CONTRACT AND SERVICE MANAGEMENT Sample Clauses

CONTRACT AND SERVICE MANAGEMENT. INTRODUCTION This Schedule specifies the requirements in respect of Contract and service management issues. IMPLEMENTATION If required by the CUSTOMER’s Order, both parties shall perform all their obligations under this Contract in accordance with the Implementation Plan. In the event that the CONTRACTOR fails (or is likely to fail), due to its Default, to fulfil an obligation by the date specified in the Implementation Plan for such fulfilment, the CONTRACTOR shall notify the CUSTOMER in writing of such failure (including full details of the reasons for and consequences of the delay) and, at the request of the CUSTOMER and without prejudice to the CUSTOMER’s other rights and remedies: arrange all such additional resources as are necessary to fulfil the said obligation as early as practicable thereafter at no additional charge to the CUSTOMER; and take all reasonable steps necessary to eliminate or mitigate the consequences of the delay, including issuing a correction plan (covering those aspects for which the CONTRACTOR is responsible) for approval not later than ten (10) Working Days after the initial notification under paragraph 2.2 of this Schedule, which once approval has been secured from the CUSTOMER, shall be followed by the CONTRACTOR. In the event that any obligation of the CONTRACTOR specified in the Implementation Plan is (or is likely to become) delayed as a result of a Default by the CUSTOMER then: the CONTRACTOR shall immediately notify the CUSTOMER of the fact of the delay (including full details of the consequences of the delay); the date associated with the relevant obligation(s) as specified in the Implementation Plan (and the dates similarly associated with any subsequent obligation(s) specified in the Implementation Plan) shall be amended by a period of time equal to the period of such CUSTOMER’s Default (or other such period as the parties agree); both parties shall use all reasonable endeavours to mitigate the impact of such delay and to recover any resultant delay to the performance of the Ordered IT Products; and the CUSTOMER shall reimburse those reasonable costs of the CONTRACTOR which are both reasonably and necessarily incurred by the CONTRACTOR as a direct result of such delay. Where a delay is attributable in part to the CONTRACTOR's Default and in part to a CUSTOMER Default, the parties shall negotiate in good faith with a view to agreeing a fair and reasonable apportionment of responsibility for the delay. If necessary, the...
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
CONTRACT AND SERVICE MANAGEMENT. 31 23 Contract Minimums.................................................................33 24 Warranties........................................................................34
Sample 1See All (4)
CONTRACT AND SERVICE MANAGEMENT. INTRODUCTION This Schedule specifies the requirements in respect of Contract and service management issues. IMPLEMENTATION If required by the CUSTOMER’s Order, both parties shall perform all their obligations under this Contract in accordance with the Implementation Plan. In the event that the SERVICE PROVIDER fails, due to its Default, to fulfil an obligation by the date specified in the Implementation Plan for such fulfilment, the SERVICE PROVIDER shall notify the CUSTOMER of such failure and, at the request of the CUSTOMER and without prejudice to the CUSTOMER’s other rights and remedies, arrange all such additional resources as are necessary to fulfil the said obligation as early as practicable thereafter at no additional charge to the CUSTOMER. In the event that any obligation of the SERVICE PROVIDER specified in the Implementation Plan is delayed as a result of a Default by the CUSTOMER then: the date associated with the relevant obligation(s) as specified in the Implementation Plan (and the dates similarly associated with any subsequent obligation(s) specified in the Implementation Plan) shall be amended by a period of time equal to the period of such CUSTOMER Default (or other such period as the parties agree); both parties shall use all reasonable endeavours to mitigate the impact of such delay and to recover any resultant delay to the performance of the Ordered Software Application Solutions; and the CUSTOMER shall reimburse those reasonable costs of the SERVICE PROVIDER which are both reasonably and necessarily incurred by the SERVICE PROVIDER as a direct result of such delay.
Sample 1
CONTRACT AND SERVICE MANAGEMENT. 16.1 BPA and Exult shall manage the relationship between the parties, the Agreement and the Country Agreements, including the provision of the Services in accordance with Schedule P (Global Governance Arrangements).
Sample 1Sample 2
CONTRACT AND SERVICE MANAGEMENT. 1.1. This Schedule specifies the requirements in respect of Contract and service management issues.
Sample 1
CONTRACT AND SERVICE MANAGEMENT. 1.1 Establishes, manages and reforms primary health programs in accordance with the R 30 strategic directions of Pilbara Population Health.
Sample 1
CONTRACT AND SERVICE MANAGEMENT. 6.1 The SERVICE PROVIDER and the CUSTOMER shall comply with their respective contract management obligations set out in Schedule 2-6.
Sample 1
AutoNDA by SimpleDocs

