Payment Does Not Imply Final Acceptance of Work Sample Clauses

Payment Does Not Imply Final Acceptance of Work. The granting of any payment by Judicial Council as provided in this Exhibit shall in no way lessen the liability of the Consultant to replace unsatisfactory Work or Material, even if the unsatisfactory character of such Work or Material may not have been apparent or detected at the time such payment was made. Materials, Data, components, or workmanship that do not conform to Exhibit D, Work to Be Performed, shall be rejected and shall be replaced by the Consultant without delay. Consultant shall, as authorized, provide the Work as specified in the Statement of Work (SOW) and as may be further specified in Work Orders authorized under this Agreement. The dates of performance and schedule applicable to the provision of the Work under this Agreement will be provided in individual issued Work Orders. Consultant agrees to provide or perform, as specified in this Agreement, the following Work set forth in this section, and as further elaborated in Work Orders when authorized under this Agreement, as well as any other services that are necessary, normal, customary, or incidental to the performance of Consultant’s responsibilities. Work Order may contain additional terms and conditions regarding the Work that is applicable only to the issued Work Order, however, no provision of the Work Order may act to modify or may conflict with the terms con conditions of this Agreement. This scope of work includes, but is not limited to the following: 1) Conduct Phase 1 Environmental Site Assessment 2) Conduct Phase 2 Environmental Site Assessment 3) Conduct Phase 3 Environmental Site Assessment 4) Conduct site visits to identify issues and collect data for environmental concerns for facility operations and occupancy. 5) Conduct inspections and manage field remedial clean-up activities including storage and transport of hazardous materials/hazardous waste. 6) Conduct monitoring and manage clean-up of air, soil, and water/groundwater resources; 7) Provide storm water-related monitoring and inspections for Construction General Permits and Municipal Separate Storm Sewer System (MS4) Permits 8) Conduct inspections and review compliance activities for underground storage tanks and aboveground storage tanks (including associated lines, pumps, and other infrastructure) 9) Prepare spill protection and prevention plans and reports, emergency response reports, worker’s health and safety assessments and reports, and injury and illness plans and reports. 10) Conduct inspections and prepar...
Sample 1
Payment Does Not Imply Final Acceptance of Work. The granting of any payment by the AOC as provided in this Exhibit shall in no way lessen the liability of the Contractor to replace unsatisfactory Work or Material, even if the unsatisfactory character of such Work or Material may not have been apparent or detected at the time such payment was made. Materials, Data, components, or workmanship that do not conform to Exhibit D, Work to Be Performed, shall be rejected and shall be replaced by the Contractor without delay. Consultant shall, as authorized, provide the Work as specified in the Statement of Work (SOW) and as may be further specified in Work Orders authorized under this Agreement. The dates of performance and schedule applicable to the provision of the Work under this Agreement will be provided in individual issued Work Orders. Consultant agrees to provide or perform, as specified in this Agreement, the following Work set forth in this section, and as further elaborated in Work Orders when authorized under this Agreement, as well as any other services that are necessary, normal, customary, or incidental to the performance of Consultant’s responsibilities. Work Order may contain additional terms and conditions regarding the Work that is applicable only to the issued Work Order, however, no provision of the Work Order may act to modify or may conflict with the terms con conditions of this Agreement. This scope of work includes, but is not limited to the following: 1. Provide and/or assist the AOC with any of the following specific Construction Health and Safety Services: 1.1. Conduct Safety and Health Assessments 1.2. Identify Industrial Hazards 1.3. Conduct Activity Hazard Analyses (AHA) on specific industrial or manufacturing processes, 1.4. Prepare Emergency Action Plans 1.5. Develop health and safety plans 1.6. Develop accident prevention plans 2. Provide and/or assist the AOC in providing any of the following specific General Industry Health and Safety Services: 2.1. Conduct Safety and Health Assessments 2.2. Identify Industrial Hazards 2.3. Develop Accident Prevention Plans
Sample 1
Payment Does Not Imply Final Acceptance of Work. The granting of any payment by the AOC as provided in this Exhibit shall in no way lessen the liability of the Contractor to replace unsatisfactory Work or Material, even if the unsatisfactory character of such Work or Material may not have been apparent or detected at the time such payment was made. Materials, Data, components, or workmanship that do not conform to Exhibit D, Work to Be Performed, shall be rejected and shall be replaced by the Contractor without delay. Background The Judicial Council of California (Council), chaired by the Chief Justice of California, is the chief policy making agency of the California judicial system. The California Constitution directs the Council to improve the administration of justice by surveying judicial business, recommending improvements to the courts, and making recommendations annually to the Governor and the Legislature. The Council also adopts rules for court administration, practice, and procedure, and performs other functions prescribed by law. The Administrative Office of the Courts (AOC) is the staff agency for the Council and assists both the Council and its chair in performing their duties. AOC Classification and Compensation Study The AOC has undergone a significant downsizing and restructuring, and has not conducted an in-depth, agency-wide review of the classification and compensation structure in recent years. The AOC Human Resources Services Office (HRSO) provides direct classification and compensation support for employees of the AOC, as well as employees of the California Supreme Court and the Courts of Appeal, and, upon request, the Superior Courts of California. This project is a comprehensive study of only AOC positions, classifications, and compensation. The Chief Justice sets compensation rates for all AOC employees per Cal. Const., Art VI, §6; Gov. Code, §19825(b). Employees of the AOC are not represented by unions. Currently, the AOC has 21 offices spread over four divisions. There are approximately 725 incumbents in 183 job classifications across various functional areas such as legal, finance, administration, education, information systems, court services, human resources, governmental affairs, and security. The AOC seeks to consolidate classifications no longer deemed essential in meeting the business needs of the organization with the goal of streamlining the classification system. The AOC’s salary listing, including links to classification specifications, is available through the foll...
Sample 1
Payment Does Not Imply Final Acceptance of Work. The granting of any payment by the AOC as provided in this Exhibit shall in no way lessen the liability of the Contractor to replace unsatisfactory Work or Material, even if the unsatisfactory character of such Work or Material may not have been apparent or detected at the time such payment was made. Materials, Data, components, or workmanship that do not conform to Exhibit D, Work to Be Performed, shall be rejected and shall be replaced by the Contractor without delay.
Sample 1

