General Responsibilities of the Contractor Sample Clauses

General Responsibilities of the Contractor. 1. The Contractor agrees to carry out his responsibilities in accordance with the provisions of the present Contract, and to undertake the Project in accordance with LOST policies and procedures. 2. The contractor has read and understood the “Contractor Declaration Form” as defined by LOST and commits to respect its terms by signing the “Declaration to respect LOST Good Business Regulations” attached to this Contract. 3. The Contractor shall determine and communicate to LOST the name of the person having the ultimate authority and responsibility for the Project on its behalf (“Project Manager”). The Project Manager shall be appointed by the Contractor, in consultation and with the approval of LOST. The approval of the Contractor’s personnel may at any time be withdrawn by LOST for reasons such as but not limited to: (a) Breach of any of the terms of contract; (b) Failure to respond to LOST’s communications timely; (c) Failure to attend scheduled meetings; (d) Failure to act respectfully and professionally; (e) Failure to supervise the Works according to professional standards and good practices: (f) Failure to respect policies and procedures If approval of any of the Contractor personnel is withdrawn by LOST, the Contractor shall, after receiving notice of such withdrawal, remove the relevant personnel from the Works and shall not thereafter employ him again on the Works in any capacity, and shall replace him by another person to be approved by LOST. 4. The contractor shall accept that the working area will be always accessible for LOST Project Manager and other LOST representatives and the donor. 5. The Contractor shall be fully responsible for all services performed by its personnel, agents, employees, or contractors (hereinafter referred to as "Personnel"). The Contractor personnel shall not be considered in any respect as being the employees or agents of LOST. The Contractor shall ensure that all relevant Lebanese labor laws are observed. LOST does not accept any liability for claims arising out of the activities performed under the present Contract, or any claims for death, bodily injury, disability, damage to property or other hazards that may be suffered by Contractor personnel as a result of their work pertaining to the Project. It is understood that adequate medical and life insurance for Contractor personnel, as well as insurance coverage for service incurred illness, injury, disability or death, is the responsibility of the Contractor. The Contr...
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
General Responsibilities of the Contractor. The Contractor shall: 1. Furnish evidence of (i) comprehensive commercial general liability insurance coverage on an occurrence basis with limits not less than One Million and 00/100 Dollars ($1,000,000) per occurrence and an aggregate of Two Million and 00/100 Dollars ($2,000,000), said coverage not to exclude liability for any lead related work; coverage to name the City of Elmira and Enterprise Community Partners, Inc., their officers and employees as additional insured’s on a primary basis; (ii) Xxxxxxx’x Compensation and Disability Insurance, as applicable; (iii) environmental pollution liability insurance coverage with limits not less than One Million and 00/100 Dollars ($1,000,000); and (iv) general contractor’s auto insurance with limits not less than limits not less than One Million and 00/100 Dollars ($1,000,000). 2. Obtain and pay for all permits and licenses necessary for the completion and execution of the Work to be performed. Such permits and licenses shall set forth the actual cost of the Work to be performed; 3. Perform the Work in conformance with the manufacturer’s instructions, and the applicable codes and ordinances, including the New York State Uniform Fire Prevention and Building Code, whether or not covered by the Work write-Up and/or drawings for the work. The contractor shall promptly notify the Department of any inconsistencies between the Work Write-Up and such manufacturer’s instructions and/or applicable codes; 4. Keep the Premises in broom-clean condition and orderly during the course of the Work and remove all debris upon completion of the Work. Materials and equipment that have been removed and replaced as part of the work shall belong to the Contractor, unless otherwise specified in writing; 5. Not assign the Contract without the written consent of the Owner and the Department; 6. Assume full responsibility to the Owner for all sub-contractors; and 7. Not change, delete, or add any item to the Agreement, Work Write-Up or plans, without the execution of a written change order signed by the Owner, Contractor and Department. If any extras are approved, the change order must not be executed, nor work started, until the Department confirms that there are sufficient funds available to pay the work to be performed under the change order. The Contractor hereby guarantees the Work to be free from all defects in workmanship or materials for a period of one (1) year from the date of final acceptance of the Work required by this Contr...
Sample 1
