COST DATA Sample Clauses
COST DATA. 1. Contractor shall maintain full and correct information as to number of workers employed in connection with each subdivision of the Work, classification and rate of pay of each worker in the form of certified payrolls, cost to Contractor of each class of materials, tools and appliances used by Contractor in the Work, and amount of each class of materials used in each subdivision of the Work. Contractor shall provide the County with monthly summaries of this information. If Contractor maintains or is capable of generating summaries or reports comparing actual project costs with Bid estimates or any budgets, it shall provide the County with a copy of such report whenever it is generated or whenever it is requested by or on behalf of the County.
2. The Contractor shall maintain daily job reports recording all significant activity on the job, including the number of workers and specific equipment on Site, work activities, work accomplished, problems encountered and delays. Contractor shall provide County with copies for each day Contractor works on the Project, to be delivered to County either the same day or the following morning before starting work at the Site. Contractor shall take weekly progress photographs of all areas of the Work. Contractor shall maintain copies of all correspondence with Subcontractors and records of meetings with Subcontractors. Contractor shall report to the surety promptly upon receiving requests from the surety to provide reporting. Contractor shall provide copies of daily job reports as requested or required by the County or as specified in the Contract.
3. County shall have the right to audit and copy Contractor’s books and records of any type, nature or description relating to the Project (including but not limited to financial records reflecting in any way costs claimed on the Project), and to inspect the Site, including Contractor’s trailer, or other job Site office, and this requirement shall be contained in the subcontracts of Subcontractors working on Site. By way of example, County shall have the right to inspect and obtain copies of all Contract, planning, design, bid, proposal and negotiation documents, cost records and job cost variance reports, design modification proposals, value engineering or other cost reduction proposals, revisions made to the original design, job progress reports, photographs, and as-built drawings maintained by Contractor. Contractor shall preserve such books, records, and other items for a ...
COST DATA. For the cost analysis portion of the study, the Data Provider will share financial data that will allow the research team to measure the cost of the intervention program being studied compared to the cost of the status quo, presented as a cost per program participant. These data may include reports on total program expenditures, broken down by purpose of expenditure, funding source, staff category, and/or for individual staff members. In addition, research staff may require assistance from budget and financial aid staff to provide and clarify information on institution-wide expenditures and financial aid data.
COST DATA. Contractor will furnish to AA in a Microsoft Excel(R) spreadsheet format, within forty-five (45) days after the end of each quarter, the following reports: DOT Form 41 Schedule P-1.2 (Statement of Operations) and P-5.2 (Aircraft Operating Expenses by type). Contractor agrees to provide this information to AA regardless of its obligation to report to the DOT.
COST DATA. A. Contractor shall maintain full and correct information as to the number of workers employed in connection with each subdivision of Work, the classification and rate of pay of each worker in form of certified payrolls, the cost to Contractor of each class of materials, tools and appliances used by Contractor in Work, and the amount of each class of materials used in each subdivision of Work. Contractor shall provide Owner with monthly summaries of this information. If Contractor maintains or is capable of generating summaries or reports comparing actual Project costs with Proposal estimates or budgets, Contractor shall provide Owner with a copy of such report upon Owner’s request and whenever it is generated.
B. Contractor shall maintain daily job reports recording all significant activity on the job, including the number of workers on Site, Work activities, problems encountered and delays. Contractor shall provide Owner with copies for each Day Contractor works on the Project, to be delivered to Owner either the same Day or the following morning before starting work at the Site. Contractor shall take monthly progress photographs of all areas of the Work. Contractor shall maintain copies of all correspondence with subcontractors and records of meetings with subcontractors.
C. Owner shall have the right to audit and copy Contractor’s books and records of any type, nature or description relating to the Project (including but not limited to financial records reflecting in any way costs claimed on the Project), and to inspect the Site, including Contractor’s trailer, or other job Site office, and this requirement shall be contained in the subcontracts of subcontractors working on Site. By way of example, Owner shall have the right to inspect and obtain copies of all Contract Documents, planning and design documents, Proposal and negotiation documents, cost records and job cost variance reports, design modification proposals, value engineering or other cost reduction proposals, revisions made to the original design, job progress reports, photographs, and as-built drawings maintained by Contractor. Owner and any other applicable governmental entity shall have the right to inspect all information and documents maintained under this paragraph 11.B at any time during the Project and for a period of five years following Final Completion. This right of inspection shall not relieve Contractor of its duties and obligations under the Contract Documents. This right of ...
COST DATA. Transportation cost for product delivery is charged on the basis of the distance between the plant/origin and the destination the customer requests the product to be delivered. This assigned destination could be customers’ location or other designated locations or project sites.
1. Customers within the radius X from the plant are charged the same; the only difference here is the order quantity. This is also the case for customers within radius Y.
Figure 4.1: An illustration of pricing rates
COST DATA. (1) Within sixty (60) days of a request, made after the Certification Date, by Class Counsel, acting in good faith and as reasonably required for oral discovery and the trial of the Proceedings, the Settling Defendants shall make reasonable efforts to provide to Class Counsel the following information regarding the Settling Defendants’ standard costs per part number from 2010 onwards:
(i) the customer name, (ii) a general part description and (iii) the cost amount.
COST DATA. E.12.1. This section must be in a submitted separately in a sealed envelope or container, clearly marked “Cost Data” and contain the completed Cost Workbook, Attachment A, identifying cost, and any other document(s) with cost data. The Cost Worksheet must contain the required items.
COST DATA. Sub-recipient shall submit original invoices, as applicable, of equipment purchase order receipts, a signed bill of lading, manufacture cut sheets and other documentation for all installed products to document the products purchased, technical specifications, cost of the project (including labor and materials) and the number and types of equipment installed.
COST DATA. The total costs of all services provided under Article V of this Contract will be tracked by the SFC during the course of this fiscal year. The CDDO will cooperate with the SFC in this process.
COST DATA. Provide a detailed schedule of fees indicating the total maximum cost for each service offered by your facility. Costs should be itemized as indicated in the Fee Schedule (A), but not limited to just those services. Please indicate all related services offered by your facility. Fee proposal is included under separate cover from this document.