Related to Payment Does Not Imply Final Acceptance of Work

  • Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.

  • Acceptance of Work The completion of the Work shall be subject to acceptance by NYSERDA in writing of all deliverables as defined in Exhibit A, Statement of Work.

  • Statement of Work The Statement of Work to which Grantee is bound is incorporated into and made a part of this Grant Agreement for all purposes and included as Attachment A.

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. 13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition. 13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and 13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph 13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State. 13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal. 13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the

  • COMMENCEMENT OF WORK UNDER A SOW AGREEMENT Commencement of work as a result of the SOW-RFP process shall be initiated only upon issuance of a fully executed SOW Agreement and Purchase Order.

  • Final Acceptance When the Project/Service or any portion thereof, as designated by the COUNTY, is ready for its intended use, the COUNTY and any other invited parties shall make an inspection of the Project/Service, to verify its completeness and develop a punch list of items needing completion or correction before final payment will be made. CONTRACTOR shall have ten (10) calendar days to correct all deficiencies. An eighty-dollar ($80.00) re-inspection fee shall be applied for the third inspection and any required re-inspection thereafter. The COUNTY shall have the right to exclude CONTRACTOR from those portions of the work designated as complete after the inspection; provided, however, that CONTRACTOR will have reasonable access for the time allotted by the COUNTY to complete or correct items on the punch list. When the work provided for under this Agreement has been completely performed by CONTRACTOR, and the final inspection has been made by the COUNTY, a final invoice will be prepared by the CONTRACTOR. The amount of this invoice, less any sums that may have been deducted or retained under the provisions of this Agreement, will be paid to CONTRACTOR in accordance with this Agreement, and after CONTRACTOR has agreed in writing to accept the balance due, as determined by the COUNTY, as full settlement of the account under the contract and of all claims in connection therewith. Occupancy by the COUNTY alone does not constitute final acceptance.

  • Commencement of Work Engineer shall not commence any field work under this Contract until he/she/it has obtained all required insurance and such insurance has been approved by County. As further set out below, Engineer shall not allow any subcontractor/subconsultant(s) to commence work to be performed in connection with this Contract until all required insurance has been obtained and approved and such approval shall not be unreasonably withheld. Approval of the insurance by County shall not relieve or decrease the liability of Engineer hereunder.

  • Required Acceptance of Daily Load Deliveries and Notification If the State is harmed by purchaser’s refusal to accept up to 10 truck deliveries of any one sort per day, Purchaser will be in breach of contract and subject to damages as per the D-026.2 and D-027.2 clauses. A truck delivery is all the wood delivered including sorts on super trucks, mule trains and pups brought to the delivery point by a single truck. The Purchaser shall notify the Contract Administrator at least 48 hours in advance if: 1. Purchaser intends to limit the number of truck deliveries accepted on any day to less than that listed above, or 2. Purchaser intends to limit the number of truck deliveries accepted on any day to the number listed above.

  • Completion of Work The Contractor agrees to complete the work on, or before October 29, 2021.

  • Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.