DETERMINATION AND EXTENSION OF CONTRACT TIME. The number of calendar or working days allowed for completion of the Work shall be stated in the contract and shall be known as the CONTRACT TIME.
DETERMINATION AND EXTENSION OF CONTRACT TIME. The number of calendar or working days allowed for completion of the Work shall be stated in the contract and shall be known as the CONTRACT TIME.
a. CONTRACT TIME based on CALENDAR DAYS shall consist of the number of calendar days stated in the Contract counting from the date of the notice to proceed and including all Saturdays, Sundays, holidays, and nonworking days. All calendar days elapsing between the effective dates of the OWNER’s orders to suspend and resume all work, due to causes not the fault of the Contractor, shall be excluded.
b. Any claim for extension of time or additional compensation for delay (including, but not limited to, compensation for extended overhead or general conditions costs) shall be made as soon as possible in writing to the OWNER but not more than ten days after the commencement of the delay. In case of continuing delay, only one claim notice per calendar month is necessary. The Contractor shall provide an estimate of the probable effect of such delay on the progress of the Work. Furthermore, within ten (10) business days after the end of each calendar month for which the Contractor (or a subcontractor at any level) has claimed a delay for which the Contractor will ultimately seek additional compensation from the OWNER, the Contractor shall submit to the OWNER a detailed and fully-supported document listing the costs claimed for the preceding calendar month by the Contractor and any impacted subcontractors, pursuant to the delay. It is understood (and the Contractor shall ensure) that these same provisions flow down to subcontractors working under the Contract. In the event that the Contractor does not comply with the requirements of this section, the Contractor shall not be entitled to any xxxx-up for fee (profit) on any compensation ultimately approved by the OWNER for the delay.
c. Seasonal weather conditions shall be considered and included in the planning and scheduling of all Work influenced by high or low ambient temperatures, precipitation and/or saturated soil to ensure completion of all Work within the Contract time. Average historical climatic conditions for the proceeding ten (10) years are published by the National Oceanographic and Atmospheric Administration (NOAA) and entitled “Local Climatological Data-Dallas/Fort Worth, Texas.”
d. For planning purposes, the following shall be considered average workdays lost per month due to weather conditions: Month Lost Time in Workdays January 5 February 4 March 5 April ...
DETERMINATION AND EXTENSION OF CONTRACT TIME. Delete the first paragraph of Subsection 108.08 in its entirety and replace with the following: Add the following new Subsection 108.08(e):
DETERMINATION AND EXTENSION OF CONTRACT TIME. CONTRACT TIME The Department shall determine and specify the contract time in the Notice to Proceed. The Date of completion shall be the date that the Department finds the work acceptable under the contract documents and that the Contractor has fully performed the work under the contract. The work on the contract will be considered substantially complete when the project has met the intention of the plans, as reasonably determined by the Engineer or the Consulting Engineer. When the Engineer or the Consulting Engineer considers the project substantially complete, the Department will discontinue the contract time charges prior to its final acceptance of the work.
DETERMINATION AND EXTENSION OF CONTRACT TIME. CONTRACT TIME The initial term of this contract is one calendar year.
DETERMINATION AND EXTENSION OF CONTRACT TIME. Delete this subsection in its entirety and substitute the following: The Contractor is advised that short duration halts to work at the Jamestown Plaza may be directed by the State Police for security reasons. The Contractor shall comply with any requests by the State Police or the RITBA or their agents to temporarily halt work and have all personnel leave the plaza site. Where appropriate under the provisions of this subsection, extensions or reductions to the Contract Time may be provided by Change Order, however, such extensions or reductions will be allowed only to the extent that the increase or decrease in the Work or delays of the types indicated herein affect current controlling operations and the overall Completion. Increases or decreases in Work or such delays that do not affect the overall completion are not to be the basis for reduction or extension of Contract Time. Extensions of Contract Time will not be granted under this subsection where it is determined by the Engineer that the Contractor could have avoided the circumstances which give rise to his requesting such extensions. If the Contractor is delayed in completion of the Work by reason of changes made under Subsection 104.02, or by any act of the Contractor consistent with Subsection 105.10, or due to the discovery of archaeological finds consistent with Subsection 107.11, or the discovery of hazardous substances, or by any act of the Engineer or of the Authority not contemplated by the Contract, any extension of Contract Time commensurate with the delay in overall completion of the Contract thus caused will be granted and the Contractor is relieved from any claim. The Contractor’s plea that insufficient time was specified is not a valid reason for extension of time. The Authority, in determining an extension of time, may, at its discretion, take into consideration any delay or delays caused by conditions beyond its control, and without the fault of the Contractor, such conditions including, but not limited to the order, decree, or judgment of any court of judge thereof, fire, other casualty, strikes, lockouts, or acts of God. The extended time for completion shall then be in full force and effect, the same as though it were the original time for completion.
