Consequences of a Delay Event Sample Clauses

Consequences of a Delay Event. (a) Upon the occurrence of a Delay Event, the Contract Time will be extended for such reasonable time as the Consultant recommends in consultation with Owner in accordance with the procedure set out in Schedule 11 – Change Procedure.
Sample 1Sample 2Sample 3See All (9)
AutoNDA by SimpleDocs
Consequences of a Delay Event. (a) Project Co shall provide written notice to the City Representative and the Independent Certifier and the Consultant within 5 Business Days of becoming aware of the occurrence of Delay Event. Project Co shall, within 10 Business Days after such notification, provide further written details to the City Representative and the Independent Certifier and the Consultant which shall include:
Sample 1

Related to Consequences of a Delay Event

  • Consequences of an Event of Default (a) If an Event of Default specified in subsections (a) through (l), (o), (p) or (q) of Section 7.01 shall occur and, be continuing or shall exist, then, in addition to all other rights and remedies which the Administrative Agent or any Lender may have hereunder or under any other Loan Document, at law, in equity or otherwise, the Lenders shall be under no further obligation to make Loans hereunder, and the Administrative Agent may, and, upon the written request of the Required Lenders shall, by notice to the Borrower, from time to time do any or all of the following:

  • Consequences of Default Upon the occurrence of any Event of Default, as defined in the Revenue Sharing Agreement:

  • Default and Consequences of Default 18.1 Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at the Supplier’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.

  • Consequences of Events of Default and Corrective Action If an Event of Default occurs, the Province may, at any time, take one or more of the following actions:

  • Consequences of Breach Without prejudice to any rights that may be available to the Principal/Owner under law or the Contract or its established policies and laid down procedures, the Principal/Owner shall have the following rights in case of breach of this Integrity Pact by the Tenderer(s)/Contractor(s) and the Tenderer/ Contractor accepts and undertakes to respect and uphold the Principal/Owner’s absolute right:

  • Consequences of Force Majeure If the Affected Party has taken all necessary steps towards mitigating the effect of a Force Majeure event, then:

  • Default Events (a) Any material breach of the Funding Agreement by the Recipient, including those set out below, will be an event of default (“Default Event”):

  • Consequences of non-compliance If a beneficiary breaches any of its obligations under this Article, the grant may be reduced (see Article 43). Such breaches may also lead to any of the other measures described in Chapter 6.

  • Consequences of Termination Upon the termination of this Agreement:

  • CONSEQUENCES OF TERMINATION AND EXPIRY 28.1 Notwithstanding the service of a notice to terminate this Framework Agreement, the Supplier shall continue to fulfil its obligations under this Framework Agreement until the date of expiry or termination of this Framework Agreement or such other date as required under this Clause 28 (Consequences of Termination and Expiry).

Time is Money Join Law Insider Premium to draft better contracts faster.