CONTRACT TIME EXTENSIONS Sample Clauses

CONTRACT TIME EXTENSIONS. ‌ A Contract Time Extension may be granted as determined by ADOT. A time extension is valid only if approved in writing as a modification to this Contract. Time extensions for projects using Federal-aid Highway funds over five (5) years after the original Contract completion date shall be approved by the Federal Highway Administration (FHWA).
Sample 1Sample 2Sample 3See All (18)
AutoNDA by SimpleDocs
CONTRACT TIME EXTENSIONS. Notwithstanding anything to the contrary in this Trade Contract Agreement, the Trade Contractor agrees that, regardless of the cause of delay and whether or not any extension of Contract Time may be granted therefore, Trade Contractor shall continue to prosecute all Trade Contractor Work not directly affected by said cause of delay and, with respect to such portion or portions of the Trade Contractor Work as may be so affected, shall take all reasonable measures to minimize the effect of said cause of delay. It is a condition precedent to the consideration or prosecution of any Claim for an extension of Contract Time that the foregoing provisions be strictly adhered to in each instance and, if the Trade Contractor fails to comply, Trade Contractor shall be deemed to have waived the Claim to the extent that proper mitigation would have shortened the period of delay. The Trade Contractor further acknowledges and agrees that adjustments in the Contract Time will be permitted for a delay only to the extent such delay (a) is not caused, or could not have been reasonably avoided, by the Trade Contractor, or (b) could not be reasonably limited or avoided by the Trade Contractor’s timely notice to the Authority of the delay or reasonable likelihood that a delay will occur.
Sample 1Sample 2Sample 3See All (7)
CONTRACT TIME EXTENSIONS. ‌ A Contract Time Extension may be granted as determined by ADOT. A time extension is valid only if approved in writing as a modification to this Contract.
Sample 1Sample 2
CONTRACT TIME EXTENSIONS. The Contractor shall not claim or be entitled to any compensation or damages from the Owner because of delay caused by the Owner, the Architect, or any person working for either of them, and any entitlement therefore is hereby waived. The Contractor agrees that his sole remedy shall be an extension of time to complete the Work as provided in the Contract Documents, except that the Owner agrees to compensate the Contractor for any damages resulting from any affirmative, willful act in bad faith performed by the Owner or his employees which unreasonably interferes with the Contractor's ability to complete the Work within the Contract Time.
Sample 1Sample 2
CONTRACT TIME EXTENSIONS. All claims for extensions of time shall be made in writing in accordance with the process for Change Orders described in Section 24.3; otherwise, they will be disallowed. If the Contractor is delayed at any time in the progress of the Work by any act or neglect of Owner, or its employee, or by any separate contractor employed by Owner, or by changes ordered in the Work, or Unavoidable Delay, the Contract Time may be extended by Change Order for such reasonable time as Owner may determine. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Contractor knows of the occurrence of an Unavoidable Delay or any other delay. 5.5.1 An extension of time for an Unavoidable Delay shall only be for a period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay. 5.5.2 An extension in Contract Time for a delay will be allowed only in the case that a Normal Working Day or Accepted Working Day is lost. A “Normal Working Day” is defined as any day, except weekends and holidays, during which the Contractor can work for at least four (4) hours. Delays will not be allowed for any other non-working days (e.g., weekends and holidays). 5.5.3 Claims by the Contractor for delays will not be allowed on account of failure to furnish interpretations, until fourteen (14) Calendar Days after a Request for Information is submitted by the Contractor, and then not unless such claim is reasonable.
Sample 1Sample 2
CONTRACT TIME EXTENSIONS. The Department may grant an extension of Contract Time when a controlling item of work is delayed by factors not reasonably anticipated or foreseeable at the time of bid. The Department may allow such extension of time only for delays occurring during the Contract Time period or authorized extensions of the Contract Time period. When failure by the Department to fulfill an obligation under the Contract results in delays to the controlling items of work, the Department will consider such delays as a basis for granting a time extension to the Contract. 