General Responsibilities of the Contractor. 1. The Contractor understands that it must receive approval by Non-Profit prior to commencing any work on the Owner’s property, evidenced by a Notice to Proceed. 2. The Contractor shall supervise and direct the work using its best skills and attention. 3. The Contractor shall post and provide the Owner or his/her agent and Non-Profit with evidence that it has secured and paid for all licenses and permits necessary for the proper execution of the work; and upon completion of the job shall provide evidence that all work has been inspected and approved by the appropriate building inspectors prior to the release of the final payment. 4. The Contractor will furnish all supervision, labor, materials, machinery, tools, equipment, and services and perform and complete all the work of this Contract in an efficient and workmanlike manner. 5. The Contractor shall be responsible for the acts and omissions of all its employees, and all Subcontractors, their agent(s) and employees, suppliers and material men and all other persons performing any of the work. 6. The Contractor shall not assign this Contract without written consent of the Owner and Non-Profit. Any request for assignment must be addressed to Non-Profit at the address listed below. 7. The Contractor at all times shall keep the premises free from accumulation of waste materials or rubbish caused by its work. Clean up and removal from the site of all debris and waste materials resulting from his work shall be the responsibility of the Contractor. Materials and equipment that have been removed and replaced as part of the work shall belong to the Contractor and shall be removed from the site unless other Non-Profit and/or the County to examine and inspect the rehabilitation work under the Contract at any reasonable time.
Sample 1
General Responsibilities of the Contractor. 1. Contractor to operate the facility in a safe and responsible manner that shall not endanger personnel or Equipment; 2. Contractor’s operator shall be on site a minimum of 40 hours per week; 3. Contractor’s operator shall notify the County and assist in scheduling and managing preventive and normal maintenance as required by all manufacturer’s instructions or recommendations and good engineering practice, and other preventive maintenance and unplanned maintenance; 4. Contractor’s operator will perform minor non-routine repairs to equipment in accordance with good engineering practice, manufacturer’s recommendations, all applicable laws, regulations, and all government authorizations as necessary to operate the plant. 5. Contractor ‘s operator will coordinate with the County to schedule with other vendors for major and routine repairs. Contractor will work to ensure that during repairs, plant downtime is minimized to the greatest extent possible and will notify County and Sacramento Municipal Utility District (SMUD) as listed in table below: Scheduling for power County notifies SMUD County will email SMUD production every two after discussing with at least one day prior to weeks Contractor’s operator by due date (cc Contractor) email. County will send a reminder to Contractor’s operator at least two days prior to the two weeks notification to SMUD and get the most updated power production information. Schedules Preventive Contractor’s operator will County will notify SMUD Maintenance (PM) for notify County by phone at least one day prior to engines and any other and email at least two PM work. maintenance that will days in advance of PM impact power generation work. Emergency shout down Contractor’s operator will County will update the notify SMUD (Real Time power production Scheduling) and County spreadsheet schedule and immediately. Contractor’s will email to SMUD for operator will estimate the Day Ahead Trading (cc how many hours the plant Contractor). will be down for. SMUD’s Real Time Scheduling will need to know when power will come back on‐ line. To schedule for one hour block of time SMUD needs to know the schedule for the next two hour. Forced PG&E Outage Contractor’s operator will County will update the notify County and SMUD power production by phone and email spreadsheet schedule and immediately. will send to SMUD for the Day Ahead Trading (cc Contractor). 6. Contractor’s operations shall be in compliance with Federal, State and local regulati...
Sample 1
General Responsibilities of the Contractor. 6.1 The Contractor shall supervise and direct the work using Contractor’s best skills and attention. The Contractor shall be solely responsible for all the means, methods, techniques, sequences, and procedures relating to the construction, and for coordinating all portions of the Work. All work shall be performed in a workmanlike manner according to standard practices. 6.2 The Contractor shall provide evidence that Contractor has secured and paid for all licenses and permits necessary for the proper execution of the Work, prior to commencing the Work for which the permits were issued. 6.3 The Contractor shall be responsible for the acts and omissions of all Contractor’s employees, and all other persons performing any of the Work. 6.4 The Contractor may not assign or transfer this Contract in any manner without the written consent of the City. 6.5 When adjacent property is affected or endangered by any Work done under this Contract, it shall be the responsibility of the Contractor to take whatever steps are necessary for the protection of the adjacent property, and to return the property to the same condition it was prior to the Work, all at the cost of the Contractor. The Contractor shall notify the City of such hazards prior to commencing the Work. The City assumes no third party or direct liability for any damage or injury to adjacent property, its owners or passersby. 6.6 The Contractor shall permit the City to examine and inspect the Work at any reasonable time. 6.7 All subcontractors shall be bound by the terms and conditions of this Contract insofar as it applies to their work, but this shall not relieve the Contractor from the responsibility to the Owner and City for the proper completion of all Work and Contractor shall not be released or relieved from the responsibilities and obligations under this Contract by virtue of any subcontract. All subcontractors hired by the Contractor to complete any work hereunder shall be licensed in Florida in the applicable trade for which they were hired and shall carry the same insurance Contractor is required to obtain and maintain under this Contract. Subcontractors for the Work shall not be debarred, suspended or otherwise ineligible to perform work for the City or other governments in accordance with the same conditions that apply to the Contractor. 6.8 Unless otherwise specifically noted, the Contractor shall provide and pay for all labor, withholding and unemployment taxes, materials, tools, construction equ...
Sample 1