Related to CONTRACT AND SERVICE MANAGEMENT

  • Program Management 1.1.01 Implement and operate an Immunization Program as a Responsible Entity

  • Collaboration Management Promptly after the Effective Date, each Party will appoint a person who will oversee day-to-day contact between the Parties for all matters related to the management of the Collaboration Activities in between meetings of the JSC and will have such other responsibilities as the Parties may agree in writing after the Effective Date. One person will be designated by Merck (the “Merck Program Director”) and one person will be designated by Moderna (the “Moderna Program Director,”) together will be the “Program Directors”. Each Party may replace its Program Director at any time by notice in writing to the other Party. Any Program Director may designate a substitute to temporarily perform the functions of that Program Director by written notice to the other Party. The initial Program Directors will be: For Moderna: [***] For Merck: [***]

  • Project Management Project Management Institute (PMI) certified project manager executing any or all of the following: • Development of Project Charter • Development of project plan and schedule • Coordination and scheduling of project activities across customer and functional areas • Consultation on operational and infrastructure requirements, standards and configurations • Facilitate project status meetings • Timely project status reporting • Address project issues with functional areas and management • Escalation of significant issues to customers and executive management • Manage project scope and deliverable requirements • Document changes to project scope and schedule • Facilitate and document project closeout

  • Virus Management Transfer Agent shall maintain a malware protection program designed to deter malware infections, detect the presence of malware within the Transfer Agent environment.

  • Case Management Prompt resolution of any dispute is important to both parties; and the parties agree that the arbitration of any dispute shall be conducted expeditiously. The arbitrators are instructed and directed to assume case management initiative and control over the arbitration process (including scheduling of events, pre-hearing discovery and activities, and the conduct of the hearing), in order to complete the arbitration as expeditiously as is reasonably practical for obtaining a just resolution of the dispute.

  • Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.

  • Change Management BellSouth provides a collaborative process for change management of the electronic interfaces through the Change Control Process (CCP). Guidelines for this process are set forth in the CCP document as amended from time to time during this Agreement. The CCP document may be accessed via the Internet at xxxx://xxx.xxxxxxxxxxxxxxx.xxxxxxxxx.xxx.

  • Transportation Management Tenant shall fully comply with all present or future programs intended to manage parking, transportation or traffic in and around the Building, and in connection therewith, Tenant shall take responsible action for the transportation planning and management of all employees located at the Premises by working directly with Landlord, any governmental transportation management organization or any other transportation-related committees or entities.

  • Development Services During the term of this Agreement, the Provider agrees to provide to or on behalf of the Port the professional services and related items described in Exhibit A (collectively, the “Development Services”) in accordance with the terms and conditions of this Agreement. The Provider specifically agrees to include at least one Port representative in any economic development negotiations or discussions in which the Provider is involved concerning (i) a port-related business prospect or (ii) a business transaction which will ultimately require Port involvement, financial or otherwise.

  • Relationship Management LAUSD expects Contractors and their Representatives to ensure that their business dealings with and/or on behalf of LAUSD are conducted in a manner that is above reproach.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!