Delays in Contractor’s Progress Sample Clauses

Delays in Contractor’s Progress. A. If Owner, Engineer, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in the Contract Times and Contract Price. Contractor’s entitlement to an adjustment of the Contract Times is conditioned on such adjustment being essential to Contractor’s ability to complete the Work within the Contract Times. B. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delay, disruption, or interference caused by or within the control of Contractor or their subcontractors or suppliers. C. If Contractor’s performance or progress is delayed, disrupted, or interfered with by unanticipated causes not the fault of and beyond the control of Owner, Contractor, and those for which they are responsible, then Contractor shall be entitled to an equitable adjustment in Contract Times. D. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for any delay, disruption, or interference if such delay is concurrent with a delay, disruption, or interference caused by or within the control of Contractor or Contractor’s subcontractors or suppliers.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Delays in Contractor’s Progress. ‌ A. If Owner, Engineer, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in Contract Price or Contract Times. B. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delay, disruption, or interference caused by or within the control of Contractor. Delay, disruption, and interference attributable to and within the control of a Subcontractor or Supplier shall be deemed to be within the control of Contractor. C. If Contractor’s performance or progress is delayed, disrupted, or interfered with by unanticipated causes not the fault of and beyond the control of Owner, Contractor, and those for which they are responsible, then Contractor shall be entitled to an equitable adjustment in Contract Times. Such an adjustment will be Contractor’s sole and exclusive remedy for the delays, disruption, and interference described in this paragraph. Causes of delay, disruption, or interference that may give rise to an adjustment in Contract Times under this paragraph include but are not limited to the following: 1. Severe and unavoidable natural catastrophes such as fires, floods, epidemics, and earthquakes; 2. Abnormal weather conditions; 3. Acts or failures to act of third-party utility owners or other third-party entities (other than those third-party utility owners or other third-party entities performing other work at or adjacent to the Site as arranged by or under contract with Owner, as contemplated in Article 8); and 4. Acts of war or terrorism. D. Contractor’s entitlement to an adjustment of Contract Times or Contract Price is limited as follows: 1. Contractor’s entitlement to an adjustment of the Contract Times is conditioned on the delay, disruption, or interference adversely affecting an activity on the critical path to completion of the Work, as of the time of the delay, disruption, or interference. 2. Contractor shall not be entitled to an adjustment in Contract Price for any delay, disruption, or interference if such delay is concurrent with a delay, disruption, or interference caused by or within the control of Contractor. Such a concurrent delay by Contractor shall not preclude an adjustment of Contract Times to which Contractor is otherwise entitled. 3. Adjustments of Contract Times or Contract Price are subject to the provisions of Article 11. E. Each Contractor request or Change Proposal s...
Sample 1
Delays in Contractor’s Progress. A. If Owner, Facilities Manager, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in the Contract Times as its sole remedy. Contractor’s entitlement to an adjustment of the Contract Times is conditioned on such adjustment being essential to Contractor’s ability to complete the Work within the Contract Times. B. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delay, disruption, or interference caused by or within the control of Contractor or their subcontractors or suppliers. C. If Contractor’s performance or progress is delayed, disrupted, or interfered with by unanticipated causes not the fault of and beyond the control of Owner, Contractor, and those for which they are responsible, then Contractor shall be entitled to an equitable adjustment in Contract Times as its sole remedy. D. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for any delay, disruption, or interference if such delay is concurrent with a delay, disruption, or interference caused by or within the control of Contractor or Contractor’s subcontractors or suppliers. E. Contractor will be allowed delays for weather conditions, based on the concurrence of Contractor and Owner or Facilities Manager, for two circumstances: 1. Isolated inclement weather, wherein the project Site is determined to be unworkable for days of precipitation and days following for short times between otherwise good weather. 2. Sustained inclement weather, wherein the project Site is determined to be unworkable for a sustained period of time, such as the winter months, with only an occasional working day within the sustained unworkable conditions. F. If Contractor believes either condition applies, a request shall be made to Facilities Manager or Owner for a Site meeting and a joint determination of the Site conditions and approval of the delay. Facilities Manager will catalog these approved delays and will incorporate them into a Change Order for signature of Owner and Contractor.
Sample 1
Delays in Contractor’s Progress. A. If Owner, Engineer, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in the Contract Times or Contract Price. B. The contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delay, disruption, or interference caused by or within the control of Contractor or its subcontractors or suppliers. C. If Contractor’s performance or progress is delayed, disrupted, or interfered with by unanticipated causes not the fault of and beyond the control of Owner, Contractor, and those for which they are responsible, then Contractor shall be entitled to an equitable adjustment in Contract Times. D. Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for any delay, disruption, or interference if such delay is concurrent with a delay, disruption, or interference caused by or within the control of Contractor or Contractor’s subcontractors or suppliers.
Sample 1
Delays in Contractor’s Progress. A. Liquidated Damages 1. Contract time is governed by out-of-service time. 2. On tank projects, date of substantial completion is the date the tank is or would have been returned to service, except for voluntary delay by Owner. Date of substantial completion is after complete cure, disinfection, and testing. A voluntary delay in filling by Owner, or delay that is no fault of the Contractor may extend Substantial Completion date. 3. Abnormal weather conditions are defined as weather conditions that are at variance with the routine. An example of the determination procedure and of the required claim format is: Project length: 45 days Substantial completion date: June 30th. Start date: May 16th. 3 years of data* 2018, 2019, 2020 Average number of rain/wind days: 9 Actual number of rain/wind days**: 12 Claim for time extension: 3 days 4. Submit weather history from nearest weather reporting station for three (3) previous years from the same time period. Submit formal, by simple claim (use format above). 5. Rain/wind day is a rain or wind day where either rain and/or wind conditions exceeded safe Work conditions or were outside the parameters of good paint practices. Wind days are winds in excess of 20 mph for over four (4) hours during normal Work hours, and rain days having measurable precipitation. 6. Weather Claim Evaluation: Engineer will evaluate claim and make sole determination as to whether days meet criteria. Engineer will disallow dates where Work could have been completed on the interior; dates that result from the Contractor’s Work practices (i.e. complete wet interior first and then move to exterior). Good weather days not used will count against claim. 7. Claimed rain/wind days that occur after the scheduled Substantial Completion Date or an extended Substantial Completion Date will not be awarded. Days past Substantial Completion and good weather days that were not used for Productive Work will be considered “days within the control of the Contractor.”
Sample 1
Delays in Contractor’s Progress. If County, Engineer, or anyone for whom County is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor may be entitled to an equitable adjustment in the Contract Times or Contract Price.
Sample 1
Delays in Contractor’s Progress 
Sample 1
AutoNDA by SimpleDocs

