ARCHITECTURAL AND CONSTRUCTION PROCEDURES Sample Clauses

ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Landlord shall pay up to the amount of the “Landlord’s Contribution” (as defined below) towards the cost of the Tenant Improvement Work. Any additional cost of the Tenant Improvement Work, including additional costs resulting from “Changes” (as hereinafter defined) requested by Tenant, shall be borne solely by Tenant and paid to Landlord as hereinafter provided. Unless otherwise specified in the Plan or Cost Estimate, all materials, specifications and finishes utilized in constructing the Tenant Improvements shall be Landlord’s building standard tenant improvements, materials and specifications for the Project as set forth in Schedule I attached hereto (“Standard Improvements”). Should Landlord submit any additional plans, equipment specification sheets, or other matters to Tenant for approval or completion in connection with the Tenant Improvement Work, Tenant shall respond in writing, as appropriate, within 5 days unless a shorter period is provided herein. Tenant shall not unreasonably withhold its approval of any matter, and any disapproval shall be limited to items not previously approved by Tenant in the Plan or otherwise. B. In the event that Tenant requests in writing a revision to the Plan (“Change”), and Landlord so approves such Change as provided in Section 1.C below, Landlord shall advise Tenant by written change order as soon as is practical of any increase in the cost to complete the Tenant Improvement Work that such Change would cause. Such cost of the Change shall include an administrative/supervision fee to be paid to Landlord or to Landlord’s management agent in the amount of 5% of the cost of such Change. Tenant shall approve or disapprove such change order in writing within 2 days following Tenant’s receipt of such change order. If Tenant approves any such change order, Landlord, at its election, may either (i) require as a condition to the effectiveness of such change order that Tenant pay the increase in the cost to complete attributable to such change order concurrently with delivery of Tenant’s approval of the change order, or (ii) defer Tenant’s payment of such increase until the date 10 days after delivery of invoices for same. If Tenant disapproves any such change order, Tenant shall nonetheless be responsible for the reasonable architectural and/or planning fees incurred in preparing such change order. Landlord shall have no obligation to interrupt or modify the Tenant Improvement Work pending Tenant’s approval of a change o...
Sample 1Sample 2See All (66)
AutoNDA by SimpleDocs
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Landlord and Tenant have approved the following plans and elevations dated November 15, 1996 prepared by Ware & Xalcxxx Xxxhitects, Inc., which together shall constitute the approved "Site Plan and Elevations": Site Plan (Sheet A-1.1), Partial Floor Plan (Sheet A-2.1), Partial Floor Plan (Sheet A-2.2), Mezzanine Plan, Stair Plans/Section & Canopy Plan (Sheet A-2.3), Partial Roof Plan (Sheet A-3.1), Partial Roof Plan (Sheet 3.2), Exterior Elevations (Sheet A-4), Wall Sections (Sheet A-5.1) and Wall Section and Enlarged Stair Plans (Sheet A-5.2). Landlord and Tenant have also approved that certain Outline Specification and Project Description Warehouse/Midtech Buildings dated 10/1/96 attached hereto as EXHIBIT X-1 (the "Outline Specification"), and certain Proposed Oak Canyon Streetscape Plan attached hereto as EXHIBIT X-2 for the off-site improvement of Oak Canyon Road (the "Oak Canyon Streetscape Plan"). The Outline Specification is hereby modified to replace the requirement for an Elevator in the "Tenant Office and Building Lobby/Core Improvements" section with a requirement for an area within the lobby of the Building for future installation of an elevator, shaft and related equipment and devices. B. On or before ninety (90) days from and after the execution of this Lease, Landlord shall submit to Tenant for Tenant's approval each of the following: (i) preliminary plans (the "Preliminary Shell Plans") for the construction of the shell Building and the landscaping, walkways, parking areas and lighting of the Site, prepared by Landlord's architect and based on the Site Plan and Elevations, which plans shall incorporate the specifications for the Building shell and site work set forth in the Sections entitled "Site Work" and "Building Shell" of the Outline Specification and fencing to enclose the truck loading area on the east side of the Site (the "Loading Fence"), (ii) space plans for the interior improvements of the Premises prepared by Landlord's architect, which space plans shall include interior partitions, ceilings, interior finishes, interior doors, suite entrance, floor coverings, window coverings, lighting, electrical and telephone outlets and plumbing connections, and which space plans shall incorporate the specifications set forth in the Section entitled "Tenant Office and Building Lobby/Core Improvements" of the Outline Specification together with plans (the "Lunch Area Plans") for an outdoor employee lunch area (the "Lunch Area") on the Sit...