Related to General Responsibilities of the Contractor

  • General Responsibilities of the Parties 1. The Parties will work together in a spirit of cooperation and partnership, with the responsibilities and accountabilities set out in this Agreement, to implement the Programme Documents in full in a timely, efficient, and effective, manner. 2. The Parties agree to carry out their respective responsibilities in accordance with the provisions of this Agreement, including the Programme Documents. 3. The Parties shall keep each other informed of all relevant activities pertaining to the implementation of the Programme Documents, and shall hold consultations when either Party considers it appropriate, including any circumstance that may affect the achievement of the results of the Programme and the Programme Documents. 4. The Parties shall fulfill their commitments with the fullest regard for the terms and conditions of this Agreement and the principles of the United Nations.

  • General Responsibilities Issuer hereby engages Distributor to act as exclusive distributor of the shares of each class of the Funds. The Funds subject to this Agreement as of the date hereof are identified on SCHEDULE A, which may be amended from time to time in accordance with Section 11 below. Sales of a Fund's shares shall be made only to investors residing in those states in which such Fund is registered. After effectiveness of each Fund’s registration statement, Distributor will hold itself available to receive, as agent for the Fund, and will receive by mail, telex, telephone, or such other method as may be agreed upon between Distributor and Issuer, orders for the purchase of Fund shares, and will accept or reject such orders on behalf of the Fund in accordance with the provisions of the applicable Fund’s prospectus. Distributor will be available to transmit orders, as promptly as possible after it accepts such orders, to the Fund’s transfer agent for processing at the shares’ net asset value next determined in accordance with the prospectuses.

  • Contractor’s General Responsibilities The Contractor, regardless of any delegation or subcontract entered by the Contractor, shall be responsible for the following when providing information technology staff augmentation services: 3.1 The Contractor is responsible for the comprehensive management of Staff. Staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment and the Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of Staff. 3.2 The Contractor shall provide Staff in accordance with Customer Requests for Quote (RFQ), and as described in Contract Exhibit J, Job Family Descriptions document. Customers may include detailed scopes of work, specific requirements of the work to be performed, and any requirements of Staff within the Request for Quote. 3.3 The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified Staff to perform the services requested by the Customer. 3.4 The Contractor shall provide Customers with Staff who have sufficient skill and experience to perform the services assigned to them. 3.5 The Contractor is responsible for ensuring that all information technology staff augmentation services furnished under the Contract meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances. 3.6 The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s Staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market. 3.7 The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s Staff. 3.8 The Contractor, throughout the term of the Contract, shall maintain all licenses, permits, qualifications, insurance, and approvals of whatever nature that are legally required for Contractor and Staff to perform the information technology staff augmentation services. 3.9 Contractor shall be responsible for all costs associated with the administration of this Contract. 3.10 The Contractor shall adhere to all work policies, procedures, and standards established by the Department and Customer. 3.11 The Contractor shall ensure that Staff conform with the Customer’s policies in all respects while on the Customer’s premises, and is responsible for obtaining all rules, regulations, policies, etc. 3.12 Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks.

