CLAUSES APPLICABLE TO ALL PURCHASE ORDERS Sample Clauses

CLAUSES APPLICABLE TO ALL PURCHASE ORDERS. FAR 52.202-1 Definitions (July 2004) FAR 52.203-3 Gratuities (April 1984) FAR 52.203-5 Covenant Against Contingent Fees (April 1984) FAR 52.203-8 Cancellation, rescission or recovery of funds for illegal or improper activities (January 1997) FAR 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (JAN 1997) FAR 52.204-4 Printed or Copied Double-Sided on Recycled Paper (August 2000) FAR 52.204-9 Personal Identity Verification of Contractor Personnel (Applicable where the Contractor will have physical access to a federally- controlled facility. Or access to a Federal Information System (September 2007) FAR 52.208-6 Marking of Leased Vehicles (April 1984) FAR 52.209-3 First Article Approval – Contractor Testing (September 1989) FAR 52.209-4 First Article Approval – Government Testing (September 1989) FAR 52.20 9-5 Certification Regarding Debarment, Suspension, Proposed Debarment, and Other Responsibility Matters (December 2001) FAR 52.211-1 Availability of Specifications (August 1998) FAR 52.211-5 Material Requirements (August 2000) FAR 52.211-15 Defense Priority & Allocation Requirements (September 1990) FAR 52.213-4 Terms and Conditions – Simplified Acquisitions (December 2007) FAR 52.215-1 Instructions to Offerors – Competitive Acquisitions (January 2004) FAR 52.215-9 Changes or Additions to Make or Buy Program (October 1997) FAR 00-000-00 Integrity of the Unit Price (Oct 1997), subparagraph (b) does not apply. FAR 52.215-18 Revision or Adjustment of Plans for Postretirement Benefits (PRB) Other Than Pension (July 2005) FAR 52.215-20 Requirem ents for Cost or Pricing Data or Information Other Than Cost or Pricing Data (October 1997) FAR 52.215-21 Requirements for Cost or Pricing Data or Information Other Than Cost or Pricing Data – Modifications (October 1997)\ FAR 52.219-23 Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns (September 2005) FAR 52.219-28 Post- Award Small Business Program Representation (June 2007) FAR 52.222-1 Notice to the Government of Labor Disputes (February 1997) FAR 52.222-3 Convict Labor (August 1996) FAR 52.222-4 Contract Work Hours and Safety Standards Act-Overtime Compensation (July 2005) FAR 52.222-8 Payrolls and Basic Records (February 1988) FAR 52.222-11 Subcontracts (Labor Standards) (July 2005) FAR 52.222-12 Contract Termination – Debarment (February 1988) FAR 52.222-13 Compliance with Xxxxx Xxxxx and Related Act Regulations (February 1988) FAR 52.222-19 Child Labor – Cooperation...
Sample 1
AutoNDA by SimpleDocs

Related to CLAUSES APPLICABLE TO ALL PURCHASE ORDERS

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Additional Procedures Applicable to High Value Accounts 1. If a Preexisting Individual Account is a High Value Account as of December 31, 2013, the Reporting [FATCA Partner] Financial Institution must complete the enhanced review procedures described in paragraph D of this section with respect to such account by December 31, 2014. If based on this review, such account is identified as a U.S. Reportable Account, the Reporting [FATCA Partner] Financial Institution must report the required information about such account with respect to 2013 and 2014 in the first report on the Account. For all subsequent years, information about the account should be reported on an annual basis.

  • Indemnity for Underlying Sales and Supplemental Agreements Vendor shall be solely responsible for any customer claims or any disputes arising out of TIPS Sales or any Supplemental Agreement as if sold in the open-market. The Parties agree that TIPS shall not be liable for any claims arising out of Vendor’s TIPS Sales or Supplemental Agreements, including but not limited to: allegations of product defect or insufficiency, allegations of service defect or insufficiency, allegations regarding delivery defect or insufficiency, allegations of fraud or misrepresentation, allegations regarding pricing or amounts owed for TIPS sales, and/or allegations regarding payment, over-payment, under-payment, or non-payment for TIPS Sales. Payment/Drafting, overpayment/over-drafting, under- payment/under-drafting, or non-payment for TIPS Sales between customer and Vendor and inspections, rejections, or acceptance of such purchases shall be the exclusive respective obligations of Vendor/Customer, and disputes shall be handled in accordance with the terms of the underlying Supplemental Agreement(s) entered into between Vendor and Customer. Vendor acknowledges that TIPS is not a dealer, subcontractor, agent, or reseller of Vendor’s goods and services and shall not be responsible for any claims arising out of alleged insufficiencies or defects in Vendor’s goods and services, should any arise.

  • Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.

  • Price Changes Applicable only to Term Contracts If this is a term contract for commodities or services, the following provisions apply.

  • General Conditions Applicable to Option to Build If the Interconnection Customer assumes responsibility for the design, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades,

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • COMPLIANCE WITH EPA REGULATIONS APPLICABLE TO GRANTS SUBGRANTS, COOPERATIVE AGREEMENTS, AND CONTRACTS Contractor certifies compliance with all applicable standards, orders, regulations, and/or requirements issued pursuant to the Clean Air Act of 1970, as amended (42 U.S.C. 1857(h)), Section 508 of the Clean Water Act, as amended (13 U.S.C. 1368), Executive Order 117389 and Environmental Protection Agency Regulation, 40 CFR Part 15.

  • Technical Standards Applicable to a Wind Generating Plant i. Low Voltage Ride-Through (LVRT) Capability A wind generating plant shall be able to remain online during voltage disturbances up to the time periods and associated voltage levels set forth in the standard below. The LVRT standard provides for a transition period standard and a post-transition period standard.

  • Acknowledgement of Existing Physical Conditions In undertaking the work under this Contract, the Contractor acknowledges that he has visited the premises and has taken into consideration all open and apparent conditions that might affect his work. No claim based on lack of knowledge of existing conditions shall be allowed unless the existing physical conditions cannot be discovered by a reasonably observant person. Any claims relating to conditions that are materially different from the Contract Documents that were not open and apparent may be adjusted as provided in this Part.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!