Sample 1
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Landlord shall cause its contractor to construct the Tenant Improvements at Landlord’s sole cost and expense, provided that any additional cost resulting from “Changes” (as hereinafter defined) requested by Tenant and “Alternates” shown in the Plan which are elected by Tenant (if any) shall be borne solely by Tenant and paid to Landlord as hereinafter provided. Unless otherwise specified in the Plan, all materials, specifications and finishes utilized in constructing the Tenant Improvements shall be Landlord’s building standard tenant improvements, materials and specifications for the Project (“Standard Improvements”), except for those additions or variations to Building Standard Improvements expressly approved by Landlord and noted on the Plan (any such addition or variation from the Standard Improvements shall be referred to herein as a “Non-Standard Improvement”). Should Landlord submit any additional plans, equipment specification sheets, or other matters to Tenant for approval or completion in connection with the Tenant Improvement Work, Tenant shall respond in writing, as appropriate, within 5 business days unless a shorter period is provided herein. Tenant shall not unreasonably withhold its approval of any matter, and any disapproval shall be limited to items not previously approved by Tenant in the Plan or otherwise.
Sample 1
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Tenant shall engage Design Blitz for the preparation of a detailed space plan for the Premises which includes interior partitions, ceilings, interior finishes, interior office doors, suite entrance, floor coverings, window coverings, lighting, electrical and telephone outlets, plumbing connections, heavy floor loads and other special requirements (“Preliminary Plan”). Upon completion of the Preliminary Plan, Landlord and Tenant shall approve an estimate of the cost to complete the Tenant Improvements in accordance with the Preliminary Plan (“Preliminary Cost Estimate”), which Preliminary Cost Estimate will be based upon estimated costs provided by Landlord’s contractor. To the extent applicable, the Preliminary Plan shall include Landlord’s building standard tenant improvements, materials and specifications for the Project as set forth in Schedule I attached hereto (“Standard Improvements”), except for changes and additions specifically requested by Tenant and approved by Landlord in writing (any such addition or variation from the Standard Improvements shall be referred to herein as a “Non-Standard Improvement”). In all events, Tenant shall approve in all respects a Preliminary Plan and a Preliminary Cost Estimate for the 43 Discovery Premises not later than May 31, 2018 (“Plan Approval Date”), it being understood that Tenant’s failure to do so shall constitute a “Tenant Delay” (as defined below).
Sample 1
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Landlord shall cause its contractor to construct the Tenant Improvements shown on the Plan at Landlord's sole cost and expense. In addition, Landlord shall pay up to the amount of the "Landlord's Contribution" (as defined below) towards any additional cost resulting from a "Change" (as hereinafter defined) requested by Tenant. Unless otherwise specified in the Plan or in any Change approved by Landlord, all materials, specifications and finishes utilized in constructing the Tenant Improvements shall be Landlord's building standard tenant improvements, materials and specifications for the Project ("STANDARD IMPROVEMENTS"). Should Landlord submit any additional plans, equipment specification sheets, or other matters to Tenant for approval or completion in connection with the Tenant Improvement Work, Tenant shall respond in writing, as appropriate, within five (5) days unless a shorter period is provided herein. Tenant shall not unreasonably withhold its approval of any matter, and any disapproval shall be limited to items not previously approved by Tenant in the Plan or otherwise.
Sample 1
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Tenant and Landlord have approved prior to the execution of this Lease, both (i) a detailed space plan for the Premises dated November 20, 1998 and consisting of Sheets PP1, PP2 and PP3, prepared by Landlord's architect, Xxxx & Xxxxxxx Architects, Inc. ("Preliminary Plan"), and (ii) an estimate dated November 24, 1998, prepared by Landlord's contractor, Insignia/ESG of California, Inc., of the cost for which Landlord will complete or cause to be completed the Tenant Improvements ("Preliminary Cost Estimate"). B. Prior to the execution of this Lease, Tenant has provided in writing to Landlord or Landlord's architect all specifications and information requested by Landlord for the preparation of final construction documents and costing, including without limitation Tenant's final selection of wall and floor finishes, complete specifications and locations (including load and HVAC requirements) of Tenant's equipment, and details of all "Non-Standard Improvements" (as defined below) to be installed in the Premises (collectively, "Programming Information"). Tenant understands that final construction documents for the Tenant Improvements shall be predicated on the Programming Information, and accordingly agrees that such information provided to Landlord is accurate and complete. C. Except as specified in the Preliminary Plan, the Tenant Improvements shall incorporate Landlord's building standard materials and specifications ("Standards") described with particularity in the Section entitled "Tenant Improvements" of that certain Outline Specifications and Project Description dated September 22, 1997 (the "Outline Specifications"). A copy of the Outline Specifications is attached as Exhibit X-1 hereto. No deviations from the Standards shall be permitted, provided that Landlord may, in its reasonable discretion, authorize in writing one or more of such deviations if requested by Tenant. Subject to the express provisions of Article II.A below, any excess cost of such deviations shall be part of "Tenant's Contribution" (as hereinafter defined). Notwithstanding anything to the contrary contained in the foregoing, Landlord shall in no event be required to approve any deviations from the Standards ("Non-Standard Improvements") if Landlord determines that such improvement (i) is of a lesser quality than the corresponding Standard, (ii) fails to conform to applicable governmental requirements, (iii) requires building services beyond the level normally provided to other t...