1. The Contractor being unable to work at least 50% of the normal work day on pre-determined controlling work items; or 2. The Contractor must make major repairs to work damaged by weather, provided that the damage is not attributable to the Contractor’s failure to perform or neglect; and provided that the Contractor was unable to work at least 50% of the normal workday on pre-determined controlling work items. When the Department grants a time extension due to rains or other inclement weather, the Contractor shall submit any objection to the additional time in writing within ten calendar days from receipt of written notice from the Engineer. Failure to submit a written appeal within ten calendar days from receipt of the written notice shall constitute a waiver of any and all rights to appeal the Department’s decision at a later time. No additional compensation will be made for delays caused by the effects of inclement weather. The Department will consider the delays in delivery of materials or component equipment that affect progress on a controlling item of work as a basis for granting a time extension if such delays are beyond the control of the Contractor or supplier. Such delays may include an area-wide shortage, an industry-wide strike, or a natural disaster that affects all Citywide Sidewalk Improvements feasible sources of supply. In such cases, the Contractor shall furnish substantiating letters from a representative number of manufacturers of such materials or equipment clearly confirming that the delays in delivery were the result of an area-wide shortage, an industry-wide strike, etc. No additional compensation will be made for delays caused by delivery of materials or component equipment. The Department will not consider requests for time extension due to delay in the delivery of custom manufactured equipment such as traffic signal equipment, highway lighting equipment, etc., unless the Contractor...
Sample 1
CONTRACT TIME EXTENSIONS. 5.1 Should Construction Manager be obstructed or delayed in the prosecution of or completion of the Work as a result of unforeseeable causes beyond the control of Construction Manager, and not due to its fault or neglect, including but not restricted to acts of God or the public enemy, acts of government, fires, floods, epidemics, quarantine regulation, strikes, lockouts, utility work being performed within the Project limits, or by unusually severe weather conditions by comparison with the ten year Osceola City, Florida average not reasonably anticipatable, Construction Manager shall notify City’s Representative and Architect/Engineer, in writing within seven (7) calendar days after the commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which Construction Manager may have had to request a Contract Time Extension. Contract Time Extension requests shall be evaluated through the Change Order process. 5.2 If Construction Manager encounters on the Project site any materials reasonably believed by Construction Manager to be petroleum, or petroleum related products, or other hazardous or toxic substances which have not been rendered harmless, Construction Manager immediately shall: (i) stop Work in the area affected, and (ii) report the condition to City’s Representative in writing. If the Work is so stopped in excess of ten (10) days and hazardous material is found, the Work in the affected area shall not thereafter be resumed except by Change Order. Any such Change Order shall include, but not be limited to, an adjustment to the Contract Time as appropriate. If no hazardous material is found after the Work is stopped, no Change Order is required to resume the Work in the affected area. Further, if the hazardous material was generated or caused by the Construction Manager or any of its employees, agents, subcontractors, or material suppliers, no Change Order will be required for an adjustment in the Contract Time and Construction Manager shall indemnify the City and hold City harmless for any costs incurred by the City with respect to such material. 5.3 NO DAMAGES FOR DELAY. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of the Work from any cause whatever, including those for which the City and Architect/Engineer may be responsible, in whole or in part, shall relieve Construction Manager of his duty to perform, or give rise to any right to damages or additiona...
Sample 1
AutoNDA by SimpleDocs
CONTRACT TIME EXTENSIONS. All claims for extensions of time shall be made in writing to the Owner within seven (7) calendar days after the beginning of the delay; otherwise, they will be disallowed. 1. Delays which could have been avoided by the exercise of care, prudence, foresight, and diligence on the part of the Contractor. 2. Delays in the execution of parts of the work, which may in themselves be unavoidable, but do not prevent or delay prosecution of other parts of the work, or the completion of the whole work within the time specified. 3. Delays arising from interruptions occurring during the prosecution of the work on account of reasonable interference of other contractors employed by the Owner, which do not prevent the completion of the whole work within the contract time.
Sample 1

