Construction Change Orders Sample Clauses

Construction Change Orders. In the event that it becomes necessary and advisable to change the scope or detail of the work to be performed under the contract(s), such changes shall be rejected or approved in writing by the contracting officers. No change orders shall be approved that increase the costs beyond the funds available in the PROJECT fund, including interest earned on those funds, unless and until the additional funds needed to pay for the added costs are committed by all PARTIES.

Construction Change Orders. All construction and development shall be performed in all material respects in accordance with the Plans and Specifications, appropriate set back requirements, any restrictive covenants and the requirements of any governmental authority, and the anticipated use to which the Improvements will be put will comply with all requirements of governmental authorities and any restrictive covenants to which the Property may be subject. Except as specifically permitted by this Section, no plans and specifications shall be utilized and no changes shall be made in the Plans and Specifications referred to herein, unless first approved by Lender in writing, and any other party where approval may be required by Lender; provided, however, that Borrower may make changes to the Plans and Specifications without Lender’s approval if (i) Borrower notifies Lender in writing of such change within forty-eight (48) hours thereafter; (ii) Borrower obtains the approval of all parties whose approval is required, including the Project General Contractor, the Project Addition General Contractor and any Governmental Authority to the extent approval from such parties is required; (iii) sufficient funds are available in the Budget line items affected by the change; (iv) the structural integrity of the Improvements is not impaired; (v) no substantial change in architectural appearance is effected; (vi) the performance of the mechanical, electrical, and life safety systems of the Improvements is not adversely affected; and (vii) the cost of or reduction resulting from any one such change does not exceed $50,000 and the aggregate change in cost of all such changes does not exceed $250,000. For the purposes of computing such “aggregate change in cost,” pursuant to clause (vii), increases shall be added to, rather than netted against, decreases. Borrower shall promptly furnish to Lender and the Inspecting Engineer, copies of all change orders, regardless of whether Lender’s approval is required.

Construction Change Orders. The project proponent must notify SASD in writing prior to commencing any change order work encountered during construction. For construction change orders to be considered for reimbursement, the project proponent must meet the requirements of Section 8.1.3 of the Ordinance. Failure to comply with any of these procedures will result in the requested change order becoming ineligible for reimbursement. In the event of non-compliance with approved contract documents, any resulting change orders that result in increased costs to obtain compliance will not be reimbursable.

Construction Change Orders. Construction change orders in excess of the Project Budget for the Project Plans and Specifications shall require written approval of the Architect, the Development Team, and the Tribal Council. If completion of the construction, equipping and furnishing of the Project cannot be reasonably accomplished within the Project Budget, then, the Tribal Council, upon receiving advice from the Development Team and the Architect, shall promptly determine which components of the Project shall be deleted or reduced in size, such that the total expenditures for Project Costs shall not exceed the approved Project Budget.

Construction Change Orders. A. Contractor shall construct the Tenant Improvements in a good and workmanlike manner substantially in accordance with the Construction Documents. Landlord shall supervise this construction. Landlord shall not be paid an administrative or construction management fee for its supervision of the Tenant Improvements. Landlord shall endeavor in good faith to cause the Tenant Improvements to be Substantially Completed on or before November 1, 1999, subject to Tenant Delay, but neither the validity of this Lease nor the obligations of Tenant under this Lease shall be affected by a failure to Substantially Complete the Premises by such date, and Tenant shall have no claim against Landlord because of Landlord's failure to Substantially Complete the Premises on such date or by any other date, except for Tenant's right to terminate in Section 9 below. B. Landlord's approval of any Change Orders shall be required, but shall not be unreasonably withheld except that Landlord, in its reasonable discretion, may withhold or delay its approval of any Change Orders to the extent that they affect the Building's structure or systems or would be visible from the exterior of the Building or from any common area in the Building. C. Upon Substantial Completion of the Tenant Improvements, Landlord will deliver possession of the Premises to Tenant. Before delivering the Premises to Tenant, Landlord will obtain a certificate of occupancy, if one is required by law for Tenant to occupy the Premises. Tenant will cooperate with Landlord as necessary to obtain any such certificate of occupancy.

Construction Change Orders. The ENGINEER shall prepare Construction Change Orders as may be required during the construction of the project.

Construction Change Orders. In the event unforeseen or undisclosed circumstances arise on a Site, or if Ubiquitel desires additional or different Construction Services, Ubiquitel and SpectraSite may, without invalidating the Contract Documents, execute changes in the Construction Services, consisting of additions, deletions or modifications on the form attached hereto as Exhibit B-3. Such Change Order shall be in writing and shall be signed by Ubiquitel and SpectraSite.

Construction Change Orders. A. Contract Bid award is based on the Base Bid. Additional work may be authorized by amending the Contract based upon Unit Prices provided in the Bid Form, the Contractor’s Schedule of Values, or other Contractor Proposals approved by the Owner’s Authorized Representative, and in accordance with Section D of the OUS General Conditions for Public Improvement Contracts. B. A Construction Change Order is a written order issued after the execution of a contract, which authorizes and directs a change in scope of work and an adjustment in the Contract Sum, Contract Time or both. C. A Contract Change Order request can be initiated by the Owner’s Authorized Representative through a proposal request to the Contractor, or by the Contractor through submittal of a proposal request in conjunction with a RFI response or Construction Directive. D. The Contractor’s proposal for Contract Change Order Work shall include the following:

Construction Change Orders. Construction change orders in excess of the Project Budget for the Project Plans and Specifications shall require written approval of the Architect, the Authority and a representative of the Gaming Commission if required by applicable

Construction Change Orders. Tenant may authorize changes to the Construction Documents without Landlord’s consent or approval unless the change: (i) materially adversely affects the structural elements of the Building Table of Contents or the Building systems; (ii) describes a floor plan substantially different from that previously approved by Landlord; (iii) does not comply with applicable laws, (iv) changes Building standard materials, or (v) affects the mechanical or electrical plan of the Premises/Building. If Landlord’s approval or consent is required under this Section, such approval or consent will not be unreasonably withheld, delayed or conditioned, and is deemed given if not refused by Landlord within five (5) days after receipt of Tenant’ request for the same. (“Change Orders”) Tenant shall submit to Landlord’s representative the plans and specifications for such Changes Orders.