Pipeline Project Sample Clauses

Pipeline Project. The DEVELOPER shall have the authority to attempt to privately acquire necessary right-of-way or to participate to the extent permitted by the FDOT in regard to the actions required prior to condemnation. To the extent the COUNTY has condemning authority, COUNTY staff involvement shall be limited to preparation of an engineering memorandum in support of a Resolution of Necessity with the timely support and cooperation of the above consultants and professionals and providing necessary representatives and witnesses in conjunction with any eminent domain proceedings. After receipt of a request by the DEVELOPER for the Resolution of Necessity, the COUNTY'S preparation and consideration of the Resolution of Necessity shall not be unreasonably withheld or delayed. The DEVELOPER, not later than the time when sixty (60) percent design plans are submitted, shall identify all real estate parcels required for the Required Roadway Improvements and identify the appropriate interests in real estate for right-of-way acquisition and furnish the same to the COUNTY. The COUNTY, not later than thirty (30) days after its receipt of the submittal, shall either approve or disapprove the submittal. If the COUNTY disapproves the submittal, it shall provide comments to the DEVELOPER explaining the reasons for the disapproval. Right-of-way maps shall be prepared in accordance with the requirements of the COUNTY'S and State of Florida's Minimum Technical Standards. Upon COUNTY approval of the submittal, the DEVELOPER shall select an attorney acceptable to the COUNTY to represent the COUNTY in the acquisition of right-of-way. Thereafter, the DEVELOPER, in conjunction with the mutually agreeable attorney, shall proceed to acquire for the COUNTY, and in the COUNTY'S name, the right-of-way pursuant to applicable law. The COUNTY, its elected officials, employees, and representatives shall not be liable under any circumstances to the DEVELOPER, its employees, contractors, material suppliers, agents, representatives, or customers for any delay occasioned by the inability to obtain the right-of-way. The DEVELOPER shall submit quarterly project status reports that document the actions and progress of right-of-way acquisitions to the COUNTY Engineer or his designee.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Pipeline Project. The foregoing paragraph shall also apply to Pipeline Project No. 2 if it is determined that Pipeline Project No. 2 is to be constructed by DEVELOPER.
Sample 1Sample 2Sample 3
Pipeline Project. In the event of a conflict between the foregoing requirements and applicable FDOT or State law competitive-bidding requirements for the S.R. 54 Pipeline Project, the FDOT requirements shall govern.
Sample 1Sample 2Sample 3
Pipeline Project. The DEVELOPER shall be solely responsible for ensuring that the S.R. 54 Pipeline Project is constructed in accordance with the plans, specifications, and required standards. Observations by the COUNTY or FDOT or their inspectors that do not discover that construction is not in accordance with the approved plans, specifications, and required standards shall not be deemed a waiver of the DEVELOPER'S requirements herein.
Sample 1Sample 2Sample 3
Pipeline Project. The new delivery pipeline system that includes increased delivery to the Lithia Point of Connection (Pipeline Segment A) and delivery to a New Point of Connection from the regional system (Pipeline Segment B).
Sample 1Sample 2
Pipeline Project. This Pipeline Project is the widening of S.R. 54 from a four (4) lane divided, rural roadway to a six (6) lane divided, rural roadway from the existing six (6) lane section west of the Suncoast Parkway interchange, eastward to the existing six (6) lane section west of U.S. 41, as shown on Exhibit D (Roadway Link Improvements). The Project shall include intersection improvements at S.R. 54 and Tower Road/Xxxxxx Xxxx Boulevard, Sunlake Boulevard, Oakstead, the Suncoast Parkway interchange, and Ballantrae Boulevard as depicted in Exhibit E as well as any other intersection improvements determined by the COUNTY and FDOT to be necessary during the design and permitting of the Project. The Project shall also include all shoulders, striping, signalization, signage, medians, stormwater-drainage facilities, floodplain mitigation, wetland mitigation, guardrails, and other roadway appurtenances, all as determined by the COUNTY, FDOT, and other permitting agencies, to be necessary during the design and permitting of the Pipeline Project (Roadway Appurtenances). Construction of this improvement satisfies Forty Million Seventy Thousand Seven Hundred Thirty-One and 00/100 Dollars ($40,070,731.00) (in July 2005 dollars) of the DEVELOPER'S proportionate-share obligations. The cost estimate for this improvement is based upon the provisions of Southwest Florida Water Management District (a.k.a. SWFWMD) in adopted DA Permit No. 43162251.00 and assumes no right-of-way acquisition for additional pond sites or floodplain mitigation. The DEVELOPER shall design, permit, construct, and acquire right-of-way (where necessary) for the S.R. 54 Pipeline Project, regardless of cost. Except for the Site-Related
Sample 1Sample 2
Pipeline Project. Such LOC shall comply with the Section 9 of this DA. The DEVELOPER shall complete the design (100 percent) of the S.R. 54 Pipeline Project by December 31, 2008. Construction of the S.R. 54 Pipeline Project shall commence by June 30, 2009, and shall be completed prior to December 31, 2010, or prior to the final plat approval of the 1,500th residential dwelling unit (du), whichever occurs first. The DEVELOPER shall post a Performance Guarantee for the S.R. 54 Pipeline Project in accordance with Section No. 9 of this DA.
Sample 1
AutoNDA by SimpleDocs
Pipeline Project. The Pipeline Project work requested under this Request for Proposal (“RFP”) for the Pipeline Project includes all work required to design, construct, commission, operate, and maintain the Pipeline Project, including the following: (a) Design the Pipeline Project, including a pipeline lateral between the Delivery Point and a natural gas trading hub or hubs on the Integrated Distribution System that can transport natural gas to the IGS as required, together with interconnection facilities necessary to connect the pipeline lateral with both the Integrated Distribution System and the Delivery Point, and metering stations to measure the quantity of natural gas delivered. The Pipeline Project design will be fit-for-purpose given the location and operations of the IGS, comply with all applicable federal, state, county, local, and/or municipal laws, regulations and standards, including 49 CFR 192 and ASME B31.8 and B31.8S, and will support a construction schedule that meets requirements for initiating the testing, startup, and commissioning of the Pipeline Project by the Commissioning Commencement Date. (b) Obtain all federal, state, county, and/or municipal permits (including conditional use permits), authorizations, consents, registrations, variances, and other approvals required by Proposer for the construction, operation, and maintenance of the Pipeline Project, together with any crossing or encroachment agreements for crossing state and county roads, other pipelines and power lines, canals, etc. (c) Obtain necessary rights-of-way for the pipeline lateral from the interconnection facilities on the Integrated Distribution System to the Delivery Point, all in compliance with applicable federal, state, county, and/or municipal laws and regulations including, if applicable, the National Environmental Policy Act, the National Historic Preservation Act, the Endangered Species Act, and the rules and regulations promulgated by the Federal Energy Regulatory Commission. (d) Construct, startup, and commission the Pipeline Project according to its design, and the practices; methods; specifications; licensing requirements; standards of care, skill, diligence, safety, and performance; and acts generally engaged in or observed by recognized and experienced national construction companies operating nationally, as in effect from time to time, which are consistent with good judgment, applicable laws, rules, regulations, codes, and standards; reliability; safety; economy; effici...
Sample 1
Pipeline Project 
Sample 1Sample 2Sample 3See All (5)