  • Additional Responsibilities This paragraph applies to all phases of Architect's work. (a) Architect shall be responsible for the professional quality, technical accuracy, timely completion and coordination of all of Architect's work, including that performed by Architect's consultants, and including designs, Drawings, Specifications, reports and other services, irrespective of Owner's approval or acquiescence in same. Architect shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his work. (b) Architect shall be responsible, in accordance with applicable law, to Owner for all loss or damage to Owner caused by Architect's negligent act or omission; except that Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any requirement to obtain a certificate of review as a condition precedent to commencement of an action, including any such requirements set forth in Section 00-00-000, C.R.S. or similar statute. (c) Architect's professional responsibility shall comply with the standard of care applicable to the type of engineering and architectural services provided, commensurate with the size, scope and nature of the Project. (d) Architect shall be completely responsible for the safety of Architect's employees in the execution of work under this Agreement, shall provide all necessary safety equipment for said employees, and shall hold harmless and indemnify and defend Owner from any and all claims, suits, loss or injury to Architect's employees. (e) Architect acknowledges that, due to the nature of architectural and related professional services and the impact of same on the Project, the Owner has a substantial interest in the personnel and consultants to whom Architect assigns principal responsibility for services performed under this Agreement. Consequently, Architect represents that Architect has selected and intends to employ or assign the key personnel and consultants identified in Appendix C - "Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project assignments and areas of responsibility stated therein. Within 10 days of execution of this Agreement, Owner shall have the right to object in writing to employment on the Project of any such key person, consultant or assignment of principal responsibility, in which case Architect will employ alternate personnel for such function or reassign such responsibility to another to whom Owner has no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any person to whom Owner has reasonable objection. Within 5 days of execution of this Agreement, Architect shall designate in writing a Project representative who shall have complete authority to bind Architect, and to whom Owner should address communications. (f) Promptly after execution of this Agreement and upon receipt of authorization from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order in which Architect proposes to accomplish his work, with dates on which he will commence and complete each major work item. The schedule shall provide for performance of the work in a timely manner so as to not delay Owner's time table for achievement of interim tasks and final completion of Project work, provided however, the Architect will not be responsible for delays beyond his control. (g) Before undertaking any work which Architect considers beyond or in addition to the scope of work and services which Architect has contractually agreed to perform under the terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or additional work should be performed, and (iii) a reasonable estimate of the cost of such work. Architect shall not proceed with such out of scope or additional work until authorized in writing by Owner. The compensation for such authorized work shall be negotiated, but in the event the parties fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule".

  • General Responsibility The Consultant shall, at all times during the Agreement, remain responsible. The Consultant agrees, if requested by the Commissioner of NYSDOT or his or her designee, to present evidence of its continuing legal authority to do business in New York State, integrity, experience, ability, prior performance, and organizational and financial capacity.

  • Mutual Responsibilities It is recognized by this Agreement to be the duty of the Company to explain fully the terms of this Agreement to all its officers, foremen and others engaged in a supervisory capacity and it is recognized to be the duty of the Union to explain fully to its members, its and their responsibilities and obligations under this Agreement.

  • School Responsibilities Pursuant to §1002.33(8)(e), F.S., the School shall be dissolved under the provisions of law under which the School was organized. Student records and copies of all administrative, operational, and financial records of the School shall be provided to the Sponsor on the date the termination/non-renewal takes effect.

  • Professional Responsibilities Other activities to support the delivery of the Xxxxxx Xxxxxx Business Plan and Xxxxxx Mission Strategic Plan, as requested by your manager • As an employee, be responsible under the Work Health & Safety Act for the health and safety of all persons they come into contact with, during employment • All hazards and injuries must be reported through the normal process as set out in Xxxxxx Mission’s Work Health, Safety and Rehabilitation Quality Management System and site procedures • Participate in the review and maintenance of industry specific and internal audit processes, as per Xxxxxx Mission’s standard policy and procedures • In relation to Xxxxxx Mission and the Uniting Church in Australia, attend such functions, meetings, seminars, training courses as directed by your supervisor • In relation to Xxxxxx Mission attend worship services as encouraged by your supervisor • Participate on a quarterly basis in Xxxxxx Mission’s Employee contribution and development process • Take responsibility for personal career development and training • Participate in Xxxxxx Mission’s Orientation program, so as to gain an understanding of, and • promote, the application of the EEO, Affirmative Action, Privacy Act, Work Health & Safety Act and other relevant legislation • Administer Xxxxxx Mission’s philosophy of care and other relevant policy documents as appropriate • Demonstrate responsible stewardship of all resources, and willingness to report impropriety in keeping with the values of Xxxxxx Mission • Ensure the reputation and integrity of Xxxxxx Mission is maintained at all times • Maintain confidentiality

