Obligation of the Developer Sample Clauses

Obligation of the Developer. To prepare a comprehensive & dependable project report after all required surveys, sub-soil and geo-tech investigations, tests on local and other materials, proposing methodologies and output test parameters. The developer shall not depend only on the information provided by RHB or other Govt. agency but shall on his own testing etc.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Obligation of the Developer. Upon the approval by City of the Agreement, Developer shall proceed with the Project as described above. The Project shall be substantially complete within twenty-four (24) months of the date of approval by City of this Agreement. Any extension of time permitted for Developer to substantially complete the Project pursuant to the Agreement shall be agreed to in writing by both Parties. Specifically, Xxxxxxxxx agrees as follows: Developer will complete the Project, including construction and improvements, in accordance with this Agreement, and the drawings and site plans shall be submitted to City for review. This includes both the interior and exterior construction and improvements. Developer will obtain all building and zoning permits in association with the Project, including permits for construction, repair, demolition, and/or renovation on the Property, consistent with the City’s most recently adopted Building Code requirements. City building code officials will be available to respond promptly to whether any proposed change will require a permit so that Developer can move forward with said work in a timely manner. City shall be entitled to a comprehensive inspection of the Property for the purpose of identifying potential fire safety, electric, plumbing and general building safety concerns to ensure the health, safety and welfare of the general public. City Fire and Building Inspection staff can assist Developer in prioritizing any list of concerns. Developer is fully responsible for identifying and mitigating any building-related concerns, or any other environmental issues with the Property. Developer understands and agrees all City Zoning Ordinances, Land Development Codes, Landscape and Screening Codes, Building Code requirements and other City ordinances not specifically waived by this Agreement shall remain in full force and effect.
Sample 1Sample 2
Obligation of the Developer. (a) to develop at the Developer’s sole cost and expense the Project Land into residential estates by designing, planning, constructing, completing and commissioning all the buildings thereto including infrastructural works, access roads, drainage and other related housing amenities; (b) to provide the necessary fund and financing for the Proposed Development; (c) to be responsible for the marketing and all the matter related therewith to procure the sales of the Proposed Development; (d) to be responsible for the sub-division of the Project Land or the relevant part thereof into sub-sidiary/divided titles in accordance with the Development Plan as approved by the relevant authorities; (e) to be responsible for all the procedural dealings with the relevant authorities in relation to the Project Land as may be deemed necessary or expedient for the completion and/or sale of the said Proposed Development and for such purposes, to pay the premium (if any) imposed by the relevant authorities; (f) To diligently construct and complete at the Developer’s own cost and expense the Proposed Development hereof in a good and workmanlike manner and strictly in accordance with the approved development plans subject only to such modifications and amendments as may be approved by the relevant authorities; (g) to apply to the relevant authorities and obtain certificate of fitness for occupation in respect of the units comprised in the Proposed Development upon completion of the same; (h) to be responsible for the delivery of the vacant possession of the respective units in respect of the Proposed Development to the purchasers after issuance of certificate of fitness for occupation by the appropriate authority; and (i) to comply with all the relevant laws, by-laws and regulations for the time being in force.
Sample 1
