Warranty Claim Sample Clauses
Warranty Claim. 5.1 The ‘Buyer’ shall notify or contact, within 1 month, their ‘Reseller’ or LG Energy Solution if the purchased or installed ‘Products’ are found to be defective, damaged and/or when the quality-related problems occur by using the Contact point in Article 10.
5.2 If the ‘Buyer’ intends to raise a claim due to the quality defect of the ‘Products’ pursuant to Articles 3 or 4 , the ‘Buyer’ shall provide LG Energy Solution with the following information.
(1) Dated proof of purchase from authorized RESU sales channel For authorized RESU sales channel information, ‘Reseller’ or ‘Buyer’ can visit the Battery Website of LG Energy Solution by the URL below and check the ‘Home Battery’ > ‘Where to Buy’.
(2) Description of defects, symptoms and when it occurred
(3) Product(s) serial number (The ‘Products’ have 3 serial numbers.)
a) Battery Module #1
b) Battery Module #2
c) BCU (Battery Control Unit)
(4) Further information requested by LG Energy Solution to determine the defect and its cause (for example, error code, description of defect and other information)
(5) ‘Certified Installer’ or ‘Reseller’ name, company name and company address
5.3 LG Energy Solution shall identify the defect notified by the ‘Buyer’, and repair or replace if the defect would be covered by the Product Warranty set out in article 3 or the Performance Warranty set out in article 4 in accordance with the terms of this Warranty.
Warranty Claim. User must notify Seller in writing of any warranty claim promptly after it becomes aware of the failure of any Product or Service to conform to this Warranty Policy. Unless otherwise provided herein or instructed by Seller when making a warranty claim, User will obtain a Return Material Authorization number from Seller and return the Product to Seller at User’s expense. User must also provide any information, documentation and materials requested by Seller when making a warranty claim, which may include proof of purchase and serial number. If User purchased the Product from a distributor, Seller may require User to make a warranty claim with such distributor instead of to Seller.
Warranty Claim. Any claim by any Contributor Indemnified Party or any OP Indemnified Party pursuant to Section 8(a) with respect to a claimed breach by the Operating Partnership or the Contributor of a representation or warranty (a "Warranty Claim") shall expire at the OP Claim Termination Date or the Contributor Claim Termination Date, as applicable, unless prior thereto, the party making a claim hereunder has delivered written notice to the other party. If any written notice of claim has been given by any OP Indemnified Party to Contributor prior to the OP Claim Termination Date or by any Contributor Indemnified Party to the Operating Partnership prior to the Contributor Claim Termination Date, then the relevant representations, warranties and indemnities shall survive the OP Claim Termination Date or Contributor Claim Termination Date, as applicable, as to (but only as to) such Warranty Claim, until such Warranty Claim has been finally resolved.
Warranty Claim. 5.1 The Buyer shall notify or contact, within 1 month, their Reseller or LG Energy Solution if the purchased or installed Products are found to be defective, damaged and/or when the quality-related problems occur by using the Contact point in Article 10.
5.2 If the Buyer intends to raise a claim due to the quality defect of the Products pursuant to Articles 3 or 4 , the Buyer shall provide LG Energy Solution with the following information.
(1) Dated proof of purchase from authorized RESU sales channel For authorized RESU sales channel information, Reseller or Buyer can visit the Battery Website of LG Energy Solution by the URL below and check the ‘Home Battery’ > ‘Where to Buy’. xxxxx://xxx.xxxxxxxxxxxx.xxx/eu (All European Countries) xxxxx://xxx.xxxxxxxxxxxx.xxx/it (Italy) xxxxx://xxx.xxxxxxxxxxxx.xxx/es (Spain) (2) Description of defects, symptoms and when it occurred
(3) Product(s) serial number (The Products have each serial numbers.)
(4) a) Battery Module #1 b) Battery Module #2
Warranty Claim. 5.1 The Buyer shall notify or contact, within 1 month, their Reseller or LG Energy Solution if the purchased or installed Products are found to be defective, damaged and/or when the quality-related problems occur by using the Contact point in Article 10.
5.2 If the Buyer intends to raise a claim due to a potential quality defect of the Products pursuant to Articles 3 or 4 , the Buyer shall provide LG Energy Solution with the following information.
(1) Dated proof of purchase from authorized RESU sales channel For authorized RESU sales channel information, Reseller or Buyer can visit the Battery Website of LG Energy Solution by the URL below and check the ‘Home Battery’ > ‘Where to Buy’. xxxxx://xxx.xxxxxxxxxxxx.xxx/eu (All European Countries) xxxxx://xxx.xxxxxxxxxxxx.xxx/it (Italy) xxxxx://xxx.xxxxxxxxxxxx.xxx/es (Spain) (2) Description of potential defects, symptoms and when they occurred
(3) Product(s) serial number (The Products have each serial numbers.)
a) RESU FLEX 8.6 : Battery Module #1~#2, BPU(Battery Protection Unit)
b) RESU FLEX 12.9 : Battery Module #1~#3, BPU(Battery Protection Unit)
c) RESU FLEX 17.2 : Battery Module #1~#4, BPU(Battery Protection Unit)
(4) Further information requested by LG Energy Solution to determine the potential defect and its cause (for example, error code, description of potential defect and other information)
(5) The name, company name and company address of the Certified Installer and/or the Reseller
5.3 LG Energy Solution shall identify the defect notified by the Buyer, and repair or replace if the defect is covered by the Product Warranty set out in Article 3 or the Performance Warranty set out in Article 4 in accordance with the terms of this Warranty.
