Party Action Schedule Sample Clauses

Party Action Schedule. Engineer Furnish [ ] review copies of the Report and other Study and Report Phase deliverables to PCCA. Within [ ] days of the Commencement Date of the Service Order. PCCA Submit comments regarding Report and other Study and Report Phase deliverables to Engineer. Within [ ] days of the receipt of Report and other Study and Report Phase deliverables from Engineer. Engineer Furnish [ ] copies of the revised Report and other Study and Report Phase deliverables to PCCA. Within [ ] days of the receipt of PCCA’s comments regarding the Report and other Study and Report Phase deliverables. Engineer Furnish [ ] review copies of the Preliminary Design Phase documents, opinion of probable Construction Cost, and other Preliminary Design Phase deliverables to PCCA. Within [ ] days of PCCA’s authorization to proceed with Preliminary Design Phase services. PCCA Submit comments regarding Preliminary Design Phase documents, opinion of probable Construction Cost, and other Preliminary Design Phase deliverables to Engineer. Within [ ] days of the receipt of Preliminary Design Phase documents, opinion of probable Construction Cost, and other Preliminary Design Phase deliverables from Engineer. Engineer Furnish [ ] copies of the revised Preliminary Design Phase documents, opinion of probable Construction Cost, and other Preliminary Design Phase deliverables to PCCA. Within [ ] days of the receipt of PCCA’s comments regarding the Preliminary Design Phase documents, opinion of probable Construction Cost, and other Preliminary Design Phase deliverables. Engineer Furnish [ ] copies of the 60% Design Phase documents, opinion of probable Construction Cost, and other Preliminary Design Phase deliverables to PCCA. Within [ ] days of the receipt of PCCA’s comments regarding the Preliminary Design Phase documents, opinion of probable Construction Cost, and other Preliminary Design Phase deliverables. Engineer Furnish [ ] copies of the 90% Design Phase documents, opinion of probable Construction Cost, and other Preliminary Design Phase deliverables to PCCA. Within [ ] days of the receipt of PCCA’s comments regarding the Preliminary Design Phase documents, opinion of probable Construction Cost, and other Preliminary Design Phase deliverables. Engineer Furnish [ ] copies of the final Drawings and Specifications, assembled drafts of other Construction Contract Documents, the draft bidding- related documents (or requests for proposals or other construction procurement documents), and any oth...
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Party Action Schedule. Engineer 65% Design deliverables to PCCA. Within 35 calendar days of authorization to proceed PCCA Submit comments regarding the 65% Design documents to Engineer. Within 5 calendar days of the receipt of the 65% Design documents Engineer 95% Design deliverables to PCCA. Within 30 calendar days of comments. PCCA Submit comments and instructions regarding the 95% Drawings and Specifications to the Engineer. Within 5 calendar days of the receipt of the 95% Drawings and Specifications Engineer Final Drawings and Specifications to PCCA Within 14 calendar days of comments Project Schedule: Design Complete April 15, 2019 Advertise April 25, 2019 Bid May 10, 2019 Award May 21, 2019 Construction 90 days EXHIBIT B FEE SCHEDULE The Engineer will perform the Services described in Exhibit A in accordance with the terms and conditions of this Contract on an hourly fee basis; provided, however, that the total fee for services rendered under this Agreement will not exceed $186,360, without Authority’s written approval. Services provided by Engineer will be billed at the hourly rates specified in Exhibit B. These fees will cover all of Engineer’s overhead costs, including but not limited to, office rent, long distance telephone charges, postage, payroll and copying charges. Fee Breakdown Design of Cargo Area $ 148,321 Topographic Survey $ 4,500 Geotechnical Investigation $ 7,500 Offsite Drainage Study $ 14,348 Add. Services/Permitting Assistance $ 9,691 Limited Bid and Construction Phase Support $ 2,000 TOTAL NOT TO EXCEED $ 186,360 The Authority agrees to reimburse the Engineer for certain authorized and approved travel expenses incurred by the Engineer during the Term and directly resulting from the Engineer’s performance of the Services under this Contract. Authority will also reimburse the Engineer for document production costs and other direct costs (collectively, “Direct Costs”) incurred by the Engineer in performing the Services. The Engineer shall submit proper documentation of any such approved travel expenses and Direct Costs to Authority from time to time, and such costs and expenses shall be billed to Authority at Engineer’s actual cost. Not later than the twentieth (20th) day of each calendar month, Engineer shall submit to Authority detailed invoices for all services performed and Direct Costs incurred, if any, pursuant to this Agreement during the prior calendar month. The invoices shall describe in detail the Services performed during the prior month and sh...
Sample 1
Party Action Schedule. Payments to Drone Business
Sample 1