Related to CONTRACT TIME EXTENSIONS

  • Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).

  • Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.

  • Contract Extension The City may, in its sole discretion, unilaterally exercise an option to extend the Contract as described in the Contract Documents. In addition, the City may, in its sole discretion, unilaterally extend the Contract on a month-to-month basis following contract expiration if authorized under Charter section 99 and the Contract Documents. Contractor shall not increase its pricing in excess of the percentage increase described in the Contract.

  • Lease Extension Lessee may request Lessor to extend the original Scheduled Expiration Date of each Lease Agreement for an additional period of three (3) years by appropriately completing, executing and delivering to Agent a written request in the form of Exhibit G(2), together with an attachment thereto setting forth the terms upon which Lessee would propose for the requested extension (a "Lease Extension Request"). Lessee shall deliver each Lease Extension Request to Agent not more than twelve (12) months and not less than nine (9) months before the original Scheduled Expiration Date. Agent shall promptly deliver to Lessor and each Participant three (3) copies of each Lease Extension Request received by Agent. If Lessor or a Participant, in its sole and absolute discretion, consents to a Lease Extension Request, such Person shall evidence such consent by executing and returning two (2) copies of such Lease Extension Request to Agent not later than the last Business Day which is not less than seven (7) months prior to the original Scheduled Expiration Date for the applicable Lease Agreement. Any failure by Lessor or any Participant so to execute and return a Lease Extension Request shall be deemed a denial thereof. If Lessee shall deliver a Lease Extension Request to Lessor pursuant to the first sentence of this Subparagraph 2.09(b), then not later than the last Business Day which is not less than six (6) months prior to the original Scheduled Expiration Date for the applicable Lease Agreement, Agent shall notify Lessee, Lessor and the Participants in writing whether (i) Agent has received a copy of the Lease Extension Request executed by Lessor and each Participant, in which case the definition of "Scheduled Expiration Date" set forth in Subparagraph 2.02(a) of the applicable Lease Agreement shall be deemed extended to the date which is three (3) years after the original Scheduled Expiration Date (subject to the receipt by Agent of any amounts payable by Lessee in connection with such extension), or (ii) Agent has not received a copy of the Lease Extension Request executed by Lessor and each Participant, in which case such Lease Extension Request shall be deemed denied. Lessee acknowledges that neither Lessor nor any Participant has promised (either expressly or implicitly), or has any obligation or commitment, to extend or consent to the extension of the Scheduled Expiration Date for either Lease Agreement at any time.

  • Patent Extensions Subject to the remainder of this Section 6.6, if any election for patent term restoration or extension, supplemental protection certificate or any of their equivalents may be made with respect to any Patent within the Licensed IP, after consultation with Celgene, the Parties will discuss and seek to reach mutual agreement whether or not to take such action. If the Parties are not able to reach mutual agreement, (a) Celgene will have the sole right to make the final decision whether or not to seek such patent term restoration or extension, supplemental protection certificate or any of their equivalents with respect to Specific Patents and Patents within the Collaboration IP licensed to Celgene hereunder and (b) Bluebird will have the sole right to make the final decision whether or not to seek such patent term restoration or extension, supplemental protection certificate or any of their equivalents with respect to all other Patents within the Licensed IP.

  • Term of Contract; Contract Extension The Contract will be in effect from the Effective Date (15 December 2016) through 31 December 2018. DAS, in its sole discretion, may extend this Contract for additional terms beyond the original term, prior to Termination or expiration, one or more times for a combined total period not to exceed the complete length of the original term.

  • No Extensions The period of time within which the Extension Right may be exercised shall not be extended or enlarged by reason of Tenant’s inability to exercise the Extension Right.

  • Due Date Extension If any payment of principal or Yield with respect to any Advance falls due on a day which is not a Business Day, then such due date shall be extended to the next following Business Day, and additional Yield shall accrue and be payable for the period of such extension at the rate applicable to such Advance.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof

  • Contract Term Extension “Contract Term Extension” means an extension of the term of this contract, at the request of Purchaser, under this Subsection. This Subsection does not obligate Contracting Officer to grant Contract Term Extension.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!