Work Changes. Owner reserves the right to order changes to the Work in the nature of additions, deletions or modifications, without invalidating this Agreement, and agrees to make corresponding adjustments in the Contract Price and time of termination if applicable. All changes will be authorized in a written “Change Order” signed by Owner and Contractor, which shall be incorporated by reference herein.
Work Changes. A. The County reserves the right to order changes in the Work to be performed under this Agreement by altering, adding to, or deducting from the Work. All such changes shall be incorporated in written change orders executed by the Consultant and the County. Such change orders shall specify the changes ordered and any necessary adjustment of compensation and completion time. If the Parties cannot reach an agreement on the terms for performing the changed work within a reasonable time to avoid delay or other unfavorable impacts as determined by the County in its sole discretion, the County shall have the right to determine reasonable terms, and the Consultant shall proceed with the changed work.
B. Any work added to the scope of this Agreement by a change order shall be executed under all the applicable conditions of this Agreement. No claim for additional compensation or extension of time shall be recognized, unless contained in a written change order duly executed on behalf of the County and the Consultant.
C. The County Manager has authority to execute without further action of the Cherokee County Board of Commissioners, any number of change orders so long as their total effect does not materially alter the terms of this Agreement or materially increase the total amount to be paid under this Agreement, as set forth in Section III(B) below. Any such change orders materially altering the terms of this Agreement or increasing the total amount to be paid under this Agreement in excess of $25,000 must be approved by resolution of the Cherokee County Board of Commissioners.
Work Changes. (a) Within 10 days after written request from Contractor (or within such other time as is specified in such request), Subcontractor shall submit to Contractor its proposal (with computations and supporting data in such detail as Contractor requires) for eliminations of, changes in, or additions to the Work thereby requested, stating:
(i) a proposed lump sum amount for such Work, which shall be based on a justified estimate of the direct cost of the change plus the applicable markup percentage for overhead and profit specified in the Prime Contract (or if no such percentage is specified, 10% for change Work performed by Subcontractor's own forces and 5% on any such Work performed by a sub-subcontractor;
(ii) unit prices therefor, in addition to any unit prices applicable thereto already specified herein, including estimated quantities and computations;
(iii) Subcontractor’s documented estimate of the direct cost of labor and material required to perform the change. If Subcontractor is authorized by Contractor to proceed on this basis, Subcontractor shall be reimbursed for the justified and documented direct cost of labor and materials incurred to perform the change plus the applicable markup percentage for overhead and profit specified in the Prime Contract (or if no such percentage is specified, 10% for change Work performed by Subcontractor's own forces and 5% on any such Work performed by a sub- subcontractor);
(iv) deductions to be allowed from the Contract Price for Work, if any, eliminated; and
(v) additional time, if any, requested for the completion of such additional or changed Work.
15(b) On receipt of such proposal, Contractor may issue a change order directing Subcontractor to proceed with the changed work, and either
(A) authorizing an adjustment in the Contract Price therefor on anyone of the bases set forth in clauses (i) to (iv), inclusive, of Section 15(a) (or partly on a unit price and partly on a fee basis), or (B) directing that the work be done at Subcontractor's cost of direct labor and of materials plus a total of 10% (unless otherwise stated in Section 1) for overhead and profit. Such change order shall also specify the deductions, if any, from the Contract Price for eliminations and additional time, if any, allowed.
15(c) Subcontractor, within two business days after such change order is issued, by written notice to Contractor, may object to any determinations of price adjustment and additional time which are not in accordance with ...
Work Changes. The County reserves the right to order changes in the Work to be performed under this Agreement by altering, adding to, or deducting from the Work. All such changes shall be incorporated in written change orders executed by the County authorizing and directing a change in services. Such change orders shall specify the changes ordered and any necessary adjustment of compensation and completion time and shall be delivered to Contractor. Contractor must submit any claim regarding such adjustment in price or completion time in writing within thirty (30) days of receiving notice of the change order. If the Parties cannot reach an agreement on the terms for performing the changed work within a reasonable time to avoid delay or other unfavorable impacts as determined by the County in its sole discretion, the County shall have the right to determine reasonable terms, and the Contractor shall proceed with the changed work. No claim for additional compensation or extension of time shall be recognized, unless contained in a written change order duly executed on behalf of the County.