Related to Delays in Contractor’s Progress

  • Contractor’s Employees and Subcontractors (a) Contractor shall only disclose PII to Contractor’s employees and subcontractors who need to know the PII in order to provide the Services and the disclosure of PII shall be limited to the extent necessary to provide such Services. Contractor shall ensure that all such employees and subcontractors comply with the terms of this DPA. (b) Contractor must ensure that each subcontractor performing functions pursuant to the Service Agreement where the subcontractor will receive or have access to PII is contractually bound by a written agreement that includes confidentiality and data security obligations equivalent to, consistent with, and no less protective than, those found in this DPA. (c) Contractor shall examine the data security and privacy measures of its subcontractors prior to utilizing the subcontractor. If at any point a subcontractor fails to materially comply with the requirements of this DPA, Contractor shall: notify the EA and remove such subcontractor’s access to PII; and, as applicable, retrieve all PII received or stored by such subcontractor and/or ensure that PII has been securely deleted and destroyed in accordance with this DPA. In the event there is an incident in which the subcontractor compromises PII, Contractor shall follow the Data Breach reporting requirements set forth herein. (d) Contractor shall take full responsibility for the acts and omissions of its employees and subcontractors. (e) Contractor must not disclose PII to any other party unless such disclosure is required by statute, court order or subpoena, and the Contractor makes a reasonable effort to notify the EA of the court order or subpoena in advance of compliance but in any case, provides notice to the EA no later than the time the PII is disclosed, unless such disclosure to the EA is expressly prohibited by the statute, court order or subpoena.

  • Sub-Contractors Transfer Agent may, without further consent on the part of Customer, subcontract with other subcontractors for telephone and mailing services as may be required from time to time; provided, however, that the Transfer Agent shall be as fully responsible to the Customer for the acts and omissions of any subcontractor as it is for its own acts and omissions.

  • Contractor’s Personnel The Contractor shall employ only personnel who are appropriately qualified, skilled and experienced in their respective trades or occupations. The Authority may require the Contractor to remove any personnel engaged for the Works, who in the opinion of the Authority: (a) has engaged in any misconduct; (b) is incompetent or negligent in the performance of his duties; (c) fails to conform with any provisions of the Contract; (d) engages in any conduct which is prejudicial to safety, health, or the protection of the environment; or (e) makes errors in the discharge of his functions. If appropriate and required by the Employer, the Contractor shall then appoint (or cause to be appointed) a suitable replacement person.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!