Software Maintenance and Upgrades Sample Clauses

Software Maintenance and Upgrades. CentralSquare will provide all hosted systems and network maintenance as deemed appropriate and necessary by CentralSquare. Maintenance and upgrades will be announced at least 24 hours in advance. The upgrades are installed at mutually agreed times. CentralSquare recommends reserving a weekly or monthly maintenance window between 0000-0500 (i.
Sample 1Sample 2
AutoNDA by SimpleDocs
Software Maintenance and Upgrades. Effective on the Commencement Date and continuing, during the Term, IFOX will provide and be responsible for the day-to-day maintenance and support of and for all software listed on Schedule D (a.k.a., the Third Party Software). All maintenance and support of Third Party Software (including, but not limited to, procurement, installation, testing, support, and maintenance of all upgrades and updates of and to Third Party Software) shall be provided and performed by IFOX as part of the Services and is included in the Base Charges. ADT may, through the Change Order process, direct IFOX to install and operate any new or upgraded or additional Third Party Software not listed on Schedule D (collectively, "New Third Party Software"). All costs for licenses, upgrades, or additional maintenance for New Third Party Software are Reimbursable Expenses, and IFOX shall be paid for such costs in accordance with Schedule C.
Sample 1
Software Maintenance and Upgrades. NIC OK shall maintain and update the Software utilized in the Services, and Client agrees that NIC OK has the sole right to do so. In connection with such maintenance and updates, Client shall test, and/or assist NIC OK in testing, the consistency and completeness of such maintenance and updates as NIC OK reasonably requests.
Sample 1
Software Maintenance and Upgrades. Software maintenance and upgrades will be performed outside of each customer’s standard business hours whenever possible. Emergency situations will be handled on a case-by-case basis in such a manner as to provide the least possible disruption to overall system operations and availability without negatively affecting system stability and integrity. All parties will have advanced notice of such upgrades and any emergency updates will have the customer’s primary contact’s approval before being done. SunGard shall use its best efforts to provide Customer with at least forty-eight (48) hours of notice prior to scheduling Scheduled Downtime for the Horizon Cloud Solution.
Sample 1
Software Maintenance and Upgrades. To the extent software is provided with any Diagnostic Product or Roche Instrument, Roche’s standard software maintenance and upgrade terms and conditions shall apply, including the customer fees charged therefor.
Sample 1
Software Maintenance and Upgrades. Notwithstanding anything to the contrary in this Agreement, Annex 3 hereto shall govern the terms of all software maintenance and upgrades.
Sample 1
Software Maintenance and Upgrades.  Verizon monitors the release of new security upgrades. The availability of security upgrades is dependent on the release schedule of the uCPE manufacturer. Verizon does not proactively upgrade features for each uCPE. These types of upgrades must be requested through a ‘Major Change Request’ as long as these versions are certified by Verizon. Additional charges may apply for major software upgrades.  Verizon does not provide on-site software maintenance unless mutually agreed under a separate written work agreement and charged at the Applicable Rates.  Verizon monitors the release of security vulnerabilities and notifies the customer on critical security patches or upgrades for the uCPE after they have been validated by Verizon and if they are applicable for the customer. Verizon informs the customer on the critical security patch or upgrade and they are installed during an agreed upon Maintenance Window. Verizon confirms to the Authorized Contacts when the installation of a ‘critical’ Security Upgrade has been completed.  The maximum number of Maintenance Windows the customer can designate is 2 per week per site. The day and time of each Maintenance Window will be specified in the Service Context. Each Maintenance Window must be at least 4 consecutive hours.  Verizon installs all Security Upgrades remotely unless remote installation is not possible due to the physical location of the Serviced Device or in case of operating system and/or firmware upgrades. Staging Services for installation of security upgrades or On-site installation of Security Upgrades can be carried out by Verizon if mutually agreed under a separate written work agreement and charged at the Applicable Rates.  All software patches that close an exploit of extreme risk vulnerabilities are applied within 72 hours of release if agreed upon with the Customer. Non-Critical Vulnerabilities will be remediated within 10 working days, or a time agreed upon between the Customer and the C-SOC.  Verizon will notify the Customer of any critical vulnerability related to the current software version running on the Customer’s uCPE that poses a risk to the Customer’s environment.  Verizon does not provide software maintenance for unsupported or end of life devices  Customer is responsible for software maintenance for all Subordinate Devices.
Sample 1
AutoNDA by SimpleDocs

Related to Software Maintenance and Upgrades

  • Software Maintenance Subrecipient shall apply security patches and upgrades in a timely manner and keep virus software up-to-date on all systems on which State data may be stored or accessed.

  • Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.

  • Routine Maintenance (i) CRC shall be responsible for Routine Maintenance when necessary or desirable to maintain the Shared Assets in a safe operating condition, and to permit and facilitate (A) the performance by CRC of its obligations pursuant to this Agreement, and (B) the use of Shared Assets by the Operators in accordance with this Agreement. (ii) CSXT or NSR, directly or through their respective affiliates, may perform the work which CRC performed prior to the date of this Agreement when (A) CRC does not possess the skills needed for such work, (B) CRC lacks the necessary employees to do such work in a timely fashion, or (C) CRC does not possess the equipment needed to do such work. CRC and the party performing the work shall agree to a reasonable fee for such work prior to performance. CRC, CSXT and NSR may agree to have additional work performed either by CSXT, NSR or their affiliates.

  • Maintenance and Support NCR Voyix is solely responsible for providing any maintenance and support services with respect to the Software as specified in the Agreement, or as required under applicable law. The parties acknowledge that Apple has no obligation whatsoever to furnish any maintenance and support services with respect to the Software.

  • Support and Maintenance Services Information about Teradici’s support and maintenance for the Licensed Product may be found at xxxxx://xxxx.xxxxxxxx.xxx.

  • Installation and Maintenance Except for the bi‐directional and production metering equipment owned by the City, all equipment on Customer’s side of the delivery point, including the required disconnect device, shall be provided and maintained in satisfactory operating condition by Customer and shall remain the property and responsibility of the Customer. The City will bear no responsibility for the installation or maintenance of Customer’s equipment or for any damage to property as a result of any failure or malfunction thereof. The City shall not be liable, directly or indirectly for permitting or continuing to allow the interconnection of the Facility or for the acts or omissions of Customer or the failure or malfunction of any equipment of Customer that causes loss or injury, including death, to any party.

  • System Maintenance The Trust understands that USBFS will perform periodic maintenance to the System(s), which may cause temporary service interruptions. To the extent possible, USBFS shall notify the Trust of all planned outages and will perform any necessary maintenance during non-business hours.

  • Support and Maintenance Where Licensee purchases support and/or maintenance services, Licensee’s initial support and/or maintenance term will begin upon delivery to Licensee of the Licensed Software and continue for one (1) year thereafter (or the length of the term if less than a year for any subscription/term license) unless otherwise specified in the applicable annual support and/or maintenance agreement, Product Order, or other written agreement executed between Licensor and Licensee. Where Licensee purchases support and/or maintenance for any Licensed Software, Licensee hereby agrees that it shall purchase such support and/or maintenance services for all of Licensee’s licensed units of such Licensed Software product. Support and/or maintenance services provided by Licensor will be subject to Licensor’s then current applicable standard annual support and/or maintenance agreement unless otherwise agreed by the parties in writing.

  • Vehicle Maintenance 16.1 You must report to thl as soon as possible, where the oil is above or below the recommended level or the warning indication light is illuminated. 16.2 You must add water/coolant to the cooling system and an appropriate Australian Society of Automotive Engineers rated oil for petrol or diesel powered vehicles (as applicable) to the engine if the indicator level is below minimum. 16.3 You agree to maintain the Vehicle in these conditions and acknowledge that any mechanical damage occasioned as a result of Your failure to maintain the Vehicle in accordance with this clause must be paid by You.

  • Project Maintenance The Local Government shall be responsible for maintenance of locally owned roads and locally owned facilities after completion of the work. The State shall be responsible for maintenance of the state highway system after completion of the work if the work was on the state highway system, unless otherwise provided for in existing maintenance agreements with the Local Government.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!