DETERMINATION AND EXTENSION OF CONTRACT TIME. Delete this subsection in its entirety and substitute the following: The work for this Contract includes work under Defined Work Pay Items. All work under Defined Work Pay Items shall be completed no later than December 10, 2021.
DETERMINATION AND EXTENSION OF CONTRACT TIME. The T/LPA will provide the Contract Time in the Advertisement, in Working Days, Days, or Mandatory Completion Date. For Working Day Projects, the Project Manager will provide the Contractor with a weekly statement showing the Contract Time, the number of Working Days used, the accumulated Working Days charged, and the number of Working Days remaining to complete the Work. The Contractor shall have three (3) Days after receipt of the weekly statement to object in writing to the weekly statement, setting forth the specific dates and justifications for the objection. If the Project Manager finds that the Contractor’s objection is valid, or if there is an error, then the Project Manager will issue corrected weekly statement(s). If the Project Manager determines that the objection is not valid the Project Manager will notify the Contractor in writing. If the Contractor continues to object to the weekly statement then the Contractor may file a Notice of Intent to Claim. If the Contractor fails to timely object, the weekly statement is deemed Accepted by the Contractor. The Contractor is not entitled to a Partial Suspension, at its own request, when any of the conditions below apply:
1. Projects with a Bar Graph Schedule
2. Projects with a Mandatory Completion Date;
3. Projects that are Calendar Day;
4. When performing Work on the Critical Path;
5. When the Contractor has not provided proper justification and the Project Manager has not approved the request;
6. The Work obstructs the Traveled Way; or
7. For issues for which the Contractor is responsible. Partial Suspension shall be lifted if the Contractor works on Critical Path activities and the Project Manager shall commence the Contract Time count. If completion of the Contract requires Extra Work that impacts the Critical Path, the Contractor shall provide the T/LPA an updated progress schedule and narrative requesting additional Contract Time associated with the Extra Work. Upon submission of adequate justification by the Contractor the District Engineer for the NMDOT District where the Project is located will determine if any adjustment in Contract Time is warranted with concurrence by the CLE. Any request for additional Contract Time shall be made in writing to the Project Manager. If the Project Manager rejects a time extension request, the Contractor may proceed pursuant to Section 105.19, “Notice of Intent to Claim.”
DETERMINATION AND EXTENSION OF CONTRACT TIME. The number of Calendar or Working Days allowed for completion of the Work shall be stated in the proposal and Contract and shall be known as the Contract Time. Should the Contract Time require extension for reasons beyond the CMR’s control, it shall be adjusted as follows:
a. Contract Time based on Working Days shall be calculated weekly by the Design Professional. The Design Professional will furnish the CMR a copy of his/her weekly statement of the number of Working Days charged against the Contract Time during the week and the number of Working Days currently specified for completion of the Contract (the original Contract Time plus the number of Working Days, if any, that have been included in approved Change Orders or Supplemental Agreements covering Extra Work.
(1) No time shall be charged for days on which the CMR is unable to proceed with the principal item of Work under construction at the time for at least 6 hours with the normal work force employed on such principal item. Should the normal work force be on a double-shift, 12 hours shall be used. Should the normal work force be on a triple-shift, 18 hours shall apply. Conditions beyond the CMR’s control such as strikes, lockouts, unusual delays in transportation, temporary suspension of the principal item of Work under construction or temporary suspension of the entire Work which have been ordered by the Airport Authority for reasons not the fault of the CMR, shall not be charged against the Contract Time.
(2) The Design Professional will not make charges against the Contract Time prior to the effective date of the Notice to Proceed.
(3) The Design Professional will begin charges against the Contract Time on the first Working Day after the effective date of the Notice to Proceed.
(4) The Design Professional will not make charges against the Contract Time after the date of Final Acceptance as defined in the subsection titled FINAL ACCEPTANCE of Section 50 of Article 2.
(5) The CMR will be allowed 1 week in which to file a written protest setting forth his/her objections to the Design Professional’s weekly statement. If no objection is filed within such specified time, the weekly statement shall be considered as acceptable to the CMR.
b. Contract Time based on Calendar Days shall consist of the number of Calendar Days stated in the Contract counting from the effective date of the Notice to Proceed and including all Saturdays, Sundays, holidays, and nonwork days. All Calendar Days elapsing between ...