Work Changes. Company shall have the right to make Changes and Provider shall have the right to request Changes. Provider must include appropriate supporting documentation with any requested Change. Changes shall be documented in a Change Order. The cost or credit for any Change shall be determined, at the Company's option, by one or more of the following methods: (i) utilizing prices and/or rates set forth in this Agreement, (ii) mutual acceptance of a properly itemized lump sum, (iii) actual cost which may include a mutually acceptable fixed or percentage fee, or (iv) competitive bid or other basis. In case any Change shall result in a Work decrease, Provider shall receive no allowance in computing the decrease in the amount for loss of anticipated revenue or profits, but if Provider, before receiving Company's Change Order, shall have incurred any cost which the Change shall render unneeded or useless, Company shall make an allowance to Provider as Company shall determine to be fair and reasonable. Provider is deemed to accept any Change Order unless Provider objects to, or rejects, the Change Order in writing within ten (10) days of receipt in accordance with Section 14.02, Notices. Company must approve a Provider requested Change in writing. PAYMENT; AUDIT RIGHTS
Work Changes. The Town reserves the right to order work changes including additions, deletions, or modifications, without invalidating the contract, and agrees to make corresponding adjustments in the contract price and time of termination. All changes will be authorized by a written change order signed by the Town or by the engineer as its agent. The change order will include conforming changes in the contract and termination time. Work shall be changed, and the contract price and termination time shall be modified only as set out in the written change order. Any adjustment in the contract sum resulting in a credit or a charge to the Town shall be determined by agreement of the parties, or by arbitration, before starting the work involved in the change.
Work Changes. Owner reserves the right to order work changes in the nature of additions, deletions, or modifications, without invalidating this agreement, and agrees to make corresponding adjustments in the contract price and in time for completion. All changes will be authorized by a written change order signed by Project Manager or a duly authorized officer of Owner, which shall define the change and shall set forth any change to the contract price and completion dates. Work shall be changed and the contract price and completion shall be modified only as set out in the written change order. Any adjustment in the purchase price resulting in a credit or a charge to Owner shall be determined by mutual agreement of the parties or by arbitration before starting the work involved in the change.
Work Changes. The City reserves the right to order work changes in the nature of additions, deletions, or modifications without invalidating the Contract, and agrees to make corresponding adjustments in the Contract price and time for completion. Any and all changes must be authorized by a written change order signed by the City’s Purchasing Agent or his designee as representing the City. Work shall be changed and the Contract price and completion time shall be modified only as set out in the written change order. Any adjustment in the Contract price resulting in a credit or a charge to the City shall be determined by mutual agreement of the parties before starting the work involved in the change. Any dispute concerning work changes which is not resolved by mutual agreement shall be decided by the City Manager who shall reduce the decision to writing. The decision of the City Manager shall be final and conclusive.
Work Changes. Any changes of work shifts for Maintenance-Custodians shall be made on a voluntary basis, or if no volunteer is available, then on an involuntary basis, in inverse order of seniority. Shift changes may be made in emergency situations on a temporary basis only; but may be made otherwise, for good cause.
Work Changes. Notwithstanding anything to the contrary contained herein, the Company will not direct or permit the performance of any work (i) pursuant to any single Work Change which would result, by itself, in an increase in the cost of any Line Item in excess of the Individual Budget Change Amount, (ii) pursuant to any single Work Change which, together with the aggregate of all Work Changes theretofore executed or carried out by the Company, would result in an increase or decrease in aggregate cost of Construction of the Improvements in excess of the Aggregate Budget Change Amount, nor (iii) pursuant to any single Work Change which would have the effect of (x) materially increasing or reducing the gross square footage of the Improvements as a whole or (y) modifying any of the design elements or construction techniques of the Improvements in any way which would adversely affect the quality of the Improvements as a whole; unless in each case it shall have received the prior written approval of the Bank. Approval by the Bank of any such Work Change shall not obligate the Bank to make any Disbursement on account of such Work Changes unless the costs therefor are reflected in the Budget. No Work Change shall be made unless the Company shall have obtained such approvals as shall be necessary under the requirements of ARPE and/or the Planning Board of Puerto Rico.