Obligation of the Developer. 4.2.1 The Developer shall be solely responsible for securing land and creating required infrastructure for development of the Project either at one location or at multiple locations, obtaining all necessary clearances and approvals from Governmental Authorities, and the connectivity of the Project with the CTU at the Delivery Point(s) for evacuation of Renewable Energy by the SCD. 4.2.2 The Developer shall be solely responsible for obtaining all Consents, Clearances and Permits as required and maintaining all Consents, Clearances and Permits in full force and effect during the Term of this Agreement. The Captive User shall provide necessary support, as sought by Developer in this regard. 4.2.3 The Developer shall be solely responsible for designing, constructing, erecting, commissioning, completing, and testing the Project in accordance with the Applicable Law, the Grid Code, the terms and conditions of this Agreement and Prudent Utility Practices. 4.2.4 The Developer shall be solely responsible for the commencement of delivering the Renewable Energy corresponding to Contracted Capacity to the Captive User no later than the SCD and continue delivering Renewable Energy from the Project throughout the Term of the Agreement. 4.2.5 The Developer shall be solely responsible for making adequate arrangements for connecting the Project through the Interconnection Facilities at the Delivery Point to enable flow of Renewable Energy from the Project. 4.2.6 The Developer shall be solely responsible for securing and maintaining the long-term Open Access and executing transmission service agreement with CTU/STU as the case may be, for evacuation of Renewable Energy corresponding to Contracted Capacity from the Project and delivering it at the Delivery Point throughout the term of the Agreement. 4.2.7 The Developer being Regional Entity shall be responsible for directly coordinating and dealing with the Captive User, SLDC and/or RLDC as the case may be, Regional Power Committees, and any other Appropriate Authority in all respects in regard to declaration of Available Capacity, scheduling and dispatch of Renewable Energy and due compliance with the Applicable Law. 4.2.8 The Developer shall ensure that the Project being implemented under this Agreement shall fulfil the criteria as per Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007, and subsequent amendments and clarifications thereof. 4.2.9 As part of scheduling of Renew...
Sample 1
Obligation of the Developer. 4.4.1 The Developer shall:- a) at its own cost and expense obtain all relevant Approvals from the Appropriate Authorities as may be necessary for the Project; b) the Developer shall unless otherwise specifically provided for in the JVA be solely responsible at its own cost and expense for carrying out all aspects of the Project; c) to complete the Project in accordance with the approved plans by the relevant authorities; d) at its own cost and expense construct all the relevant infrastructure in connection with the Project in accordance with the requirements and standards of the relevant authorities; e) to complete the construction of the Project and to do all acts and things necessary to procure the issuance of the Certificate of Completion and Compliance and deliver vacant possession of the units to the purchasers. 4.4.2 The Developer shall fully indemnify and keep indemnified the Landowner against all claims, costs, expenses, charges, fees, or sums payable or paid or damages, losses and liabilities suffered or to be suffered or to be incurred by the Landowner arising from the Developer’s acts omission arising from the JVA and execution of this Project including the Developer’s non compliance of its obligation under item 4.4.1.
Sample 1
Obligation of the Developer. 12.1. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on or before 31st December 2022 unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature or by any reasons which are beyond the control of the promoter affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure reasons then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment. Provided that the promoter is not able to hand over the project to the allotee under circumstances other than Force Majeure conditions then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. The promoter shall pay along with 12 % p.a. interest within forty- five days of it becoming due under the above said circumstances. Provided that where if the Allottee does not intend to withdraw from the Project, the Promoter shall pay the Allottee 12 % p.a. interest for every month of delay, till the handing over of the possession of the Apartment.
Sample 1
AutoNDA by SimpleDocs
Obligation of the Developer 
Sample 1Sample 2Sample 3See All (20)

