Time and Schedule. A Preliminary Design and Construction Schedule, including major milestones for the production of the Design Development Documents and Construction Documents, as well as the anticipated time required for construction, is attached as Exhibit D and is incorporated into and made a part of this Contract by reference. The Design Professional and the Owner agree that the time limits shown in the schedule for design are reasonable and achievable. Changes in the major milestone dates will require the consent of both parties, which shall not be unreasonably withheld.
Time and Schedule. A Preliminary Design and Construction Schedule, including major milestones for the production of the design and construction documents, as well as the anticipated time required for construction is to be attached to each Design Order as Exhibit B and is incorporated into and made a part of this Contract by reference.
Time and Schedule. 3.1.1 Time is of the essence as to the prosecution of the Subcontract Work.
3.1.2 If requested, the Subcontractor shall provide the Contractor with scheduling information and Subcontractor's proposed schedule for the Subcontract Work. The Contractor may prepare the Schedule of Work for the Project.
3.1.3 Within seven (7) days of receiving the Schedule of the Work and any updates thereto the Subcontractor shall review such and notify the Contractor in writing of Subcontractor’s acceptance or of any revisions the Subcontractor believes should be made. Any agreed upon revisions shall be the basis for a “no cost” Change Order. If the parties cannot agree upon revisions to the Schedule of Work, Contractor may issue a Written Authorization to Proceed pursuant to Paragraph 5.1 directing performance in accordance with the Schedule of Work as provided by Contractor. The Subcontractor’s failure to provide written notice of acceptance or revisions within the seven (7) days shall constitute acceptance by the Subcontractor and a waiver of Subcontractor’s right to assert a claim seeking an extension of the Subcontractor’s time for performance or an adjustment of the Subcontract Price based on objections or revisions later raised by the Subcontractor.
3.1.4 Contractor shall have the right to modify the construction schedule, to suspend, delay or accelerate, in whole or in part, the commencement or execution of Subcontract Work, or vary the sequence thereof, without compensation to the Subcontractor. In the event such a delay or suspension extends the overall time of performance, the time for the Subcontractor to complete its work shall be extended.
3.1.5 The Subcontractor shall commence the Subcontract Work promptly upon notice to proceed. The Subcontractor shall prosecute the Subcontract Work in a prompt and diligent manner as directed by the Contractor and in accordance with the Schedule of Work without hindering the Work of the Contractor or any other subcontractor. The Subcontractor shall
Time and Schedule. Consultant has sole and absolute control over all work schedule and service delivery dates.
Time and Schedule. Design-Builder shall submit a final project schedule as described in Article 2.1. The progress schedule shall be revised by the Design-builder at least monthly to reflect all changes in contract Work and adjustments in time, money, or both that are approved by the Owner. The schedule shall show the date of commencement of work on each pertinent phase or item of construction, percentage of scheduled completion at the end of each fifteen (15) days, and the date of completion of each phase or item of work. The progress schedule shall indicate labor, materials, and equipment actually incorporated in the Work (construction in place). No progress shall be indicated for materials and equipment on the site but not incorporated into the Work. The schedule shall be submitted each month with the Pay Request, in duplicate. No payment will be made without the progress schedule.
