Construction Phase Support Sample Clauses

Construction Phase Support. The Engineer will complete the following tasks as required during the construction phase: 1. Attend one (1) pre-construction meeting with County and/or City staff and the selected contractor. 2. Attend one (1) field review meeting with County and/or City staff and the contractor to review the locations of staked pole locations. 3. Attend one (1) field review meeting with County and/or City staff and the contractor to develop a final punch list to be addressed by the contractor prior to completion. 4. Review and approve or take other appropriate action in respect to shop drawings and samples and other data which contractor is required to submit, but only for conformance with the information given in the contract documents. Such review and approvals or other action will not extend to means, methods, techniques, equipment choice and usage, sequences, schedules, or procedures of construction or to related safety precautions and programs. The Engineer will review up to eight (8) contractor submittals. 5. Respond to reasonable and appropriate contractor requests for information (RFIs) and issue necessary clarifications and interpretations of the contract documents as appropriate. Any orders authorizing variations from the contract documents will be made by County and/or City. The Engineer will respond to up to four (4) RFIs. 6. Provide minor revisions to plans to address differing site conditions, third party accommodation, or other owner directed changes. Revisions to plans will include revision clouds around any changes, will include descriptions and quantities of changes, and CAD files. The Engineer will provide up to two (2) minor plan revisions. 7. Prepare record drawings based on redlines from County, City, and/or contractor. The Engineer shall not be responsible for the means, methods, techniques, sequences, or procedures of construction selected by the contractor or the safety precautions and programs incidental to the work of the contractor. The Engineer shall not guarantee the performance of the contractor nor be responsible for the acts, errors, omissions, or the failure of the contractor to perform the construction work in accordance with the contract documents. County agrees to include in all construction contract provisions the indemnification of both County and the Engineer for contractor’s negligence and to name both County and the Engineer as additional insured on the applicable contractor’s insurance policies.
Sample 1Sample 2
AutoNDA by SimpleDocs
Construction Phase Support. The engineer will provide technical design support, respond to questions about the design that arise during construction.
Sample 1
Construction Phase Support. Once the 100% Construction Drawing plans are completed or the Building Permit is issued, Xxxxxxx has completed the Base Scope of Services. Any additional revisions to the construction documents, construction meetings, value engineering changes, or construction administration items will be billed as an hourly service. Dunaway will provide construction administration services as follows: a. Attend a preconstruction meeting, b. Review and respond on the Client’s behalf for shop drawing submittals related to elements of the design for which Xxxxxxx is responsible. c. Review and respond to written Requests for Information from the Client’s contractor regarding elements of the design for which Xxxxxxx is responsible. d. Two (2) site visits during construction, and e. Final walk through. Only those services specifically mentioned in the Scope of Work section are offered as part of this proposal. Proposal for Professional Services Oak Valley - South Xxxxx Street Trailhead Page 5 The following is a list of some, but not necessarily all, of the services that can be useful or required for a Project of this type. The listed services have not been included in this proposal. Dunaway can provide or sub-consult many of these services if desired by the Client. If the Client determines any of these services is desired, Xxxxxxx can either amend this proposal to incorporate the desired service or services or recommend other actions to cover the needs as expressed.
Sample 1
Construction Phase Support. Civil West Engineering will provide construction phase support to address requests for information (RFIs) and to provide inspection services. Assumptions: • Estimated maximum of 3 RFIs. • Assumes one pre-construction meeting with Contractor • Includes one post construction site inspection to verify adherence to plans.
Sample 1
Construction Phase Support. Geosyntec staff will be available to assist during construction phase, including responding to questions, or modifying design in response to unanticipated field conditions. Budgetted on level of support.
Sample 1
Construction Phase Support. Construction phase services include such services as shop drawing review, office and field engineering support, field observation, construction contract administration, change order review and processing, preparation of record drawings, etc. For this proposal it is assumed that PBS&J will perform no construction management, administration or field observation. We will assist with construction engineering support, including review of up to four (4) submittals, review of up to three (3) RFIs, review of up to one (1) change order, attendance at the pre- construction meeting and up to three (3) progress meetings. PBS&J will also complete record drawings on the mylars and in the Microstation files when construction is completed. Record drawings will be based on changes to the drawings from the contractor's furnished record of constructixx xxxxxxx. January 11 , 0000 Xxxxx Xxxxxx, Park Designer Beta Street Green Alley Project Page 6 of 6
Sample 1
Construction Phase Support. Engineer will assist the PCCA with limited general representation during the construction phase of the project. The PCCA will provide day to day project representative and standard general construction services. Engineer’s professional services provided during the project construction phase may include assisting the PCCA staff in in their general representation duties on an on-call basis by assisting in answering Contractor RFIs or reviewing Contractor submittals, or attending a pre-construction or monthly construction meeting subject to the following limitations: A. Engineer anticipates assisting with (6) as funds allow. B. Engineer anticipates assisting with (8) as funds allow. C. Engineer anticipates assisting with (8) RFIs as funds allow.
Sample 1
AutoNDA by SimpleDocs