Related to Obligation of the Developer

  • Obligation of the Company In connection with the registration of the Registered Securities, the Company shall do each of the following: (a) Prepare promptly and file with the SEC within one hundred twenty (120) days after the date hereof, a Registration Statement with respect to not less than the maximum allowable under Rule 415 of Registered Securities, and thereafter use all commercially reasonable efforts to cause such Registration Statement relating to the Registered Securities to become effective within five (5) business days after notice from the Securities and Exchange Commission that such Registration Statement may be declared effective, and keep the Registration Statement effective at all times prior to the termination of the Purchase Agreement until the earliest of (i) the date that is three months after the completion of the last Closing Date under the Purchase Agreement, (ii) the date when the Investor may sell all Registered Securities under Rule 144 without volume limitations, or (iii) the date the Investor no longer owns any of the Registered Securities (collectively, the "Registration Period"), which Registration Statement (including any amendments or supplements, thereto and prospectuses contained therein) shall not contain any untrue statement of a material fact or omit to state a material fact required to be stated therein or necessary to make the statements therein, in the light of the circumstances under which they were made, not misleading; (b) Prepare and file with the SEC such amendments (including post-effective amendments) and supplements to the Registration Statement and the prospectus used in connection with the Registration Statement as may be necessary to keep the Registration Statement effective at all times during the Registration Period, and to comply with the provisions of the Securities Act with respect to the disposition of all Registered Securities of the Company covered by the Registration Statement until the expiration of the Registration Period. (c) With respect to the Registered Securities, permit counsel designated by Investor to review the Registration Statement and all amendments and supplements thereto a reasonable period of time (but not less than two (2) business days) prior to their filing with the SEC, and not file any document in a form to which such counsel reasonably objects. (d) As promptly as practicable after becoming aware of the following facts, the Company shall notify Investor and Investor’s legal counsel identified to the Company and (if requested by any such person) confirm such notice in writing no later than one (1) business day thereafter (i): (A) when a prospectus or any prospectus supplement or post-effective amendment to the Registration Statement is filed; (B) with respect to the Registration Statement or any post-effective amendment, when the same has become effective; (ii) of the issuance by the SEC of any stop order suspending the effectiveness of the Registration Statement covering any or all of the Registered Securities or the initiation of any proceedings for that purpose; and (iii) of the receipt by the Company of any notification with respect to the suspension of the qualification or exemption from qualification of any of the Registered Securities for sale in any jurisdiction, or the initiation or threatening of any proceeding for such purpose. (e) Unless available to the Investor without charge through XXXXX, the SEC's website or the Company's website, furnish to Investor, promptly after the same is prepared and publicly distributed, filed with the SEC, or received by the Company, one (1) copy of the Registration Statement, each preliminary prospectus and the prospectus, and each amendment or supplement thereto; (f) Use all commercially reasonable efforts to (i) register and/or qualify the Registered Securities covered by the Registration Statement under such other securities or blue sky laws of such jurisdictions as the Investor may reasonably request and in which significant volumes of shares of Common Stock are traded, (ii) prepare and file in those jurisdictions such amendments (including post-effective amendments) and supplements to such registrations and qualifications as may be necessary to maintain the effectiveness thereof at all times during the Registration Period, (iii) take such other actions as may be necessary to maintain such registrations and qualification in effect at all times during the Registration Period, and (iv) take all other actions reasonably necessary or advisable to qualify the Registered Securities for sale in such jurisdictions: provided, however, that the Company shall not be required in connection therewith or as a condition thereto to (A) qualify to do business in any jurisdiction where it would not otherwise be required to qualify but for this Section 3(f), (B) subject itself to general taxation in any such jurisdiction, (C) file a general consent to service of process in any such jurisdiction, (D) provide any undertakings that cause more than nominal expense or burden to the Company or (E) make any change in its charter or by-laws or any then existing contracts, which in each case the Board of Directors of the Company determines to be contrary to the best interests of the Company and its stockholders; (g) As promptly as practicable after becoming aware of such event, notify the Investor of the happening of any event of which the Company has knowledge, as a result of which the prospectus included in the Registration Statement, as then in effect, includes any untrue statement of a material fact or omits to state a material fact required to be stated therein or necessary to make the statements therein, in the light of the circumstances under which they were made, not misleading ("Registration Default"), and promptly prepare a supplement or amendment to the Registration Statement or other appropriate filing with the SEC to correct such untrue statement or omission, and take any other commercially reasonable steps to cure the Registration Default, and, unless available to the Investor without charge through XXXXX, the SEC's website or the Company's website, deliver a number of copies of such supplement or amendment to the Investor as the Investor may reasonably request. (h) [INTENTIONALLY OMITTED]; (i) Use its commercially reasonable efforts, if eligible, either to (i) cause all the Registered Securities covered by the Registration Statement to be listed on a national securities exchange and on each additional national securities exchange on which securities of the same class or series issued by the Company are then listed, if any, if the listing of such Registered Securities is then permitted under the rules of such exchange, or (ii) secure designation of all the Registered Securities covered by the Registration Statement as a National Association of Securities Dealers Automated Quotations System ("Nasdaq”) security within the meaning of Rule 11Aa2-1 of the SEC under the Securities Exchange Act of 1934, as amended (the "Exchange Act"), and the quotation of the Registered Securities on the Nasdaq Capital Market; or if, despite the Company’s commercially reasonable efforts to satisfy the preceding clause (i) or (ii), the Company is unsuccessful in doing so, to use its commercially reasonable efforts to secure authorization of the Financial Industry Regulatory Authority (“FINRA”) and quotation for such Registered Securities on the over-the-counter bulletin board and, without limiting the generality of the foregoing; (j) Provide a transfer agent for the Registered Securities not later than the Subscription Date under the Purchase Agreement; (k) Cooperate with the Investor to facilitate the timely preparation and delivery of certificates for the Registered Securities to be offered pursuant to the Registration Statement and enable such certificates for the Registered Securities to be in such denominations or amounts as the case may be, as the Investor may reasonably request and registration in such names as the Investor may request; and, within five (5) business days after a Registration Statement which includes Registered Securities is ordered effective by the SEC, the Company shall deliver, and shall cause legal counsel selected by the Company to deliver, to the transfer agent for the Registered Securities (with copies to the Investor) an appropriate instruction and opinion of such counsel, if so required by the Company’s transfer agent; and (l) Take all other commercially reasonable actions necessary to expedite and facilitate distribution to the Investor of the Registered Securities pursuant to the Registration Statement.

  • Obligation of the Parties 2.1 The Fund shall prepare and be responsible for filing with the SEC and any state securities regulators requiring such filing, all shareholder reports, notices, proxy materials (or similar materials such as voting instruction solicitation materials), prospectuses and statements of additional information of the Fund. The Fund shall bear the costs or registration and qualification of its Shares, preparation and filing of the documents listed in this Section 2.1 and all taxes to which an issuer is subject on the issuance and transfer of its shares. 2.2 At least annually, the Fund or its designee shall provide the Company, free of charge, with as many copies of the current prospectus (describing only the Portfolios) for the Shares as the Company may reasonably request for distribution to existing Contract owners whose Contracts are funded by such Shares. The Fund or its designee shall provide the Company, at the Company's expense, with as many copies of the current prospectus for the Shares as the Company may reasonably request for distribution to prospective purchasers of Contracts. If requested by the Company in lieu thereof, the Fund or its designee shall provide such documentation (including a "camera ready" copy of the new prospectus as set in type) and other assistance as is reasonably necessary in order for the parties hereto once each year (or more frequently if the prospectus for the Shares is supplemented or amended) to have the prospectus for the Contracts and the prospectus for the Shares printed together in one document; the expenses of such printing to be borne by the Company. In the event that the Company requests that the Fund or its designee provide the Fund's prospectus in a "camera ready" format, the Fund shall be responsible solely for providing the prospectus in the format in which it is accustomed to formatting prospectuses and shall bear the expense of providing the prospectus in such format (e.g., typesetting expenses), and the Company shall bear the expense of adjusting or changing the format to conform with any of its prospectuses. 2.3 The prospectus for the Shares shall state that the statement of additional information for the Shares is available from the Fund or its designee. The Fund or its designee, at its expense, shall print and provide such statement of additional information to the Company (or a master of such statement suitable for duplication by the Company) for distribution to any owner of a Contract funded by the Shares. The Fund or its designee, at the Company's expense, shall print and provide such statement to the Company (or a master of such statement suitable for duplication by the Company) for distribution to a prospective purchaser who requests such statement. 2.4 The Fund or its designee shall provide the Company free of charge copies, if and to the extent applicable to the Shares, of the Fund's proxy materials, reports to Shareholders and other communications to Shareholders in such quantity as the Company shall reasonably require for distribution to Contract owners. 2.5 The Company shall furnish, or cause to be furnished, to the Fund or its designee, a copy of each prospectus for the Contracts or statement of additional information for the Contracts in which the Fund or its investment adviser is named prior to the filing of such document with the SEC. The Company shall furnish, or shall cause to be furnished, to the Fund or its designee, each piece of sales literature or other promotional material in which the Fund or its investment adviser is named, at least five Business Days prior to is use. No such prospectus, statement of additional information or material shall be used if the Fund or its designee reasonably objects to such use within five Business Days after receipt of such material. 2.6 The Company shall not give any information or make any representations or statements on behalf of the Fund or concerning the Fund or its investment adviser in connection with the sale of the Contracts other than information or representations contained in and accurately derived from the registration statement or prospectus for the Fund Shares (as such registration statement and prospectus may be amended or supplemented from time to time), reports of the Fund, Fund-sponsored proxy statement, or in sales literature or other promotional material approved by the Fund or its designee, except with the written permission of the Fund or its designee. 2.7 The Fund shall not give any information or make any representations or statements on behalf of the Company or concerning the Company, the Accounts or the Contracts other than information or representations contained in and accurately derived from the registration statement or prospectus for the Contracts (as such registration statement and prospectus may be amended or supplemented from time to time), or in materials approved by the Company for distribution including sales literature or other promotional materials, except with the written permission of the Company. 2.8 The Company shall amend the registration statement of the Contracts under the 1933 Act and registration statement for each Account under the 1940 Act from time to time as required in order to effect the continuous offering of the Contracts or as may otherwise be required by applicable law. The Company shall register and qualify the Contracts for sale to the extent required by applicable securities laws and insurance laws of the various states.

  • Conditions to Obligation of the Depositor The obligation of the Depositor to purchase the Receivables is subject to the satisfaction of the following conditions:

  • Conditions to Obligation of the Company The obligation of the Company to effect the Merger is also subject to the satisfaction or waiver by the Company at or prior to the Effective Time of the following conditions:

  • No Obligation of the Trustee (i) The Trustee shall have no responsibility or obligation to any beneficial owner of a Global Note, a member of, or a participant in the Depositary or any other Person with respect to the accuracy of the records of the Depositary or its nominee or of any participant or member thereof, with respect to any ownership interest in the Notes or with respect to the delivery to any participant, member, beneficial owner or other Person (other than the Depositary) of any notice (including any notice of redemption or repurchase) or the payment of any amount, under or with respect to such Notes. All notices and communications to be given to the Holders and all payments to be made to Holders under the Notes shall be given or made only to the registered Holders (which shall be the Depositary or its nominee in the case of a Global Note). The rights of beneficial owners in any Global Note shall be exercised only through the Depositary subject to the applicable rules and procedures of the Depositary. The Trustee may rely and shall be fully protected in relying upon information furnished by the Depositary with respect to its members, participants and any beneficial owners. (ii) The Trustee shall have no obligation or duty to monitor, determine or inquire as to compliance with any restrictions on transfer imposed under this Indenture or under applicable law with respect to any transfer of any interest in any Note (including any transfers between or among Depositary participants, members or beneficial owners in any Global Note) other than to require delivery of such certificates and other documentation or evidence as are expressly required by, and to do so if and when expressly required by, the terms of this Indenture, and to examine the same to determine substantial compliance as to form with the express requirements hereof.

  • Obligation of the Company Unconditional Nothing contained in this Article or elsewhere in this Subordinated Indenture or in the Subordinated Securities is intended to or shall impair, as between the Company, its creditors other than the holders of Senior Indebtedness, and the Holders of the Subordinated Securities, the obligation of the Company, which is absolute and unconditional, to pay to the Holders of the Subordinated Securities the principal of (and premium, if any) and interest payable in the respect of the Subordinated Securities as and when the same shall become due and payable in accordance with their terms, or is intended to or shall affect the relative rights of the Holders of the Subordinated Securities and creditors of the Company other than the holders of Senior Indebtedness nor shall anything herein or therein prevent the Trustee or the Holder of any Security from exercising all remedies otherwise permitted by applicable law upon default under this Subordinated Indenture, subject to the rights, if any, under this Article of the holders of Senior Indebtedness in respect of cash, property or Subordinated Securities of the Company received upon the exercise of any such remedy. Upon any payment or distribution of assets of the Company referred to in this Article, the Trustee and the Holders of the Subordinated Securities shall be entitled to rely upon any order or decree made by any court of competent jurisdiction in which any such dissolution, winding up, liquidation or reorganization proceeding affecting the affairs of the Company is pending or upon a certificate of the trustee in bankruptcy, receiver, assignee for the benefit of creditors, liquidating trustee or agent or other person making any payment or distribution, delivered to the Trustee or to the Holders of the Subordinated Securities, for the purpose of ascertaining the persons entitled to participate in such payment or distribution, the holders of the Senior Indebtedness and other indebtedness of the Company, the amount thereof or payable thereon, the amount paid or distributed thereon and all other facts pertinent thereto or to this Article.

  • Files Management and Record Retention relating to Grantee and Administration of this Agreement a. The Grantee shall maintain books, records, and documents in accordance with generally accepted accounting procedures and practices which sufficiently and properly reflect all expenditures of funds provided by Florida Housing under this Agreement. b. Contents of the Files: Grantee must maintain files containing documentation to verify all funds awarded to Grantee in connection with this Agreement, as well as reports, records, documents, papers, letters, computer files, or other material received, generated, maintained or filed by Grantee in connection with this Agreement. Grantee must also keep files, records, computer files, and reports that reflect any compensation it receives or will receive in connection with this Agreement.

  • TERM AND TERMINATION OF THIS AGREEMENT; NO ASSIGNMENT (a) This Agreement shall go into effect as to the Fund on the date set forth above and shall, unless terminated as hereinafter provided, continue in effect for a period of two years from the date of approval by shareholders of the Fund at a meeting called for the purpose of such approval. This Agreement shall continue in effect thereafter for additional periods not exceeding one (l) year so long as such continuation is approved for the Fund at least annually by (i) the Board of Trustees of the Trust or by the vote of a majority of the outstanding voting securities of the Fund and (ii) the vote of a majority of the Trustees of the Trust who are not parties to this Agreement nor interested persons thereof, cast in person at a meeting called for the purpose of voting on such approval. The terms “majority of the outstanding voting securities” and “interested persons” shall have the meanings as set forth in the 1940 Act; (b) This Agreement may be terminated by the Trust on behalf of the Fund at any time without payment of any penalty, by the Board of Trustees of the Trust, by the Manager, or by vote of a majority of the outstanding voting securities of a Fund without the payment of any penalties, upon sixty (60) days’ written notice to the Sub-Adviser, and by the Sub-Adviser upon sixty (60) days’ written notice to the Fund and the Manager. In the event of a termination, the Sub-Adviser shall cooperate in the orderly transfer of the Fund’s affairs and, at the request of the Board of Trustees or the Manager, transfer any and all books and records of the Fund maintained by the Sub-Adviser on behalf of the Fund; and (c) This Agreement shall terminate automatically in the event of any transfer or assignment thereof, as defined in the 1940 Act. This Agreement will also terminate in the event that the Management Agreement is terminated.

  • Conditions to Obligation of the Buyer The obligation of the Buyer to consummate the transactions to be performed by it in connection with the Closing is subject to satisfaction of the following conditions: (i) the representations and warranties set forth in Section 3(a) above shall be true and correct in all material respects at and as of the Closing Date; (ii) the Seller shall have performed and complied with all of their covenants hereunder in all material respects through the Closing; (iii) there shall not be any injunction, judgment, order, decree, ruling, or charge in effect preventing consummation of any of the transactions contemplated by this Agreement; (iv) all necessary governmental, shareholder and third party consents and approvals in connection with the transactions contemplated by the Agreement shall have been obtained; (v) the Seller shall have delivered to the Buyer certificates executed by the responsible officer or the secretary of the Seller, as applicable, certifying (A) that each of the conditions specified in Section 9(a)(i)-(iv) are satisfied in all respects, (B) the resolution(s) of the Seller's board of directors authorizing the Seller's execution, delivery and performance of the Agreement and all matters in connection with the Agreement and transactions contemplated thereby, and (C) the incumbency of the officer of the Seller executing the Agreement and all other documents executed and delivered in connection therewith; (vi) the relevant parties shall have entered into the agreements in the forms set forth in (A) Exhibit G (Agreement Amending the Warrants), (B) Exhibit H (Assumption Agreement regarding the Warrants) and (C) Exhibit I (Agreement Amending Securities Purchase Agreement) and attached hereto and the same shall be in full force and effect; (vii) the Buyer shall have received: (A) from Hungarian Counsel of the Seller, a legal opinion in the form set forth in Exhibit L attached hereto, and dated as of the Closing Date, to the effect that (u) the Seller need not give any notice to, make any filing with, or obtain any authorization, consent, or approval of any government or governmental agency in order to consummate the transactions contemplated by this Agreement, or if such notice filing, authorization, consent or approval is needed, it has been gained or obtained, (v) any arbitration award in favor of the Buyer obtained pursuant to this Agreement would be valid and enforceable before a court of competent jurisdiction in Hungary and (x) the matters set forth in Section 3(a)(i) and the first and third sentences of Section 3(a)(ii) of the Agreement; and (B) from US Counsel to the Seller, an opinion in the form as may be attached hereto as Exhibit K, and dated as of the Closing Date (y) covering the matters set forth in the second sentence of Section 3(a)(ii) of the Agreement and (z) stating that no registration is required under the Securities Act to transfer the Shares, Unsecured Notes or the Warrants to Buyer in accordance with the Agreement; (viii) the Closing Arrangements set forth in Exhibit J attached hereto shall have been implemented in full to the Buyer's satisfaction; for the avoidance of doubt Seller acknowledges and agrees that unless and until the Closing Arrangements set forth in Exhibit J have been implemented as contemplated by this Section 9(a)(viii), Buyer shall have no obligation whatsoever to pay the Purchase Price; (ix) Since the date of the this Agreement, no event or events shall have occurred which have had or reasonably may be expected to have a Material Adverse Effect; (x) All actions to be taken by the Seller in connection with consummation of the transactions contemplated hereby and all certificates, opinions, instruments, and other documents required to effect the transactions contemplated hereby will be reasonably satisfactory in form and substance to the Buyer; and (xi) The Buyer shall have had the opportunity to conduct a reasonable investigation of the matters set forth in Schedule 3(a)(viii) of this Agreement and satisfy itself that no material commercial risk will be transferred with respect to the Shares, Unsecured Notes and Warrants as a result of the dispute described therein in the event that the Closing shall occur. The Buyer may waive any condition specified in this Section 9(a) if it executes a writing so stating at or prior to the Closing.

  • Conditions to Obligation of the Purchaser The obligation of the Purchaser to purchase the Receivables from the Seller on the Closing Date is subject to the satisfaction of the following conditions:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!