DEVELOPER’S CONSTRUCTION OBLIGATIONS Sample Clauses

DEVELOPER’S CONSTRUCTION OBLIGATIONS. In addition to the foregoing, the Developer covenants and agrees that during the course of the construction of the Pre-Servicing Works, the Developer shall: (a) Continue to maintain the erosion and siltation control devices and structures, fencing, and access control; (b) Put and keep in place measures to control ponding, weeds, dust and mud as well as erosion, siltation and slippage conditions; (c) Continuously keep all roads and sidewalks used for access to the Lands as well as streets and sidewalks surrounding the Lands in good condition, free from mud and dust during construction; (d) Maintain all parking spaces and driveways with a stable surface so as to prevent the raising of dust; (e) Continue to maintain tree preservation and protection for existing trees; (f) Supply and install, at its cost, all traffic control signs and devices and prior to roadways being used, to erect signs a minimum of 1.2 metres by 1.5 metres to read as follows: “ROAD NOT ASSUMED BY MUNICIPALITY – USE AT YOUR OWN RISK”; (g) Prior to any construction, provide construction access to the Lands including all necessary signage, whether temporary or permanent, and which approved access will be the only access to the Lands until otherwise authorized by the Municipality with the temporary access to be removed by the Developer when directed by the Municipality; (h) Construct all Pre-Servicing Works to that they will conform to the road, lot and building block pattern of the draft plan of subdivision; (i) Permit, at all times, access to the Lands by the Municipality, its employees, agents and designates to inspect and otherwise observe the progress of construction, and if necessary, to effect emergency repairs to take remedial action; (j) Maintain all access roads in good repair; (k) Not interfere with or obstruct the use of sidewalks and roadways outside the limits of the Lands without the consent of the Municipality; (l) Maintain an unobstructed emergency route at all times with a minimum width of six (6) metres constructed of granular and with sufficient compaction to provide access for all emergency vehicles; (m) Be responsible for any damage caused to any existing utility, road, street, structure or plan; (n) Ensure that there are no hazardous conditions on the Lands; (o) Dispose of all construction refuse and debris in an orderly and sanitary fashion off the Lands; (p) Not engage in any blasting operations without the consent of the Municipality and providing appropriate insuran...
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
DEVELOPER’S CONSTRUCTION OBLIGATIONS. Developer shall construct or cause to be constructed the Private Improvements within the times and in the manner set forth in this Article and as more particularly set forth in the Schedule of Performance and the Scope of Development, including the Construction Documents, as either may be amended from time to time in accordance with this Agreement or the Ground Lease. All construction with respect to the Project shall be accomplished expeditiously, diligently, within the timeframes set forth within the Schedule of Performance and in accordance with good construction and engineering practices and applicable laws. Without limiting the provisions of Attachment 15A hereof (SCA/MMRP), Developer shall undertake commercially reasonable measures to minimize damage, disruption or inconvenience, caused by such work and make adequate provision for the safety and convenience of all persons affected by such work. Developer, while performing any construction with respect to the Project, shall undertake commercially reasonable measures in accordance with good construction practices to minimize the risk of injury or damage to adjoining portions of the Property and any improvements thereon and the surrounding property, and to members of the public, caused by or resulting from the performance of such construction. In order to protect the City's proprietary interest in prompt completion of construction, Developer shall use commercially reasonable efforts, prior to commencement of construction, to enter into a project labor agreement with the Building & Construction Trades Council of Alameda County and its affiliated unions. Such project labor agreement shall require such unions (i) to refrain from work stoppages on project construction, and (ii) to take steps to facilitate compliance contractor compliance with the Construction Jobs Policy, including priority referral of Local Residents (as defined in the Construction Jobs Policy) and permitting contractors to employ Local Residents referred by the Jobs Center (as defined in the Construction Jobs Policy) as described in the Construction Jobs Policy.
Sample 1
DEVELOPER’S CONSTRUCTION OBLIGATIONS. ‌ (a) Developer shall commence construction and carry out the development of Improvements diligently to completion on the Site within the times and in the manner set forth herein and in the Schedule of Performance (Attachment 5) and Scope of Development (Attachment 6), as such dates may be extended from time to time as provided herein (including, without limitation, events of Force Majeure). (b) Developer shall construct, or cause to be constructed, the Improvements in a first class manner, in accordance with Section 4.02(a) above and with applicable law, including the San Francisco Building Code and Administrative Bulletin AB-093 (Implementation of Green Building Regulations). (c) Sixty (60) days prior to the Construction Commencement Date, Developer shall submit to Successor Agency for its review and approval an active community liaison program for keeping neighborhood residents informed about construction of the Improvements. (d) Developer shall comply with all City construction noise ordinances and regulations including, but not limited to, the following: (i) San Francisco Police Code Article 29 “Regulation of Noise”; and (ii) DBI’s “Night Noise Permit Issuance Policy and Procedure”.
Sample 1
DEVELOPER’S CONSTRUCTION OBLIGATIONS. The Developer shall construct (or irrevocably commit adequate funds to construct) the following improvements in accordance with the provisions of the Capital Facilities Phasing Plan, Exhibit F: (a) Water storage tank and connecting waterlines to Steamboat 700: if required by the City-wide Master Water and Wastewater Master Plan. (b) Those facilities required by the City-wide Water and Wastewater Master Plan as said plan may be amended to meet SB 700 Development Water and Sewer Master Plan requirements at the time of platting, excluding water and wastewater treatment and storage facilities (other than the water storage tank identified in 3(a) above). (c) Construction shall comply with the applicable requirements of the City of Steamboat Springs standard specifications for water and wastewater utilities in effect at the time of construction.
Sample 1
DEVELOPER’S CONSTRUCTION OBLIGATIONS. The Developer shall construct or irrevocably commit adequate funds to construct those facilities shown on the master drainage plan in accordance with the phasing schedule set forth in such plan.
Sample 1

Related to DEVELOPER’S CONSTRUCTION OBLIGATIONS

  • ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Design and Construction In complying with the requirements of the specification both with respect to arrangement and detail, design is to conform to the best current engineering practice. Each of the several parts of the material is to be of the maker’s standard design provided that this design is in general accordance with the specification. The essence of design should be simplicity and reliability in order to give long continuous service with high economy and low maintenance cost. Particular attention should be paid to internal and external access in order to facilitate inspection, cleaning and maintenance. The design dimensions and materials of all parts are to be such that they will not suffer damage as a result of stresses under the most severe conditions. Fully detailed specifications of the several parts of the material are to be submitted describing particularly the materials to be used. The materials used in the construction of the material are to be of the highest quality and selected particularly to meet the duties required of them. Mechanisms are to be constructed to avoid sticking due to rust or corrosion. Workmanship and general finish are to be of the highest class throughout. All similar parts of the material are to be interchangeable. All equipment is to operate without undue vibration and with the least possible amount of noise and is not to cause a nuisance. All equipment is to be designed to minimize the risk of fire and any damage, which may be caused in the event of fire. The equipment is also to be designed to prevent ingress of all vermin, accidental contact with live parts and to minimize the ingress of dust and dirt. The use of materials, which may be liable to attack by termites or other insects, is to be avoided.

  • Notifications of Outages and Maintenance In the event that a Registry Operator plans maintenance, it will provide notice to the ICANN emergency operations department, at least, twenty-­‐four (24) hours ahead of that maintenance. ICANN’s emergency operations department will note planned maintenance times, and suspend Emergency Escalation services for the monitored services during the expected maintenance outage period. If Registry Operator declares an outage, as per its contractual obligations with ICANN, on services under a service level agreement and performance requirements, it will notify the ICANN emergency operations department. During that declared outage, ICANN’s emergency operations department will note and suspend emergency escalation services for the monitored services involved.

  • Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.

  • Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.

  • Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!