CONSTRUCTION REVIEW. For projects involving construction, Owner acknowledges that under generally accepted professional practice, interpretations of construction documents in the field are normally required, and that performance of construction-related services by the design professional for the project permits errors or omissions to be identified and corrected at comparatively low cost. Owner agrees to hold Consultant harmless from any claims resulting from performance of construction-related services by persons other than Consultant.
CONSTRUCTION REVIEW. The Independent Tester shall: Visit the Site and monitor the Works for their compliance with the Authority's Construction Requirements, Project Co’s Proposals and the Approved RDD.25 The frequency and timing of the Independent Tester's visits are dependent on the progress of construction on Site. The Contractor shall agree a programme with the Independent Tester for the inspection of key construction processes and the completed [Phases of the] Works and shall give the Independent Tester advance notice of these Works being carried out on Site. The Independent Tester shall identify any aspect of the Works which needs to be inspected before being covered over by subsequent activity so that he may satisfy himself that these have been constructed in accordance with the Contractor's Quality Plan without the need for opening up. Randomly check that the Works are being undertaken in accordance with the Construction Quality Plan that has been agreed by the Authority and Project Co. Review the written Mechanical and Electrical engineering services testing and commissioning procedure. Undertake selective witnessing of the Mechanical and Electrical services testing and commissioning. The Independent Tester has indicated that these sampling proportions should amount to approximately [fifty] percent [(50%)]. The Independent Tester shall review [one hundred] percent [(100%)] of all test results. If in the professional judgment of the Independent Tester, because of the results of witnessing (or because of other circumstances) a different sampling percentage is appropriate he shall provide a detailed report in respect of that and any change in the percentage sampling resulting in a change of fees will be borne by Project Co, the Authority or the Contractor as they shall agree, failing such agreement, as determined by the Dispute Resolution Procedure. Inspect rectification works which have previously prevented the Independent Tester from certifying the Project as complete. Concurrent with the issue of the Certificate of Practical Completion, agree a list of Snagging Matters with the Authority and Project Co together with its programme for implementation and issue a Snagging Notice in accordance with Clause 18 of the Design Build Finance and Maintain Agreement. Check the production of the relevant operating manuals, relevant approvals, test results, inspection records and as built drawings and monitor the timely handover of this documentation.
CONSTRUCTION REVIEW. A. The Engineer will periodically observe the construction of all work covered by this Contract. The Engineer, on behalf of the Owner, shall be authorized to determine the amount or quantities of the several items of work which are to be paid for under this Contract; to order field changes within the scope of the Contract and to render decisions on any questions which may arise relative to the execution of the work covered by this Contract. The Engineer does not have authority to suspend work on the project. The Trade Contractor shall not suspend any portion of the work nor resume suspended work without the written authority of the Owner.
B. Neither Engineer's authority to act under the Contract nor any decision made by Engineer in good faith either to exercise or not exercise such authority shall give rise to any duty or responsibility of the Engineer to the Trade Contractor, any subcontractor, any supplier, or any other person or organization performing any of the Work, or to any surety for any of them.
C. Whenever in the drawings, plans or Contract Documents the terms "as ordered", "as directed", or the adjectives "reasonable", "suitable", "acceptable", "proper" or "satisfactory" or adjectives of like effect or import are used to describe a requirement, direction, review or judgment of Engineer as to the work, it is intended that such requirement, direction, review or judgment will be solely to evaluate the work for compliance with the contract documents. The use of any such term or adjective shall not be effective to assign to Engineer any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or authority to undertake responsibility for the project. Neither the Owner nor the Engineer will be responsible for the acts or omissions of Contractor or any Subcontractor, any Supplier, or of any other person or organization performing or furnishing any of the Work.
D. Periodic observation of the work in progress by the Engineer will be done whenever the Contractor is performing work that requires review as determined by the Engineer. The normal working time shall be during a regular 5-day, 40-hour work week, Monday through Friday. If the Trade Contractor elects to work more than 40 hours per week and observation is required during this overtime work as determined by the Engineer, the Engineer shall be paid by the Trade Contractor at the rate as specified herein for all review time required over the normal 5-day, 40-hour...
CONSTRUCTION REVIEW. The Consultant shall review and make recommendations upon the following:
a. Construction schedules from each contractor.
b. Payment requisitions from each contractor for each fiscal share of the project.
CONSTRUCTION REVIEW. The Manager shall maintain efficient supervision of the Work. The Manager shall evaluate the Work being performed at each Approved Project in light of the plans and specifications for such Approved Project. Following a request by the County, the Manager shall promptly upload to the Project Dataroom any documents or information requested by the County’s Authorized Representative relating to or concerning the development or construction of an Approved Project. The County’s monitoring and review, as set forth above, shall not in any way be construed as relieving the Manager of any of its obligations, responsibilities or liabilities under this Agreement.
CONSTRUCTION REVIEW a. Construction schedules from each contractor.
b. Payment requisitions from each contractor for each fiscal share of the Project.
c. Requests of the Contractor for interpretation of the Contract Documents.
d. Claims by each contractor.
e. Contractor requests regarding proposed changes to the contract documents.
f. Change orders including recommendations
g. Construction schedules and proposed work locations of any contractor.
CONSTRUCTION REVIEW. 1. Before Project construction begins, Mn/DOT and Wis/DOT shall meet with the construction contractor to ensure that construction plans are consistent with the approved Project design.
2. During construction, Mn/DOT and Wis/DOT shall monitor Project construction and shall provide a record of those monitoring activities in the Annual Report prepared pursuant to Stipulation IX.
3. Mn/DOT shall identify a point of contact to be responsible for responding to inquiries and complaints from the public regarding historic preservation issues that arise during the implementation of the terms of this Amended MOA.
CONSTRUCTION REVIEW. Architect does not accept responsibility for the design of a construction project unless the Architect's contract includes review of the contractor's shop drawings, product data, and other documents, and includes site visits during construction in order to ascertain that, in general, the work is being performed in accordance with the construction contract documents.
CONSTRUCTION REVIEW. Construction Review by ENGINEER does not constitute a warranty or guarantee of any type. Construction contractors engaged by CLIENT shall be fully responsible for the quality of their own work and for adhering to the plans and specifications. ENGINEER shall not be responsible for the supervision and management of the work forces of the constructors, including the construction means, methods, techniques, sequences or safety procedures employed by the constructors to complete the work. CLIENT and CLIENT’S constructors shall promptly report to ENGINEER any alleged defects in the Work in order that ENGINEER may take prompt measures to remedy such alleged defects. ENGINEER may recommend to CLIENT the rejection of any Work that does not conform with ENGINEER’S recommendations, specifications or design.
CONSTRUCTION REVIEW. DELETE and REPLACE this subsection with the following:
