Technical or Contractual Problems Contractor shall meet with the Department's personnel, or designated representatives, to resolve technical or contractual problems occurring during the contract term or to discuss the progress made by Contractor and the Department in the performance of their respective obligations, at no additional cost to the Department. The Department may request the meetings as problems arise and will be coordinated by the Department. The Department shall provide Contractor a minimum of three full working days notice of meeting date, time, and location. Face-to-face meetings are desired; however, at Contractor's option and expense, a conference call meeting may be substituted. Contractor’s consistent failure to participate in problem resolution meetings, Contractor missing or rescheduling two consecutive meetings, or Contractor’s failure to make a good faith effort to resolve problems may result in termination of the contract.
Obligations of the Customer 3.1 The Customer agrees to: (a) The Customer shall give the Company not less than 14 days prior written notice of any proposed change of ownership of the Customer and or any change in the Customer’s details (including but not limited to, changes in the customer’s name, address, contact phone/fax numbers or business practice). The Customer shall be liable for any loss incurred by the Company as a result of the Customers failure to comply with this clause. (b) Pay the Company the Price for carrying out the Works in accordance with this agreement; (c) Provide the Company with all necessary plans, specifications, services and amenities, so as to allow the Company to carry out the Works, provide access to the Location and ensure to the Company’s reasonable satisfaction that the Location remains in a state and condition that is safe for the Company and its employees and agents; (d) Ensure the Location complies with all necessary bylaws and restrictions is structurally sound (in accordance with all legislation governing safety in the workplace); (e) Not to cause any disruption or obstruction to the carrying out of any Works and to follow any reasonable instructions provided by the Company about the Works; (f) Where the Works requires co-ordination with other trades then the Customer will supply the Company with a schedule detailing all relevant information so as to allow the Company sufficient time to co-ordinate with the Customer’s other tradespersons; (g) Permit the Company to attach such reasonable signage as the Company may wish to any Works so as to identify that the Company is carrying out the Works; (h) In circumstances where it wishes to make a claim against the Company pursuant to the guarantee given in clause 13.2, exclusively permit the Company or its authorised representative to remedy or make good any defects in its Workmanship and not permit any other third party to do so. 3.2 Without prejudice to any other right or remedy of the Company, if the Customer fails to carry out or perform any of its obligations pursuant to this clause 3 (excepting clause 3.1(g)) then, in addition to any Additional Expenses Charge that may apply, the Company may charge the Customer a Services Delay Charge for each day (or part thereof) that the Company is, in its reasonable opinion, unable and/or not required to carry out or perform the Works as a result of such breach by the Customer. 3.3 Where the Customer requests any Related Work to be carried out, the Company will use its best endeavours to source suppliers and/or contractors to carry out the Related Work, but the Customer is responsible for the commissioning, controlling, and payment for such work. 3.4 The Customer acknowledges that unless otherwise agreed in writing between the Customer and the Company, the Customer shall be responsible for obtaining, paying for and maintaining in force all permits, approvals, authorisations, authorities, licences and consents of all regulatory authorities whatsoever which are or may be necessary or advisable in connection with the Works.
Obligations of the Client 4.1. The client undertakes to inform the company in advance (meaning no later than 2 calendar days) about the dispatch of the goods, by entering the shipment into the Xxxxx.xxx software. 4.1.1. In case of non-compliance with subparagraph 3.2.1 of this agreement, the company has the right to refuse the client in accepting and placing his goods at the warehouse. 4.2. To send goods from the warehouse or to carry out other operations, the client is obliged to provide his client number (client ID) and data of the goods.
Obligations of Client (a) The Client is bound by and must comply at all times with all rules, protocols, policies, procedures and induction requirements published by Viterra from time to time in the Pricing, Procedures and Protocols Manual, including those in relation to: (i) the terms and conditions of the Export Select and Purchase Option services offered by Viterra; (ii) health, safety and environment; (iii) site rules; (iv) labour ordering conditions for shipping; (v) operating conditions for Viterra's rail facilities; (vi) access and operating conditions for road movements at Viterra facilities, and must comply with all reasonable directions issued by Viterra. (b) While on any premises owned or operated by Viterra, the Client must (and must ensure that its employees, agents and contractors) comply with all reasonable directions given by Viterra's representatives, and do not create or bring on site any hazard or contamination.
COMPLIANCE WITH LEGAL OBLIGATIONS Contractor shall procure and maintain for the duration of this Contract any state, county, city or federal license, authorization, waiver, permit, qualification or certification required by statute, ordinance, law, or regulation to be held by Contractor to provide the goods or services required by this Contract. Contractor will be responsible to pay all taxes, assessments, fees, premiums, permits, and licenses required by law. Real property and personal property taxes are the responsibility of Contractor in accordance with NRS 361.157 and 361.159. Contractor agrees to be responsible for payment of any such government obligations not paid by its subcontractors during performance of this Contract.
Obligations of Executive (a) For two years following the Termination Event, Executive agrees not to personally solicit any of the employees either of the Company or of any entity in which the Company directly or indirectly possesses the ability to determine the voting of 50% or more of the voting securities of such entity (including two-party joint ventures in which each party possesses 50% of the total voting power of the entity) to become employed elsewhere or provide the names of such employees to any other company which Executive has reason to believe will solicit such employees. (b) Following the occurrence of a Termination Event, Executive agrees to continue to satisfy Executive’s obligations under the terms of the Company’s standard form of Proprietary Information and Non-Disclosure Agreement previously executed by Executive (or any comparable agreement subsequently executed by Executive in substitution or supplement thereto). Executive’s obligations under this Section 4.2(b) shall survive the termination of this Agreement. (c) It is expressly understood and agreed that although Executive and the Company consider the restrictions contained in this Section 4 to be reasonable, if a final judicial determination is made by a court of competent jurisdiction that the time or territory or any other restriction contained in this Agreement is an unenforceable restriction against Executive, the provisions of this Agreement shall not be rendered void, but shall be deemed amended to apply as to such maximum time or territory and to such maximum extent as such court may judicially determine or indicate to be enforceable. Alternatively, if any court of competent jurisdiction finds that any restriction contained in this Agreement is unenforceable, and such restriction cannot be amended so as to make it enforceable, such finding shall not affect the enforceability of any of the other restrictions contained herein. (d) Following a Termination Event, Executive agrees not to make any public statement or statements to the press concerning the Company, its business objectives, its management practices, or other sensitive information without first receiving the Company’s written approval. Executive further agrees to take no action which would cause the Company or its employees or agents any embarrassment or humiliation or otherwise cause or contribute to the Company’s or any such person’s being held in disrepute by the general public or the Company’s employees, clients, or customers. (e) Executive acknowledges and agrees that the Company’s remedies at law for a breach or threatened breach of any of the provisions of Section 4.2(a) or Section 4.2(b) would be inadequate and, in recognition of this fact, Executive agrees that, in the event of such a breach or threatened breach, in addition to any remedies at law, the Company, without posting any bond, shall, with respect to a breach or threatened breach of Section 4.2(a) or Section 4.2(b) only, obtain equitable relief in the form of specific performance, temporary restraining order, temporary or permanent injunction, or any other equitable remedy which may then be available.
Customer Information and Release Authorization Throughout this Agreement, you authorize Clearview Energy or its agents to obtain and review information from credit-reporting agencies regarding your credit history and information from the Utility relating to you and your account that includes, but is not limited to: account name and number; billing history; payment history; rate classification; historical and future electricity usage; meter readings; and characteristics of electricity service. Clearview Energy will not provide or sell such information to any other party without your consent unless required to do so by law, or it is necessary to enforce the terms of this Agreement. Clearview Energy reserves the right to reject your enrollment, or terminate this Agreement, in the event you rescind these authorizations.
Accommodations of Spiritual or Cultural Observances Where an employee observes a cultural/spiritual day other than those listed above, the employee shall submit their request in January of each year for the twelve (12) month period following March 1st, identifying the required date they need off.
Obligations of Employer Within 3 weeks of receiving an application for parental leave the employer notify in writing the employee of their entitlement to parental leave and whether their position will be kept open. Subject to the position not being both a key position and one it which is not practical to employ someone on a fixed term agreement as a replacement then the employer shall keep the employee’s position open for them on their return to work. Recognise the employee’s service as being continuous on their return to work. Ensure the employee’s terms and conditions remain the same.
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement. (iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person. (iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority. (v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3. (vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event. (vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement: (a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws; (b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway; (c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement; (d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement; (e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement; (f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement; (g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice; (h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times; (i) cooperate with other contractors employed by the Authority and personnel of any public authority; and (j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others. (viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works. (ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor. (x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects. (xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement. (xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices. (xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.