Sample 1
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Concurrently with sign-off by Tenant, the space plans, construction drawings and specifications for all improvements and finishes, together with any changes thereto, shall be submitted to Landlord (with samples as required) for review and approval by Landlord and its architect for the Project. To the extent applicable, the build-out of the Tenant Improvements shall include Landlord’s building standard tenant improvements, materials and specifications for the Project. Should Landlord approve work that would necessitate any ancillary Building modification or other expenditure by Landlord, then except to the extent of any remaining balance of the “Landlord Contribution” as described below, Tenant shall, in addition to its other obligations herein, promptly fund the cost thereof to Landlord.
Sample 1
AutoNDA by SimpleDocs
ARCHITECTURAL AND CONSTRUCTION PROCEDURES 
Sample 1

Related to ARCHITECTURAL AND CONSTRUCTION PROCEDURES

  • SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.

  • Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Design and Construction In complying with the requirements of the specification both with respect to arrangement and detail, design is to conform to the best current engineering practice. Each of the several parts of the material is to be of the maker’s standard design provided that this design is in general accordance with the specification. The essence of design should be simplicity and reliability in order to give long continuous service with high economy and low maintenance cost. Particular attention should be paid to internal and external access in order to facilitate inspection, cleaning and maintenance. The design dimensions and materials of all parts are to be such that they will not suffer damage as a result of stresses under the most severe conditions. Fully detailed specifications of the several parts of the material are to be submitted describing particularly the materials to be used. The materials used in the construction of the material are to be of the highest quality and selected particularly to meet the duties required of them. Mechanisms are to be constructed to avoid sticking due to rust or corrosion. Workmanship and general finish are to be of the highest class throughout. All similar parts of the material are to be interchangeable. All equipment is to operate without undue vibration and with the least possible amount of noise and is not to cause a nuisance. All equipment is to be designed to minimize the risk of fire and any damage, which may be caused in the event of fire. The equipment is also to be designed to prevent ingress of all vermin, accidental contact with live parts and to minimize the ingress of dust and dirt. The use of materials, which may be liable to attack by termites or other insects, is to be avoided.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Applicable Law and Construction This Lease may be executed in counterparts, shall be construed as a sealed instrument, and shall be governed exclusively by the provisions hereof and by the laws of the state where the Property is located without regard to principles of choice of law or conflicts of law. A facsimile signature to this Lease shall be sufficient to prove the execution by a party. If any provisions shall to any extent be invalid, the remainder shall not be affected. Other than contemporaneous instruments executed and delivered of even date, if any, this Lease contains all of the agreements between Landlord and Tenant relating in any way to the Premises and supersedes all prior agreements and dealings between them. There are no oral agreements between Landlord and Tenant relating to this Lease or the Premises. This Lease may be amended only by instrument in writing executed and delivered by both Landlord and Tenant. The provisions of this Lease shall bind Landlord and Tenant and their respective successors and assigns, and shall inure to the benefit of Landlord and its successors and assigns and of Tenant and its permitted successors and assigns, subject to Article 13. The titles are for convenience only and shall not be considered a part of this Lease. This Lease shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared primarily by counsel for one of the parties, it being recognized that both Landlord and Tenant have contributed substantially and materially to the preparation of this Lease. If Tenant is granted any extension or other option, to be effective the exercise (and notice thereof) shall be unconditional; and if Tenant purports to condition the exercise of any option or to vary its terms in any manner, then the purported exercise shall be ineffective. The enumeration of specific examples of a general provision shall not be construed as a limitation of the general provision. Unless a party’s approval or consent is required by the express terms of this Lease not to be unreasonably withheld, such approval or consent may be withheld in the party’s sole discretion. The submission of a form of this Lease or any summary of its terms shall not constitute an offer by Landlord to Tenant; but a leasehold shall only be created and the parties bound when this Lease is executed and delivered by both Landlord and Tenant and approved by the holder of any mortgage of the Premises having the right to approve this Lease. Nothing herein shall be construed as creating the relationship between Landlord and Tenant of principal and agent, or of partners or joint venturers or any relationship other than landlord and tenant. This Lease and all consents, notices, approvals and all other related documents may be reproduced by any party by any electronic means or by facsimile, photographic, microfilm, microfiche or other reproduction process and the originals may be destroyed; and each party agrees that any reproductions shall be as admissible in evidence in any judicial or administrative proceeding as the original itself (whether or not the original is in existence and whether or not reproduction was made in the regular course of business), and that any further reproduction of such reproduction shall likewise be admissible. If any payment in the nature of interest provided for in this Lease shall exceed the maximum interest permitted under controlling law, as established by final judgment of a court, then such interest shall instead be at the maximum permitted interest rate as established by such judgment.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!