  • Custodial Responsibilities (a) Each Custodian shall provide access to the Mortgage Loan Documents in possession of the applicable Custodian regarding the related Mortgage Loans and REO Property and the servicing thereof to the Trustee, the Certificateholders, the FDIC, and the supervisory agents and examiners of the FDIC, such access being afforded only upon reasonable prior written request and during normal business hours at the office of the applicable Custodian. Each Custodian shall allow representatives of the above entities to photocopy any of the records and documentation and shall provide equipment for that purpose at the expense of the person requesting such access. (b) Each Custodian may resign from its obligations hereunder upon 60 days' prior written notice to the Trustee, the Depositor, the Securities Administrator and the Servicers. Such resignation shall take effect upon (i) the appointment of a successor Custodian reasonably acceptable to the Depositor within such 60 day period; and (ii) delivery of all Mortgage Loan Files to the successor Custodian. The Trustee shall have the right, but not the obligation, to become the successor Custodian. If no successor Custodian is appointed within 60 days after written notice of such Custxxxxx'x xesignation is received by the Trustee, the applicable Custxxxxx xxx petition a court of competent jurisdiction to appoint a successor Custodian. Upon such resignation and appointment of succesxxx Xxxxxdian, the applicable Custodian shall, at such Custodian's expense, xxxxxxxx transfer to the successor Custodian, as directed in writing by the Trustee, all applicable Mortgage Files being administered under this Agreement. Notwithstanding the foregoing, the Trust Fund, not the applicable Custodian, shall bear the costs relating to the transfer of Mortgage Files if such Custodian shall resign with cause (including such Custodian's resignation due to the failure of such Custodian to be paid xxx xxxx due to such Custodian hereunder). (c) For so long as reports are required to be filed with the Commission under the Exchange Act with respect to the Trust, each Custodian shall not utilize any Subcontractor for the performance of its duties hereunder if such Subcontractor would be "participating in the servicing function" within the meaning of Item 1122 of Regulation AB without the prior written consent of the Depositor, in its sole discretion. (d) Each Custodian shall indemnify the Depositor, the Sponsor, the Securities Administrator and any director, officer, employee, agent and affiliate of the Depositor, the Sponsor or the Securities Administrator and hold them harmless against any and all claims, losses, damages, penalties, fines, forfeitures, reasonable and necessary legal fees and related costs, judgments, and any other costs, fees and expenses that any of them may sustain in any way related to (i) the failure of the applicable Custodian to deliver when required any assessment of compliance required to be delivered by the applicable Custodian or (ii) any material misstatement or omission contained in any assessment of compliance provided to be delivered by the applicable Custodian. This indemnity shall survive the termination of this Agreement or the earlier resignation or removal of the applicable Custodian. (e) Notwithstanding anything in this Agreement to the contrary, no Custodian shall be required to deliver, or to cause to be delivered, an assessment of compliance or accountant's attestation report pursuant to Section 3.23 for any fiscal year of the Trust in which the Custodian's Weighted Average Percentage is 5% or less. The "Custodian's Weighted Average Percentage" means, for each fiscal year of the Trust and each Custodian, the quotient, expressed as a percentage, of (A) the aggregate of the Stated Principal Balance for each Distribution Date in such fiscal year of the Mortgage Loans for which such Custodian acted as Custodian divided by (B) the aggregate of the Pool Stated Principal Balance for each Distribution Date in such fiscal year.

  • Personal Responsibility The Participant and his/her parent(s) or legal guardian(s) certify that Participant has no physical or mental condition that precludes him/her from participating in the Activities and that he/she is not participating against medical advice.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!