Related to Construction Phase Support

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items: 9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.

  • Construction Phase Part 1 –

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Construction Work The regulation at 41 C.F.R. § 60-1.3 defines “construction work” as the construction, rehabilitation, alteration, conversion, extension, demolition or repair of buildings, highways, or other changes or improvements to real property, including facilities providing utility services. The term also includes the supervision, inspection, and other onsite functions incidental to the actual construction.

  • PRE-CONSTRUCTION PHASE FEE The Pre-Construction Phase Fee is the total compensation payable to Contractor for the performance of Pre-Construction Phase Services, except for Additional Pre-Construction Phase Services approved in advance and in writing by Owner. The Pre-Construction Phase Fee shall be a lump sum amount based on the AACC established in this Agreement. 6.1 Except as specifically allowed by Owner, Contractor shall not be entitled to any increase in the Pre-Construction Phase Fee for any costs, expenses, liabilities or other obligations arising from the performance of Pre-Construction Phase Services. 6.2 Costs associated with the following items are specifically, but not exclusively, included in the establishment of the Pre-Construction Phase Fee: profit and profit sharing; general overhead; salaries and labor; housing and relocation; estimating, scheduling and information management systems and software; contract administration; office expenses; printing and copying; consulting fees; legal or accounting fees; cost of money; taxes; insurance premiums and deductibles; bond costs; purchase or rental of equipment; utilities; travel; per diem; fines or penalties; and damage awards. 6.3 If the scope of the Pre-Construction Phase Services is changed materially, the Pre- Construction Phase Fee shall be equitably adjusted. If the AACC is changed materially before acceptance of the GMP Proposal, the Pre-Construction Phase Fee shall be adjusted in writing in proportion to the change in the AACC. There shall be no adjustments in the Pre-Construction Phase Fee following acceptance of the GMP Proposal. 6.4 For Additional Pre-Construction Phase Services that are approved in advance and in writing by Owner, Contractor shall be entitled to additional compensation computed as follows: 6.4.1 A pre-established lump sum amount; or 6.4.2 The hourly cost of Contractor’s employees or consultants who actually perform the Additional Services based on the employee’s Worker Wage Rate or prorated Monthly Rate plus the actual cost of allowable expenses incurred in the performance of the Additional Pre-Construction Phase Services, plus an overhead and profit markup of ten percent (10%) of the total cost; or 6.4.3 As otherwise agreed in advance and in writing.

  • Preconstruction Phase The Preconstruction Phase shall mean the period commencing on the date of this CM/GC Contract and ending upon commencement of the Construction Phase; provided that if the Owner and CM/GC agree, the Construction Phase may commence before the Preconstruction Phase is completed, in which case both phases shall proceed concurrently, subject to the terms and conditions of the Contract Documents.

  • Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.

  • Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!