improvement, alteration, modification, addition, repair or replacement made by or on behalf of Lessee, whether prior to or during the term, shall become the property of the Port Authority (subject to Lessee's right to use the same during the term of this Agreement and, to remove, modify, alter, improve, repair or replace the same in connection with construction and installation work performed in accordance with this Section 12 or otherwise in connection with the performance of Lessee's rights and obligations under this Agreement, provided, that any such removal, modification, alteration, improvement, repair or replacement shall be made in accordance with the applicable provisio...
Sample 1
Construction by the Lessee. The Lessee shall not erect any structures, make any modifications, alterations, additions, improvements, repairs or replacements or do any construction work on or to the premises, or install any fixtures in or on the premises (other than trade fixtures, removable without injury to the premises) without the prior consent of the Port Authority which consent will not be exercised arbitrarily, and in the event any construction, improvement, alteration, modification, addition, repair or replacement is made or done with or without such consent and unless the consent of the Port Authority shall expressly provide otherwise, the same shall immediately become the property of the Port Authority and the Lessee shall have no right to change or remove the same either during the term or at the expiration thereof. Notwithstanding the foregoing, immediately upon notice from the Port Authority given at any time during the letting, the Lessee shall remove or change any of the same made or done by it without the Port Authority's consent, and in the case of any of the same made or done with the Port Authority's consent, the Lessee if so required by notice from the Port Authority, shall remove or change the same immediately upon the expiration or termination of the letting, or immediately upon receipt of such notice as may be given within sixty (60) days after such expiration or termination provided, however, that if the Lessee so requests by written notice given to the Port Authority not earlier than one hundred twenty (120) days prior to, nor later than sixty (60) days after the expiration of the term of the letting, the Port Authority within thirty (30) days after receipt of such notice will notify the Lessee as to which construction, improvement, alteration, modification, repair or replacement made by the Lessee has to be removed or changed. With respect to any modifications, additions, alterations, improvements, installations or construction made or done by the Port Authority at the request of the Lessee either prior to or during the term of the letting, the Lessee shall have the same obligations as provided above with respect to that made or done by the Lessee with the Port Authority's consent.
Sample 1
Construction by the Lessee. The Lessee shall not erect any structures, make any modifications, alternations, additions, improvements, repairs or replacements or do any construction work on or to the premises, or install any fixtures in or on the premises (other than trade fixtures, removable without injury to the premises) without the prior consent of the Port Authority, and in the event any construction, improvement, alternation, modification, addition, repair or replacement is made or done with or without such consent and unless the consent of the Port Authority shall expressly provide otherwise, the same shall immediately become the property of the Port Authority and the Lessee shall have no right to change or remove the same either during the term or at the expiration thereof. Notwithstanding the foregoing, immediately upon notice from the Port Authority given at any time during the letting, the Lessee shall remove or change any of the same made or done by it without the Port Authority's consent, and in the case of any of the same made or done with the Port Authority's consent, the Lessee if so required by notice from the Port Authority, shall remove or change the same immediately upon the expiration or termination of the letting, or immediately upon receipt of such notice as may be given within sixty (60) days after such expiration or termination. With respect to any modifications, additions, alterations, improvements, installations or construction made or done by the Port Authority at the request of the Lessee either prior to or during the term of the letting, the Lessee shall have the same obligations as provided above with respect to that made or done by the Lessee with the Port Authority's consent.
Sample 1
Construction by the Lessee. The Lessee shall not erect any structures, make any modifications, alterations, additions, improvements, repairs or replacements or do any construction work on or to the premises, or install any fixtures in or on the premises (other than trade fixtures, removable without injury to the premises) without the prior consent of the Port Authority, and in the event any construction, improvement, alteration, modification, addition, repair or replacement is made or done with or without such consent and unless the consent of the Port Authority shall expressly provide otherwise, the same shall immediately become
Sample 1
Construction by the Lessee. (a) The following terms, when used in this Agreement, shall, unless the context shall require otherwise, have the respective meanings given below:
Sample 1
Construction by the Lessee. (a) The Lessee shall, prior to its submission to the Port Authority of the plans and specifications hereinafter provided for, submit to the Port Authority for its consent, the Lessee's comprehensive plan for the development of the site, including but not limited to renderings, layouts, locations, models, estimated commencement and completion dates, and preliminary functional plans.
Sample 1
AutoNDA by SimpleDocs
Construction by the Lessee 
Sample 1

Related to Construction by the Lessee

  • Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.

  • Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

  • Budget For Tenant Improvements A preliminary detailed breakdown by trade of the costs incurred or that will be incurred in connection with the design and construction of the Tenant Improvements is set forth on Schedule 3 attached hereto (the “Budget”). The Budget is based upon the TI Construction Drawings approved by Tenant and shall include a payment to Landlord of administrative rent (“Administrative Rent”) equal to 1.5% of the TI Costs, which Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with monitoring the construction of the Tenant Improvements and Changes, and shall be payable out of the TI Fund. Landlord shall provide Tenant with a final Budget promptly following approval of the TI Construction Drawings by Landlord and Tenant. The Budget shall be subject to Tenant’s review and approval which approval shall not be unreasonably withheld, conditioned or delayed by Tenant. Tenant shall have the right to approve any use of the contingency in the Budget by Landlord; provided, however, that, Tenant’s approval shall not be unreasonably withheld, conditioned or delayed, and the contingency shall not be available for use by Tenant for any Changes until all unforeseen conditions, changes to resulting from governmental agencies and the like have first been paid for out of the contingency.

  • Construction of Improvements (A) Lessee warrants and agrees that the Building will be constructed on the Leased Premises, and all other improvements to the land, including the parking lot, approaches, and service areas, will be constructed in all material respects by Lessee substantially in accordance with the plot, plans, and specifications heretofore submitted to Lessor.

  • CONSTRUCTION OF PREMISES Landlord will diligently perform “Landlord’s Work” and Tenant will diligently perform “Tenant’s Work” (if any) as described in the Workletter attached as Exhibit “F” in accordance with the Workletter and the rest of this Lease. Landlord’s Work will be deemed substantially completed even if Landlord has not completed “punch list” or other minor items, as long as (i) Landlord agrees to use reasonable efforts to complete these items within thirty (30) days of signing the punch-list, excluding any items which require special materials or equipment that are unavailable; and (ii) the punch-list items can be completed after Tenant’s occupancy without causing substantial interference with Tenant’s use of the Premises. Tenant’s final punch list will be submitted to Landlord with in fifteen (15) days after Landlord notifies Tenant that Landlord’s Work is substantially completed. Substantial completion of Landlord’s Work will be deemed to have occurred on the earlier of: the date as of which Landlord’s architect certifies in good faith that Landlord’s Work has been substantially completed in substantial conformance with the plans and specifications therefore (or the date as of which such substantial completion would have occurred but for any delays or Tenant’s Work for which Tenant is responsible); or the date that the applicable governmental authorities issue a temporary or final certificate of occupancy for the Premises (or the date as of which such a certificate of occupancy reasonable could have been issued but for any delays or Tenant’s Work for which Tenant is responsible). If and as long as Tenant does not interfere in any way with the construction process (by causing disharmony, scheduling or coordinating difficulties, etc.) Tenant, may, at Tenant’s sole risk and expense, enter the Premises 30 days prior to the substantial completion of Landlord’s Work (“Early Access Period”) for the purposes of installing Tenant’s decorations, movable furniture and business fixtures. The determination of such interference by Landlord shall be conclusive. The Early Access Period shall commence upon Tenant’s receipt of Landlord’s notice of same. For the time period commencing on the date that Landlord’s Work is substantially complete and ending on the date that is ten days after such substantial completion (the “Fixture Period”), Tenant shall have the right to access the Premises for the purposes of installing its furniture, fixtures, audio/visual, security, and other equipment Any access by Tenant prior to the Lease Commencement Date shall be subject to all the terms and conditions of this Lease, except that Tenant shall not be obligated to pay rent during the Fixture Period.

  • Construction of Hotel (i) To Seller’s knowledge, the Hotel has been constructed in a good and workmanlike manner without encroachments except as noted on the Survey and in accordance in all material respects with the Construction Plans. To Seller’s knowledge, the Hotel has received all building permits and certificates of occupancy necessary for the operation thereof, and is in compliance with applicable zoning, platting, subdivision, health, safety and similar laws, rules, regulations, ordinances and codes.

  • Delay of the Substantial Completion of the Premises Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!