Time and Schedule. Unless specifically identified in this Agreement, HWC’s services and compensation will be for a reasonable period of time for completion of the Project. HWC acknowledges the importance to the CLIENT of the CLIENT’s project schedule and agrees to put forth reasonable efforts in performing the services with due diligence under this Agreement in a manner consistent with that schedule, as provided in Exhibit B hereto. The CLIENT understands, however, that HWC’s performance must be governed by sound professional practices. If in this Agreement, specific periods of time for rendering services are set forth or specific dates by which services are to be completed are provided, and if such periods of time or dates are changed through no fault of HWC, for reasons including but not limited to delay of state or municipal agencies in approvals or other governmental decisions regarding the Project, or delay in site or land acquisition, the rates and amounts of compensation provided herein shall be subject to equitable adjustment. If CLIENT has requested changes in the scope, extent, or character of the Project, the rates and amounts of compensation, and time of performance of HWC’s services shall be adjusted equitably. If the Project is suspended for more than thirty (30) calendar days in the aggregate, through no fault of HWC, and/or in whole or in part by CLIENT, HWC shall be compensated for services performed and charges incurred prior to receipt of notice to suspend, and, upon resumption, an equitable adjustment in fees to accommodate the resulting demobilization and remobilization costs. In the event of such suspension, or if HWC’s services are extended by Contractor’s actions or inactions for more than sixty (60) calendar days beyond the original scheduled completion date through no fault of HWC, there shall be an equitable adjustment in the Project schedule based on the delay caused by the suspension or the Contractor. In the event the Project is suspended for more than ninety (90) days in the aggregate, HWC or CLIENT may, at its option, terminate this Agreement upon giving notice in writing to the other party. HWC shall be entitled to full payment for services rendered to the date of voluntary termination. HWC is not responsible for delays caused by factors beyond HWC’s reasonable control, including but not limited to delays because of strikes, lockouts, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other regulatory authorit...
Time and Schedule. The time periods for the performance of Designer/Builder's services and work are as follows: Work can begin immediately upon signature of this Contract and authorization of the first Task Order. The schedule for each activity will be specified within each Task Order. Owner will authorize each task based upon their funding availability and CDM will not proceed without a written authorization via Task Order.
Time and Schedule. 4.1 The Contractor shall diligently prosecute the Work, with adequate forces and achieve Substantial Completion, Physical Completion, and Completion within the Contract Time. The Contractor shall not commence any Work until the Owner has issued the written Notice to Proceed. Notice to Proceed will not be issued until the contract has been executed and any required contract bonds, evidence of insurance, Inclusion Plan and Schedules have been approved by the Owner. The Contractor shall begin on the date specified in the Notice to proceed and shall bear all risks for any Work begun prior to such Notice.
Time and Schedule. We anticipate that Tasks 1-3 can be completed within four months. We have identified four meeting with the last meeting being a final presentation to the Staff and/or Commission. This final meeting will occur in Month 5.
Time and Schedule. Time is of the essence in the performance and completion of the Work pursuant to the Subcontract and this Agreement. Subcontractor shall commence and complete the Work in accordance to the Job Schedule established by the Contractor or the Owner, and Subcontractor acknowledges that it is familiar with such Job Schedule. Subcontractor agrees to complete the entire contract and provide necessary workmen to do the said job within the period of time required, or allotted by the Contractor so that Contractor is not held up on project. It is the intention of the parties that the Subcontractor shall be responsible for completion of the entire job within the time allotted for the work to be completed by the General Contractor and it shall be Subcontractor’s duty and responsibility to schedule the work so that overtime or extra personnel is not necessary. In the event that Subcontractor falls behind the Job Schedule such that, in the sole and reasonable judgment of Contractor, it appears that Subcontractor will not complete the work on a Project within the established Job Schedule, or that Subcontractor will not complete identifiable portions of the Work within the Job Schedule required for completion of that/those portion(s) of the Work, then Subcontractor shall, upon written request of Contractor, work overtime, additional shifts, or adopt such other procedures as may be necessary to restore adherence to the Job Schedule. The full cost of any such overtime work, additional shifts, etc. and/or other procedures shall be borne wholly by Subcontractor. In executing this Agreement and any Work Order, Subcontractor covenants and specifically agrees for itself and for each subcontractor, employee, labourer, mechanic, material and equipment supplier and all other persons acting through or under Subcontractor that no claim or claims shall be filed, asserted and/or maintained by it, them or any of them against Contractor, Architect, Landlord or any other Subcontractors for damages or monetary/financial losses incurred as a result of delays in the work of another Subcontractor. Subcontractor shall cause this covenant to be inserted in and made a part of each and every subcontract that it executes with respect to the Work. Delays, if claimed by Subcontractor and considered justifiable by Contractor will be balanced by an extension of time to the required completion date of the Work concerned. Subcontractor for itself and for each subcontractor acting through it thereunder fur...