Transportation Management Plan for Use During Construction Sample Clauses

Transportation Management Plan for Use During Construction. Temporary closures of SR-905, Xxxxxx Xxxxx Drive and Alta Road will be required to construct SR-11. Therefore, temporary detours will be necessary. Sanyo Avenue will serve as the main detour when Xxxxxx Xxxxx Drive and Alta Road are closed. During construction of the project, falsework will be constructed over Sanyo Avenue, thereby closing the Sanyo Avenue detour for approximately two weeks that will include one lane closure with a flagman during the day and complete closure at night. During this intermittent closure of Sanyo Avenue, traffic will be redirected along Airway Road, La Media Road, and Otay Mesa Road. It is assumed that the detour utilizing Sanyo Avenue will be required throughout the majority of the project‟s construction period. Xxxxxx Xxxxx Drive will need complete closure for five days and a new at-grade detour will be built adjacent to the new bridge site that will remain open for six months. Falsework will also be constructed over SR-905 for the eastbound SR-905 connector to SR-11 and will require a temporary detour for approximately four nights to construct and remove falsework. When this closure occurs, both the eastbound and westbound SR-905 will be detoured along Siempre Viva Road and La Media Road where there are SR-905 interchanges at both local roads. As part of the Preferred Alternative the southbound SR-125 to eastbound SR-11 connector will require a temporary closure of Otay Mesa Road for three nights to construct and remove falsework. When this occurs, the detour will be along Harvest Road, Airway Road and La Media Road. Reasonable access to businesses along the detours should be maintained throughout the duration of the Project‟s construction. The Project expects the main detour to be operational throughout the duration of construction and assumes no modifications are necessary to any streets. In order to plan for minimizing motorist delays while implementing projects on the State highway system, a Preliminary Transportation Management Plan (TMP) has been developed in conjunction with this Project Report (Attachment K). The TMP addresses closures and other requirements to complete the project in a cost effective and timely manner with minimal interference with the traveling public. Specific objectives of the TMP are: Reduce traffic delay or time spent in the queue to less than 15 minutes above normal recurring traffic delay. Maintain traffic flow throughout the SR-905 corridor and the surrounding areas. Provide a safe environm...
AutoNDA by SimpleDocs
Transportation Management Plan for Use During Construction. A Transportation Management Plan (TMP) will be prepared during the final design phase to minimize delay and inconvenience to the traveling public, in accordance with Caltrans requirements and guidelines. The TMP will address traffic impacts from staged construction, detours, and specific traffic handling concerns during construction of the Project. A TMP Data Sheet is provided in Attachment H and includes a preliminary estimate of cost for these activities. The TMP for the project will be further developed during the final design phase and may require additional traffic studies to evaluate traffic operations. The need for lane closures during off-peak hours or short-term detour routes for ramp closures will be identified in the TMP. The TMP will also include briefings to local officials and a public information program to inform the public of project progress and upcoming closures and detours. Table 7-2 is a list of the TMP strategies and contains a brief description of each item that should be further detailed in the TMP. Additional aspects of a TMP should include ride-sharing agencies, transit operators, and neighborhood and special-interest groups; consideration of construction strategies and contract incentives; and CHP and local law enforcement involvement. Integrated Incident/Emergency Management Program The use of electronics, computers, and wireless communication systems to coordinate real-time responses to incidents and emergencies by various emergency providers and enforcement agencies, particularly around construction sites. Freeway Service Patrol Dedicated patrol trucks along construction site, particularly during peak commute hours. California Highway Patrol Additional CHP presence will be required during temporary partial and full freeway and ramp closures. Construction Zone Enhanced Enforcement Program Cooperative program between Caltrans and the CHP for proactive police enforcement at construction sites on the State highway system. Portable Changeable Message Signs These signs used to inform motorists about traffic conditions and future roadwork. Traffic Control Improvements Examples include changes in signal timing, use of temporary signals, adding detectors for actuation, and coordinating traffic signals. Street Improvements, Signing, and Striping Examples include temporary removal of median islands or on-street parking, changes in turn restrictions and prohibitions, and provision of detour and guidance signage, etc. Comprehensive GIS/Dat...

Related to Transportation Management Plan for Use During Construction

  • Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Transportation Management Tenant shall fully comply with all present or future programs intended to manage parking, transportation or traffic in and around the Building, and in connection therewith, Tenant shall take responsible action for the transportation planning and management of all employees located at the Premises by working directly with Landlord, any governmental transportation management organization or any other transportation-related committees or entities.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).

  • Quality Management System Supplier hereby undertakes, warrants and confirms, and will ensue same for its subcontractors, to remain certified in accordance with ISO 9001 standard or equivalent. At any time during the term of this Agreement, the Supplier shall, if so instructed by ISR, provide evidence of such certifications. In any event, Supplier must notify ISR, in writing, in the event said certification is suspended and/or canceled and/or not continued.

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.

  • Procurement of Goods and Services (a) If the HSP is subject to the procurement provisions of the BPSAA, the HSP will abide by all directives and guidelines issued by the Management Board of Cabinet that are applicable to the HSP pursuant to the BPSAA. (b) If the HSP is not subject to the procurement provisions of the BPSAA, the HSP will have a procurement policy in place that requires the acquisition of supplies, equipment or services valued at over $25,000 through a competitive process that ensures the best value for funds expended. If the HSP acquires supplies, equipment or services with the Funding it will do so through a process that is consistent with this policy.

  • Project Management Plan 3.2.1 Developer is responsible for all quality assurance and quality control activities necessary to manage the Work, including the Utility Adjustment Work. Developer shall undertake all aspects of quality assurance and quality control for the Project and Work in accordance with the approved Project Management Plan, Good Industry Practice and applicable Law. 3.2.2 Developer shall develop the Project Management Plan and its component parts, plans and other documentation in accordance with the requirements set forth in Section 1.5.2.5

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!