Warranty Claim. To make a claim or for service under this Limited Warranty, you must notify Ambient in writing, providing the date of claim, contact information of claimant, address of installation, installer’s contact information, description of the product involved, and nature of the defect at xxxx@xxxxxxxxx.xxx. At Ambient’s sole option, Ambient may retain the services of, or require the claimant to retain the services of, as a condition of warranty coverage, an inspector to examine the Product and its installation. Such inspection, if requested by Ambient, must take place within the earlier of: (1) sixty (60) days after the claimant becomes aware of the subject condition, or (2) forty five (45) days after Ambient is informed of the subject condition. The findings of the inspection shall not be binding on Ambient or dispositive of any warranty dispute, but if the inspection finds that a defect exists in the Product within the scope of this Limited Warranty, Ambient may reimburse the claimant for the commercially reasonable cost of the inspection, in addition any other remedy, at its sole discretion, that may arise under the Limited Warranty. This Limited Warranty shall be interpreted under and by the laws of the State of Maryland, excluding conflicts of law provisions. Any action to enforce or interpret the terms of this Limited Warranty shall be brought exclusively in the courts of the State of Maryland (or the counties thereof) sitting in Howard County, Maryland, or (to the extent the requirements of federal court jurisdiction are satisfied) in the courts of the United States sitting in the State of Maryland, and by accepting delivery of the Product the customer and/or end user consents to the exclusive jurisdiction and proper venue of such courts.
Warranty Claim. Xxxxx’s right in the event of any Product flaws and defects on the basis of the principles specified in these GWC.
Warranty Claim. 7.1 Unless expressly stipulated in the Sales Contract, the Seller makes no warranty or condition, expressly or impliedly, as to the fitness or suitability of the goods for any particular or use or the merchantability thereof.
7.2 If any warranty exists, the Seller’s liability shall be limited to the replacement or repair of the defective Goods.
7.3 Any claim by the Buyer of whatever nature arising under or in relation to the Sales Contract shall be made by registered airmail within thirty (30) days after the arrival of the Goods at the port of destination, or solely with respect to claims alleging the existence of a latent defect of the Goods, within six (6) months after the arrival of the Goods at the port of destination, and any such claims shall contain full particulars with evidence certified by an authorized surveyor.
Warranty Claim. Any claim under this Direct Warranty is subject to you notifying Aegex or an Aegex authorized service company of the defect within a reasonable time of it having come to your attention and in any event no later than before the expiration of the Warranty Period. When making a claim under this Direct Warranty you will be required to provide all of the following:
1. Full details for device exchange:
a) Contact Name b) Company Name
c) Postal Address d) ZIP/Postal Code e) Country
f) Phone Number
g) Email address for shipment tracking and correspondence
2. The Product information required:
a) Model Part Number
b) Serial Number
c) Proof of Purchase
d) Detailed description of the defect This information is mandatory to create an RMA for your claim. Failure to submit all requested information may result in delays to issue your RMA.
Warranty Claim. 22.1 A defect shall only be subject to warranty specified in the commercial offer.
22.2 A warranty claim must be raised by Customer within fourteen (14) Days after the defect has or could have become reasonably apparent and the Contractor must be provided at the Site with the defective part for inspection and repair within additional thirty (30) Days after the warranty claim has been raised. If a defect arises on a non- removable part of the Aircraft, the Parties shall in good faith agree how to remedy such defect in a way convenient for customer and reasonably acceptable for the Contractor.
22.3 The Contractor shall correct any defect covered by this warranty at its own cost and expense at the Site or at any other place Customer and Contractor may agree upon from time to time. If the Customer requests the Contractor to correct the defect of a Component at another location as the Site, the Customer shall arrange at its own risk and expense for the removal and transport of the defective Components to and from the location where the repair shall be made and for the reinstallation of the respective Component.
22.4 If the Customer, after prior written authorization of the Contractor, have the defects subject to this warranty repaired or rectified by a third party, the Contractor: - Will reimburse all direct costs (labour and accessories) and expenses reasonably incurred by Customer in connection with any such repair or rectification; and - Shall be authorized by the maintenance organisation responsible for such repair or rectification, to have a representative on site who will have access to any documentation established in relation to such repair or rectification; and - Will not be liable in relation to the workmanship of such repair or rectification.
22.5 The works performed by the Contractor are exclusively warranted against any defect attributable to the labour which appears within twelve (12) months or one thousand five hundred (1500) operating hours (whichever is reached first) after the date XXXXXXX INDUSTRY returns the equipment to the Customer.
22.6 Regarding Maintenance Services, Contractor’s warranty shall be excluded (i) if the defect has been caused because the Maintenance Object has been altered, overhauled or repaired during the warranty period by any party other than the Contractor, or (ii) if the Customer has not taken all reasonable precautions to prevent an aggravation of the defect or damage, or (iii) if the Customer does not comply with o...