Related to Pipeline Project

  • Project 3.01. The Recipient declares its commitment to the objectives of the Project. To this end, the Recipient shall carry out the Project in accordance with the provisions of Article IV of the General Conditions.

  • Project Site The “Project Site” is the place where the Work is being carried on.

  • Pipelines Developer shall have no interest in the pipeline gathering system, which gathering system shall remain the sole property of Operator or its Affiliates and shall be maintained at their sole cost and expense.

  • The Project The Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part.

  • Generating Facility The Interconnection Customer’s device for the production of electricity identified in the Interconnection Request, but shall not include the Interconnection Customer’s Interconnection Facilities.

  • Underground Facilities All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including without limitation those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems.

  • Projects There shall be a thirty (30) km free zone around the projects excluding the Metro Vancouver Area. For local residents, kilometers shall be paid from the boundary of the free zone around the project. Workers employed by any contractor within an identified free zone who resides outside of that same free zone will be paid according to the Kilometer Chart from the project to their residence less thirty

  • Access to Project Site Redeveloper shall permit the representatives of the City to enter Project Site at any and all reasonable times, as the City may deem necessary for the purposes of this Redevelopment Agreement, including but not limited to work and inspection of all work being performed in connection with the construction of the Redeveloper Improvements. Similarly, the City shall permit Redeveloper such entry upon the public rights of way for such purposes. No compensation shall be payable nor shall any charges be made in any form by any party for the access or inspection provided for in this Section. The City’s right of access granted under this Section shall terminate upon issuance by the City of the Redeveloper’s Certificate of Completion of Redeveloper Improvements. Notwithstanding the above, Redeveloper shall not be relieved of the provisions contained in Chapter 14.29 of the Lincoln Municipal Code regarding the use of streets for private construction purposes.

  • Development of the Project 4.1 TSP's obligations in development of the Project: a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project; b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with: i. the Electricity Act and the Rules made thereof; ii. the Grid Code; iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020. iv. Safety/ security Guidelines laid down by the Government; v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement; c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code. d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement; e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities; f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities; g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities; h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this; i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India; j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above. k. to comply with all its obligations undertaken in this Agreement. 4.2 Roles of the Nodal Agency in implementation of the Project: 4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia: a. appoint an Independent Engineer within 90 days of the Effective Date b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project; c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and f. perform any other responsibility (ies) as specified in this Agreement.

  • MAINTENANCE OF THE SAID BUILDING / APARTMENT / PROJECT The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the association of the allottees. The cost of such maintenance has been included in the Total Price of the [Apartment/Plot].

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!