BASIC SERVICES; CONSTRUCTION PHASE Sample Clauses

BASIC SERVICES; CONSTRUCTION PHASE. 4.1. Administration and Coordination of Construction Contract and Construction. CM will provide administrative, management and related services necessary to administer the Construction Contract for an Assigned Project, including, without limitation: (i) receive, review and forward to the District and the Architect the Contractor(s)’ Certificates of Insurance and Bonds along with commentary as to the extent to which the same comply with requirements of the Construction Contract; (ii) advice and recommendations to the District for issuance of Notice(s) to Proceed directing commencement of construction of the Assigned Project or portions thereof; issuance of the Notice(s) to Proceed on behalf of the District as directed or authorized by the District; (iii) scheduling, coordinating and conducting pre-construction and construction meetings; recording, maintaining and distributing minutes thereof; (iv) in consultation with the Architect, develop and implement procedures for the submittal and processing of Submittals; (v) in consultation with the District and the Architect, develop and implement procedures for the handling and disposition of the Contractor’s requests for information or clarifications; (vi) establish and implement procedures for the transmittal and receipt of communications, drawings and other information between CM, Architect and the Contractor relating to construction of the Assigned Project; (vii) assist the District in selection and retention of Test/Inspection Service Providers and the Project Inspector; (viii) review the Contractor’s Construction Schedules and implement provisions of the Construction Contract relating to the Contractor’s obligations for development, maintenance, updating and compliance with the Construction Schedule for the Assigned Project; and (ix) establish Site staging, lay down and storage areas. The CM’s Basic Services relating to Assigned Project communications shall utilize forms, processes and other measures implemented by the District in connection with construction of the Assigned Project, including without limitation, the eDocs web-based document control management system implemented by the District for the Assigned Projects.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
BASIC SERVICES; CONSTRUCTION PHASE. 1. All of the Engineer’s Construction Phase Services (“Construction Phase Services”) as described in this Article 1, Section D Shall be performed on an “as requested” basis. The Contractor shall determine the level of effort required for such Services and pay for same on time and expense basis, as described in Addendum A. 2. The Engineer shall timely review and approve or otherwise respond to the Contractor’s submittals, including shop drawings, product data and samples, but only for the limited purpose of checking for conformance with information given by Engineer and the design concept expressed in the Construction Documents. Where requested by Contractor, Engineer shall review submittals for specific details but without any liability to Engineer arising from such review. Any detailed review shall not relieve Contractor of responsibility to construct the Project in accordance with the Issued for Construction Documents. The Engineer’s review shall not constitute approval of safety precautions or of construction means, methods, techniques, sequences or procedures. 3. The Engineer shall furnish interpretations and clarifications of the drawings and specifications, by means of additional drawings, addenda or otherwise, as are necessary for the proper execution and progress of the Project. All such interpretations and clarifications shall be consistent with the intent of the Construction Documents and reasonably inferable from them. 4. The Engineer shall communicate with the Owner and the Contractor’s subcontractors and suppliers only through the Contractor. 5. The Engineer shall have reasonable access to the Project site as necessary to perform the Construction Phase Services that are requested of it. 6. The Engineer shall visit the Project site as requested by Contractor or pursuant to such schedule as the Parties may establish, to become generally familiar with the quality of the construction. After each Project site visit, the Engineer shall promptly provide the Contractor with copies of all notes and field reports. Although the Engineer has no responsibility to discover defects or deficiencies in the construction, if the Engineer becomes aware of any such defects or deficiencies, it shall give prompt written notice to the Contractor. The Engineer shall not be responsible for construction means, methods, techniques, sequences or procedures, or for ensuring that the Contractor’s Work is in accordance with the Construction Documents. 7. The Engineer is not ...
Sample 1
BASIC SERVICES; CONSTRUCTION PHASE. A. The City will provide general construction administration of the construction contract. Consultant shall provide support when requested by the City.
Sample 1
BASIC SERVICES; CONSTRUCTION PHASE. The Contractor's basic --------------------------------- services following Owner's approval of the Fixed Price Agreement are described below. (1) The Contractor shall obtain necessary approvals of the Plans and Specifications by the governmental authorities having jurisdiction over the Project, which includes the obtaining of a building permit ("BUILDING PERMIT"), the cost for which shall be the obligation of Owner, which cost shall be set forth in the Fixed Price Agreement. Owner agrees that all permits necessary for the handling, processing and/or packaging of food products and/or which are mandated by health and food safety governmental department shall be the obligation of Owner to obtain, which permits are collectively referred to as "HEALTH/FOOD PERMITS." (2) During the course of construction, the Contractor shall prosecute the Work diligently to completion with the sufficient people on the job at all times and shall cooperate with and provide access and coordination for the electrical installation and preparation for and installation of equipment by contractors engaged directly by the Owner. (3) Unless otherwise provided in the Contract Documents, the Contractor shall pay for labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation and other facilities and services necessary for proper execution and completion of the Work. (4) The Contractor shall correct Work which does not conform to the Construction Documents, unless approved in writing by Owner. (5) The Contractor shall give notices and comply with laws, ordinances, rules, regulations and lawful orders of public authorities relating to the Project. (6) The Contractor at all times shall keep the Property and surrounding area free from dust which might become a nuisance to other property owners, accumulation of waste materials or rubbish caused by the operations under the Agreement. At the completion of the Work, the Contractor shall remove from and about the Project the Contractor's tools, construction equipment, machinery, surplus materials, waste materials and rubbish. If after first giving seven (7) days written notice to Contractor, the Contractor fails to clean up at the completion of the Work, the Owner may do so as provided in the Contract Documents, and the cost thereof shall be deducted from the Contract Sum. Contractor shall perform the following final cleaning activities for all trades at the completion of the Work: (i) Remove an...
Sample 1
BASIC SERVICES; CONSTRUCTION PHASE 
Sample 1Sample 2Sample 3

