PRELIMINARIES AND GENERAL. Bill No. 1
PRELIMINARIES AND GENERAL. Bill No. 1 Preliminaries Latent defects liability period (Clause 27). Clause 27.0 is amended by the addition of the following clauses:
PRELIMINARIES AND GENERAL. Bill No. 1 Preliminaries Payment will be made for materials and goods:- Yes Dispute resolution :- Mediation (in terms of clause 40) followed by litigation. Arbitration rules as recommended by the Association of Arbitrators (SA) :- N/A Clause 42.2.5 Date on which possession of the site is intended to be given on :- 5 working days from the date of the letter of appointment to the Contractor. Clause 42.2.6 Period for the commencement of the works after the contractor takes possession of the site :- 2 Working days. Completion in Sections are required : NO Clause 42.2.7 Intended date of practical completion and the penalty per calendar day for the works as a whole :- To be advised. Penalty amount to be advised. Clause 42.2.8 Intended dates of practical completion and the penalties per calendar day for the works in sections : N/A Clause 42.2.9 The law applicable to this agreement shall be that of - South Africa. PRELIMINARIES AND GENERAL Bill No. 1 Preliminaries Clause 42.3.1 Contract works insurance to be effected by Contractor for the sum of: Contract Sum plus 20% With a deductible of : to be determined by the Contractor but not greater than the maximum of R50,000.00 as stipulated by the Municipality. Clause 42.3.2 Supplementary insurance is required : Yes SASRIA insurance required to be effected by the Contractor for the amount of: Contract Sum plus 20% (with a deductable to be determined by the Insurance company issueing the policy). Clause 42.3.3 Public liability insurance to be effected by Contractor For the amount of: R 10 million With a deductible of: R 2,500.00 Clause 42.4.1 Waiver of the contractor's lien is required :- YES Clause 42.4.2 Number of construction document copies to be supplied to the Contractor free of charge :- 3 Clause 42.4.3 Bills of Quantities drawn up in accordance with :- Standard System of Measuring Building Work - Seventh Edition including all amendments PRELIMINARIES AND GENERAL Bill No. 1 Preliminaries Clause 42.4.4 Number of days for submission of priced documents : 5 working days from the Letter of Appointment. Clause 42.4.5 JBCC Engineering General Conditions are to be included in the documents :- No Clause 42.4.6 The contract value is to be adjusted using CPAP:- NO Definitions and Interpretation (B1) 1 F: ……….… V: ….……… T: ….……... Item Checking of documents (B2.1) Notwithstanding the issue of the tender drawings, it will remain the responsibility of the Tenderer to study all available drawings at the offices of the Principal...
PRELIMINARIES AND GENERAL. Bill No. 1 Preliminaries The Contractor shall record in triplicate in a suitable A4 size triplicate book kept at the site, a daily record of work done, all site visits by the Principal Agent and other professional personnel and all events affecting the Works, such as progress, issue of plans, breakdown of machinery, etc. The labour, plant and material on site shall be recorded as well as work performed. Entries must be made by the Contractor and must be signed and forwarded to the Principal Agent for his counter- signature on a daily basis. Copies of these records shall be for the Architect, Quantity Surveyor and Contractor. 1 F: ……….… V: ….……… T: ….……... Item C7. Labour record At the end of each week the contractor shall provide the principal agent with a written record, in schedule form, reflecting the number and description of tradesmen and labourers employed by him and all subcontractors on the works each day. 2 F: ……….… V: ….……… T: ….……... Item
PRELIMINARIES AND GENERAL. Bill No. 1 Preliminaries The Council shall at all times have the right to summarily suspend the performance of the Contractor hereunder pending compliance by the Contractor with any requirement, regulation and/or direction referred to. The Council shall be entitled to set-off against any amount owed by the Council to the Contractor hereunder any loss or damage suffered by it as a result of the suspension of the Contractor's performance in the circumstances envisaged above. The Tenderer shall price for all necessary items to comply with the Occupational Health and Safety. 1 F: ……….… V: ….……… T: ….……... Item C16. Covid-19 Compliance Measures The Contractor is required to price for Covid 19 compliance and the pricing thereof shall be deemed to include all the mandatory requirements.