Related to Party Action Schedule

  • Evaluation Schedule CLIENT REFERENCES The Tenderer shall provide details of his performance on each of the previous projects listed in the “Relevant Experience” returnable schedule. “Client Reference Scorecards” will be completed by each of the respective Clients for the projects listed in the “Relevant Experience” returnable schedule. The following are to be completed by the Client and Principal Agent and is to be supported in each case by a letter of award and the works completion certificate. Both Client and Principal Agent must sign and stamp the documents, failure to obtain both signatures and stamps will result in no allocation of points. PROJECT NAME and SCOPE OF WORK: Principal agent: ................................................................................................................................. Client: .. ..............................................................................................................................................

  • Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement.

  • Vacation Schedules (a) Employees shall submit their vacation requests to the supervisor on or before:

  • Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.

  • RDO Schedule a) The Schedule of RDO’s to be observed each year will generally be as provided under the VBIA.

  • Third Schedule MINERAL LEASE Lease No Goldfield(s) XXXXXXXXX THE SECOND by the Grace of God of the United Kingdom, Australia and Her other Realms and Territories Queen, Head of the Commonwealth, Defender of the Faith: TO ALL TO WHOM THESE PRESENTS shall come GREETINGS: KNOW YE that WHEREAS by an Agreement made the day of 1968 between the State of Western Australia of the one part and HAMERSLEY IRON PTY. LIMITED (hereinafter called “the Company” which expression will include the successors and assigns of the company including where the context so admits the assignees of the Company under the said Agreement) of the other part the said State agreed to grant to the Company a mineral lease of portion or portions of the lands referred to in the said Agreement as “the mining areas” AND WHEREAS the said Agreement was ratified by the Act 196 which said Act (inter alia) authorized the grant of a mineral lease to the Company NOW WE in consideration of the rents and royalties reserved by and of the provisions of the said Agreement and in pursuance of the said Act DO BY THESE PRESENTS GRANT AND DEMISE unto the Company subject to the said provisions ALL THOSE pieces and parcels of land situated in the Goldfield(s) containing approximately acres and (subject to such corrections as may be necessary to accord with survey when made) being the land shaded pink on the plan in the Schedule hereto and all those mines, veins, seams, lodes and deposits of iron ore in on or under the said land (hereinafter called “the said mine”) together with all rights, liberties, easements, advantages and appurtenances thereto belonging or appertaining to a lessee of a mineral lease under the Mining Xxx 0000 including all amendments thereof for the time being in force and all regulations made thereunder for the time being in force (which Act and regulations are hereinafter referred to as “the Mining Act”) or to which the Company is entitled under the said Agreement TO HOLD the said land and mine and all and singular the premises hereby demised for the full term of twenty-one years from the day of 19 with the right to renew the same from time to time for further periods each of twenty-one years as provided in but subject to the said Agreement for the purposes but upon and subject to the terms covenants and conditions set out in the said Agreement and to the Mining Act (as modified Third Schedule by the said Agreement) YIELDING and paying therefor the rent and royalties as set out in the said Agreement. AND WE do hereby declare that this lease is subject to the observance and performance by the Company of the following covenants and conditions, that is to say: —

  • ARBITRATION - SCHEDULING Timely complaints shall be submitted to and determined by an arbitrator. Each arbitration proceeding shall commence not earlier than ten (10) calendar days and not later than thirty (30) calendar days following the date of filing of the complaint.

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

  • Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.

  • Shift Schedule The words "shift schedule" when used in this Agreement shall mean a timetable of the shifts and off days assigned to a position or group of positions which commences at the beginning of a pay period and includes one complete rotation of said shifts.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!