Related to BASIC SERVICES; CONSTRUCTION PHASE

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • PRE-CONSTRUCTION PHASE FEE The Pre-Construction Phase Fee is the total compensation payable to Contractor for the performance of Pre-Construction Phase Services, except for Additional Pre-Construction Phase Services approved in advance and in writing by Owner. The Pre-Construction Phase Fee shall be a lump sum amount based on the AACC established in this Agreement. 6.1 Except as specifically allowed by Owner, Contractor shall not be entitled to any increase in the Pre-Construction Phase Fee for any costs, expenses, liabilities or other obligations arising from the performance of Pre-Construction Phase Services. 6.2 Costs associated with the following items are specifically, but not exclusively, included in the establishment of the Pre-Construction Phase Fee: profit and profit sharing; general overhead; salaries and labor; housing and relocation; estimating, scheduling and information management systems and software; contract administration; office expenses; printing and copying; consulting fees; legal or accounting fees; cost of money; taxes; insurance premiums and deductibles; bond costs; purchase or rental of equipment; utilities; travel; per diem; fines or penalties; and damage awards. 6.3 If the scope of the Pre-Construction Phase Services is changed materially, the Pre- Construction Phase Fee shall be equitably adjusted. If the AACC is changed materially before acceptance of the GMP Proposal, the Pre-Construction Phase Fee shall be adjusted in writing in proportion to the change in the AACC. There shall be no adjustments in the Pre-Construction Phase Fee following acceptance of the GMP Proposal. 6.4 For Additional Pre-Construction Phase Services that are approved in advance and in writing by Owner, Contractor shall be entitled to additional compensation computed as follows: 6.4.1 A pre-established lump sum amount; or 6.4.2 The hourly cost of Contractor’s employees or consultants who actually perform the Additional Services based on the employee’s Worker Wage Rate or prorated Monthly Rate plus the actual cost of allowable expenses incurred in the performance of the Additional Pre-Construction Phase Services, plus an overhead and profit markup of ten percent (10%) of the total cost; or 6.4.3 As otherwise agreed in advance and in writing.

  • Pre-Construction Phase Employer’s Liability, Workers’ Compensation, Comprehensive General Liability and Comprehensive Automobile Liability in the amounts as set forth in the UGSC.

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Construction Phase Part 1 –

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items: 9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!