PRELIMINARIES AND GENERAL. NOTES PREAMBLES
PRELIMINARIES AND GENERAL. BUILDING AGREEMENT AND PRELIMINARIES
PRELIMINARIES AND GENERAL. ITEM NO DESCRIPTION UNIT QUAN- TITY RATE AMOUNT SECTION NO.2 BILL NO.1 ALTERATIONS SUPPLEMENTARY PREAMBLES For preambles see preambles for all trades GENERAL In taking down and removing existing work, the utmost care shall be taken to avoid any structural or other damage to the remaining portions of the building. contractor shall cover up and protect from injury all not removed and shall make good at his own expense any damage that may occur Provide and erect all casings and protection for and cover up all existing fittings, door, windows, joinery work, walls, floors, etc. not disturbed during the alterations and clear away and make good on completion Prices for demolition of any portion of the structure shall include for its demolition complete with all surface finishes such as plaster, screeds, etc., all attached items of such as skirtings, cupboards, etc., and all reinforcement, conduit pipes, lintels, etc., built into that portion of the structure including the carting away of all rubble, debris, etc. Removal of the alterations to the Electrical and Mechanical installations shall be executed by the Nominated Sub-Contractors and the contractor shall be responsible for the co-ordination of such work with his own TOTAL CARRIED FORWARD thresholds, xxxxx, etc (building up openings and making good finishes elsewhere) Timber single door , not exceeding 2,5m² Glazed window panes not exceeding 2,5m² Hacking up/off and removing ceramic tiles including removing mortar bed or adhesive from concrete or brickwork and preparing surfaces for new screed, plaster,tile finish, etc Tiles to walls Tiles to floor Taking down and removing roofs, floors, panelling, ceilings, partitions, etc. Gypsum plasterboard ceilings, including cornices, timber brandering, etc. Steel gutters and rain downpipes Tongued and grooved timber suspended floors,including carpet floor coverings, skirtings, timber joists, bearers, etc. Taking up and removing vinyl floor coverings and preparing screeds for new floor coverings Vinyl tile floor covering TOTAL CARRIED FORWARD R - ITEM NO DESCRIPTION UNIT QUAN- TITY RATE AMOUNT 9 10 11 12 Taking out and removing sanitary fittings, etc., including No No m² m² 2 1 80 75 R - R - R - R - good tiling and paintwork elsewhere) Neatly taking out wash hand basin, including short lengths of piping, etc., and store a side for client. Neatly taking out WC pan with cistern, including short lengths of piping, etc., and store a side for client. Making good plaster wall...
PRELIMINARIES AND GENERAL. Item Description Item Sub-Total
A.1 Safety File Compilation and Approval
A.2 Contract insurance A.3 ORTIA Airport Permits including Induction and AVOP A.4 CTIA Airport Permits including Induction and AVOP A.4 KSIA Airport Permits including Induction and AVOP A.5 BFIA Airport Permits including Induction and AVOP A.5 CDSIA Airport Permits including Induction and AVOP A.6 GRJ Airport Permits including Induction and AVOP A.7 XXX Airport Permits including Induction and AVOP A.8 KPA Airport Permits including Induction and AVOP A.9 UPN Airport Permits including Induction and AVOP A.10 ORTIA Site Establishment A.11 CTIA Site Establishment A.12 KSIA Site Establishment A.13 BFIA Site Establishment A.14 CDSIA Site Establishment A.15 GRJ Site Establishment A.16 XXX Site Establishment A.17 KPA Site Establishment A.18 UPN Site Establishment A.19 Department of Health Certificate
PRELIMINARIES AND GENERAL. The JBCC Minor Works Agreement (Edition 5.2 – May 2018) prepared by the Joint Building Contracts Committee shall be the applicable building agreement, amended as hereinafter described The JBCC General Preliminaries (May 2018) published by the Joint Building Contracts Committee for use with the JBCC Minor Works Agreement (Edition 5.2 – May 2018) shall be deemed to be incorporated in this project specific preliminaries, amended as hereinafter described Tenderers are referred to the above mentioned documents for the full intent and meaning of each clause thereof (hereinafter referred to by heading and clause number only) for which such allowance must be made as may be considered necessary. Copies of both documents and a full set of the drawings are available for scrutiny at the Office of the Principal Agent. Where standard clauses or alternatives are not entirely applicable to this contract, such modifications, corrections or supplements as will apply are given under each relevant clause heading. Where any item is not relevant to this specific contract, such item is marked N/A (signifying Not Applicable). Carried Forward SECTION NO. 1 BILL NO. 1 PRELIMINARIES AND GENERAL Quantity Rate R Amount Brought Forward SECTION A:
